The URL can be used to link to this page

Home My WebLink About3725 Sheridan BoulevardCity of Wheat Ridge Residential Roofing PERMIT - 201709053 PERMIT NO: 201709053 ISSUED: 11/14/2017 JOB ADDRESS: 3725 Sheridan BLVD EXPIRES: 11/14/2018 JOB DESCRIPTION: Permit to install 20.67 squares 7/12 pitch IKO Cambridge IR Asphalt shingles, house only **Revision add redecking 20.67sq** *** CONTACTS *** OWNER (303)424-5633 HAMILTON CHRIS SUB (303)679-8509 Mark Schymanski 160210 Genesis Construction Inc. *** PARCEL INFO *** ZONE CODE: UA / Unassigned USE: UA / Unassigned SUBDIVISION CODE: 2412 / LAKESIDE, STEWART GARDENS, OLI BLOCK/LOT#: 0 / *** FEE SUMMARY *** ESTIMATED PROJECT VALUATION: 7,780.00 FEES Total Valuation 0.00 Use Tax 163.38 Permit Fee 172.60 ** TOTAL ** 335.98 *** COMMENTS *** *** CONDITIONS *** Midroof & Final Roof inspections for ROOFS 6/12 PITCH & OVER: 3rd party inspection will be required for both the midroof and final inspections. The 3rd party inspection report AND THE ORIGINAL PERMIT CARD needs to be dropped off to the Permit Desk at the City of Wheat Ridge. The report MUST BE SIGNED by the Homeowner. REGARDING ROOF VENTILATION: Roof ventilation shall comply with IBC Sec. 1203.2 or IRC Sec. R806. The installation of ridge venting requires the installation or existence of soffit venting. For calculation purposes, one hat or turtle vent equal to one-half of one square foot of opening. Effective December 1, 2014, asphalt shingle installations require an approved midroof inspection, conducted when 25-75 percent of the roof covering is installed, prior to final approval. Installation of roof sheathing (new or overlay) is required on the entire roof when spaced or board sheathing with ANY gap exceeding one half inch exists. Sheathing and mid -roofs may be called in at the same time, one hundred percent of the sheathing must be complete and 25-75 percent of the mid -roof may be complete. Asphalt shingles are required to be fastened to the roof deck with a minimum of 6 nails per shingle. Ice and water shield is required. Eave and rake metal is required. A ladder extending 3 feet above the roof eave and secured in place is required to be provided for all roof inspections. Roof ventilation is required to comply with applicable codes and/or manufacturer installation instructions, whichever is more stringent. In order to pass a final inspection of elastomeric or similar type roof coverings, a letter of inspection and approval from the manufacturer technical representative stating that "the application of the roof at (project address) has been applied in accordance with the installation instruction for (roof material brand name) roof covering" is required to be on site at the time of final inspection. City of Wheat Ridge Residential Roofing PERMIT - 201709053 PERMIT NO: 201709053 ISSUED: 11/14/2017 JOB ADDRESS: 3725 Sheridan BLVD EXPIRES: 11/14/2018 JOB DESCRIPTION: Permit to install 20.67 squares 7/12 pitch IKO Cambridge IR Asphalt shingles, house only **Revision add redecking 20.67sq** 1, by m signature, do hereby attest that the work to be performed shall comply with all accompanying approved plans and specifications, applicable building codes, and all applicable municipal codes, policies and procedures, and that 1 am the legal owner or have been authorized by the legal owner of the property and am authorized to obtain this permit and perform the work described and approved in conjunction with this permit. I further attest that I am legally authorized to include alI entities named within this document as partes to the work to be performed and that all work to be performed is disclosed in this document and/or its' accompanying approved plans and specifications. Signature of OWNER or CONTRACTOR (Circle one) Date I . This permit was issued based on the information provided in the permit application and accompanying )Tans and specifications and is subject to the compliance with those documents, and all applicable statutes, ordinances, regulations, policies and procedures. 2. This permit shall expire 365 days after the date of issuance regardless of activity. Requests for extension must be made in writing and received prior to the date of expiration. An extension of no more than 180 days made be granted at the discretion of the Chief Building Official and may be subject to a fee equal to one-half of the original permit fee. 3. If this permit expires, a new permit may be required to be obtained. Issuance of a new permit shall be subject to the standard requirements, fees and procedures for approval of any new permit. Re -issuance or extension of expired permits is at the sole discretion of the Chief Building Official and is not guaranteed. 