Loading...
HomeMy WebLinkAbout4014 Parfet StreetCity of Wheat Ridge E -Res. Window Replacement PERMIT - 201803316 PERMIT NO: 201803316 ISSUED: 12/31/2018 JOB ADDRESS: 4014 Parfet St EXPIRES: 12/31/2019 JOB DESCRIPTION: Residential window replacement -one window in living room, U -factor is .32. *** CONTACTS *** OWNER (303)907-3823 COLONNADE REAL SUB (770)433-8211 Gary Cummings 170102 Home Depot U.S.A., Inc. *** PARCEL INFO *** ZONE CODE: UA / Unassigned USE: UA / Unassigned SUBDIVISION CODE: 2403 / APPLEWOOD VILLAGES, PROSPECT V BLOCK/LOT#: 0 / *** FEE SUMMARY *** ESTIMATED PROJECT VALUATION: 799.00 FEES Window Replacement 50.00 Total Valuation 0.00 Use Tax 16.78 ** TOTAL ** 66.78 *** COMMENTS *** *** CONDITIONS *** Both the front and back of this permit are required to be posted on the job site at all times. If the complete permit is not present, inspections WILL NOT be performed. Work shall comply with 2012 IRC & 2017 NEC. Per IRC Sec. R314, smoke detectors are required to be installed in every sleeping room, in hallways outside of sleeping rooms, and on every level of the structure. I, by m signature, do hereby attest that the work to be performed shall comply with all accompanying approved plans and specifications; applicable building codes, and all applicable municipal codes, policies and procedures, and that I am the legal owner or have been authorized by the legal owner of the property and am authorized to obtain this permit and perform the work described and approved in conjunction with this permit. I further attest that I am legally authorized to include all entities named within this document as parties to the work to be performed and that all work to be performed is disclosed in this document and/or its' accompanying approved plans and specifications. Signature of OWNER or CONTRACTOR (Circle one) Date I. This permit was issued based on the information provided in the permit application and accompanying plans and specifications and is subject to the compliance with those documents, and all applicable statutes, ordinances, regulations, policies and procedures. 2. This permit shall expire 365 days after the date of issuance regardless of activity. Requests for extension must be made in writing and received prior to the date of expiration. An extension of no more than 180 days made be granted at the discretion of the Chief Building Official and may be subject to a fee equal to one-half of the originalpennit fee. 3. If this permit expires, a new permit may be required to be obtained. Issuance of a new permit shall be subject to the standard requirements, fees and procedures for approval of any new permit. Re -issuance or extension of expired permits is at the sole discretion of the Chief Building Official and is not guaranteed. 4. No work of any manner shall be performed that shall results in a change of the natural flow of water without prior and specific approval. 5. The permit holder shall notify the Building and Inspection Services Division in accordance with established policy of all required inspections and shall not proceed or conceal work without written approval of such work from the Building and Inspection Services Division. 6. The issuan�&= hall not be construed to be a permit for, or an approval of, any violation of any provision