4, No work of an manner shall be performed that shall results in a changeof the natural flow of water without prior and specific approval. 5. The permit holder shall notify the Building and Inspection Services Division in accordance with established policy of all required inspections and shall not proceed or conceal work without written approval of such work from the Building and Inspection Services Division. 6. The issuance or granting of a permit shall not be construed to be a permit for or an approval of, any violation of any provision of any applicable code or any ordinance or regulation of this jurisdiction. Approval of work is subject to field inspection. Signature of Chief Building Officialbate, REQUESTS MUST BE MADE BY 11:59PM ANY BUSINESS DAY FOR IN PECTION THE FOLLOWING BUSINESS DAY. City of ��W heat dge COMMLJNiTy DEVELOPMENT Building & Inspection Services Division 7500 W. 291h Ave., Wheat Ridge, CO 80033 Office: 303-235-2855 * Fax: 303-237-8929 Inspection Line: 303-234-5933 Email: perm its(a-)ci.wheatridge.co.us FOR OFFICE USE ONLY Date: �,�J j -7 Add to Permit #�17 7 Building Permit Revision/Amendment Application *** Please complete all highlighted areas on both sides of this form. Incomplete applications may not be processed. *** Property Address: '-�7W 31t'<-( Property Owner (please print): ��,, i ; �'1� 1 �-;� Phone: 06, iiy (r 7� 1 C) Property Owner Email: La mo Mailing Address: (if different than property address) Address , State, Zip: Submitting Company: LXA��i`� Contact Person: L-6-� �`�� Phone: C? Contractor: t7h'` ��(t(��c� c�•� Contractors City License #: Phone: fn��/ ' ��5.�'a 2' Contractor E-mail Address: Please Note: Additional valuation must include all general and subcontracted work to be performed related to the revisions and/or amendments declared in the description of work and which were not included in the original permit valuation. If revisions or amendments increase the original valuation, additional fees will be due at the time of approval. Depending on the scope of work, additional plan review fees may be due upon approval ($60.00 an hour — 2 hour minimum). Description of revised/amended work: Pfd �2eDec k,00% Sq. Ft./LF �{G- Amps Btu's Gallons Squares 1 (D • (C -� Other Additional Project Value: (Must include all general and subcontracted work to be performed related to revisions/amendments described above) 00 OWNER/CONTRACTOR SIGNATURE OF UNDERSTANDING AND AGREEMENT I hereby certify that the setback distances proposed by this permit application are accurate and do not violate applicable ordinances, rules or regulations of the City of Wheat Ridge or covenants, easements or restrictions of record; that all measurements shown and allegations made are accurate; that I have read and agree to abide by all conditions printed on this application and that I assume full responsibility for compliance with applicable City of Wheat Ridge codes and ordinances for work under any permit issued based on this application; that I am the legal owner or have been authorized by the legal owner of the property to perform the described work and am also authorized by the legal owner of any entity included on this application to list that entity on this application. CIRCLE ONE: (OWNER) (CONTRACTOR) or (AUTHORIZED REPRESENTATIVE) )oof (OWNER) (CONTRACTOR) PRINT NAME: 1 ii��f H (�+, SIGNATURE: Lz` / `- ��-DATE: ZONING COMMMENTS: Reviewer: BUILDING DEPARTMENT COMMENTS: Reviewer: PUBLIC WORKS COMMENTS: Reviewer: PROOF OF SUBMISSION FORMS Fire Department ❑ Received ❑ Not Required Water District ❑ Received ❑ Not Required Sanitation District ❑ Received ❑ Not Required DEPARTMENT USE ONLY OCCUPANCY CLASSIFICATION: Building Division Valuation: $ ADDITIONAL PROVISIONS- Unless otherwise specified herein, the following additional provisions are expressl inc— r t d ' h' 1 Contract, Plans, Specifications, Permits and Fees. The work described in this contract shall be done according to the plans and the plan specifica- tions (if any) except in the case of conflict when the provisions of this contract shall have control over both the plans and the plan specifications. All required building permits will be paid for by owner and obtained by Contractor. All other charges, taxes, assessments, fees etc., of any kind whatsoever, required by any government body, telephone or utility compa- ny or the like shall be paid for by Owner. 2.Installation. Contractor has the right to subcontract any part of, or all of, the work herein 3.Change Orders. Should Owner, construction lender, or any government body or inspector require any modification to the work covered under this contract, any cost incurred by Contractor shall be added to the contract price as extra work and Owner agrees to pay Contractor his normal selling price for such extra work. All extra work as well as any other modifications to the original contract shall be specified and approved by both parties in a written change order. All change orders as well as all insurance supple- ments, shall become a partof this contract and shall be incorporated herein. 4.Owner's Responsibility: insurance etc. Owner is responsible for the fol- lowing: (1) to see that all necessary water, electrical power, access to premises, and toilet facilities are provided on the premises. (2) to provide a storage area on the premises for equipment and materials. (3) to relocate and protect any item that prevents Contractor from having free access to the work areas such as but not limited to TV or radio antennas, vehicles, tools or garden equipment. In the event that Owner fails to relocate such items, Contractor may relocate these items as required but in no way is Contractor responsible for damage to these items during their relocation and during the performance of the work. (4) to obtain permission from the owner(s) of adjacent property(ies) that Contractor must use to gain access to the work areas. Owner agrees to be responsible and to hold Contractor harmless and accept any risks resulting from the use of adjacent property(ies) by Contractor. (5) to correct any existing defects which are recognized during the course of the work. Contractor shall have no liability for correcting any existing defects such as, but not limited to, dry rot, structural defects, or code violations. (6) to maintain property insurance with Fire, Course of Construction, all Physical Loss with Vandalism and Malicious Mischief clauses attached, in a sum at least equal to the contract price, prior to and during performance of this contract. If the project is destroyed or damaged by an accident, disaster or calamity, or by theft or vandalism, any work or materials supplied by Contractor in reroofing or restoring the project shall be paid for by Owner as extra work. (7) to timely fill out and submit any documentation required by the insurance company. 5 -Delay. Contractor shall not be held responsible for any damage occa- sioned by delays resulting from: work done by Owner's subcontractors, extra work, acts of owner or owner's agent including failure of owner to make timely rogress payments or payments for extra work, shortages of material andyor labor, bad weather, fire, strike, war, governmental regula- tions, or any other contingencies unforeseen by Contractor or beyond Contractor's reasonable control. 6.Surplus Materials and Salvage. Any surplus materials left over after this contract has been completed are the property of Contractor and will be removed by same. No credit is due Owner on returns for any surplus materials because this contract is based upon a complete job. All salvage resulting from work under this contract is the property of Contractor. 7.Cleanup & Advertising. Upon completion, and after removing all debris and surplus materials, wherever possible, Contractor will leave premises in a neat, broom clean condition. Any debris consisting of dust, dirt, asphalt, or small bits of materials that settle into attics, garage areas, or any other area being worked over with open beam ceilings or no attic, is unavoidable and Contractor shall not be responsible for this cleanup. Contractor recom- mends that Owner lay out drop cloths to protect such areas wherever owner discovers debris infiltration. Owner hereby grants to Contractor the right to display signs and advertise at the job site for the period of time starting at the date of signing of this contract and continuing uninterrupted until fourteen (14) days past the date the job is completed and payment in full has been made. Owner grants Contractor the right to publish the project street address on a 'references" list and to take "before" and after" photos which may be given to prospective customers. 8.Concealed Damage & Dry Rot. Contractor will inform Owner of any dry rot or other sub -roof deterioration which is concealed and is discovered during the course of the work. Contractor is not responsible to repair any such discovered deterioration and any work done by Contractor to remedy such discovered deterioration will only be done as extra work in a written change order. 9 -Termites, Pests & Hazardous Substances. Owner understands that Con- tractor is not qualified or licensed as an inspector or abatement contractor for Hazardous Materials (as defined by the government), or for Pests (in- Cluding Termites). Should any such hazardous substances or Pest be sus- pected to be present on the premises, it is the Owners' responsibility to arrange and pay for inspection and abatement. Contractor cannot certify or warrant your building as being free of hazardous substances or pests. 10. Collection & Legal Fees. Owner agrees to pay all collection fees and charges that result should Owner default in payment of this contract. Overdue accounts are subject to interest charged at 18% per annum or at the highest rate allowed by law. In the event litigation or arbitration arises out of this contract, prevailing party(ies) are entitled to all legal, arbitration, and attorney fees. The court or arbitrator shall not be bound to award fees based on any set, fee schedule but shall if it so chooses, award the true amount of all costs, expenses and attorney fees paid or incurred. y po a e "to t Is contract: 11. Arbitration of Disputes. Any controversy or claim arising out of or relating to this proposal/contract, or the breach thereof, shall be settled by arbitration in accordance with the applicable Con- struction Industry Arbitration Rules of the American Arbitration Association which are in effect at the time the demand for arbitra- tion is filed. A judgment upon the award rendered by the arbitrator(s) may be entered in any court having jurisdiction there- of. Any arbitration award shall be subject to correction and/or vacation for the reasons stated in the law. The arbitrator shall award reasonable attorneys fees and expenses to the prevailing party. After being given due notice, should any party fail to appear at or participate in the arbitration proceedings, the arbitrator shall make an award based upon the evidence presented by the party(ies) who do (does) appear and participate. Notwithstanding Contractor's right to arbitrate, Contractor does not waive any of its lien rights. Venue for arbitration hearings shall be the project county unless otherwise agreed to by the parties. NOTICE: By initialing in the space below you are agreeing to have any dispute arising out of the matters included in the "arbitration of disputes" provision decided by neutral arbitration as provided by law and you are giving up any rights you might possess to have the dispute litigated in a court or jurytrial. By initialing in the space below you are giving up your judicial rights to discovery and ap- peal, unless those rights are specifically, included in the "arbitra- tion of disputes" provision. If you refuse to submit to arbitration after agreeing to this provision, you may be compelled to arbitrate under the authority of the applicable laws. Your agreement to this arbitration provision is voluntary. We have read and understand the foregoing and agree to submit disputes arising out of the matters included in the "arbitration of disputes" provision totraLrtrati on. I Agree to Arbitration:(Initalsner} (Initials of Owner) NOTICES PER COLORADO S838 1) If the client plans to use the proceeds of a property or casualty insurance policy to pay for the roofing work, the roofing contractor cannot pay, waive, rebate, or promise to pay, waive, or rebate all or part of any deductible applicable to the claim for payment for roofing work on the covered residential property. 2) Owner may rescind this contract if the insurer denies the claim in whole or in part, as long as the person notifies Contractor within 72 hours after the claim is denied. Contractor will refund any moneys paid by the customer within 10 days after receipt of this notice of rescission. Owner may not rescind the contract when supplemental claims for additional roofing services not reasonably foreseen at the time of initial inspection for this contract, (concealed damage for example), are denied by the Insurance Company. See provision (8) in this contract for details about concealed damage. Owner may give notice of rescission in writing to Contractor at the address listed herein on page one or by email to Contractor at the email listed herein (if any). Email notice of rescission is effective on the date of the email. Standard mail notice of rescission is effective upon deposit in the United States Mail, postage pre -paid. Personal delivery of notice of rescission is effective upon delivery. 3) If Owner rescinds this contract, Contractor may retain all or a portion of any payments or deposits made by Owner to compen- sate Contractor for roofing work actually performed on the residen- tial property in a workmanlike manner consistent with standard roofing industry practices. Contractor, however, may retain only an amount required to compensate Contractor for the actual work performed. Page TWO of 2 Total Pages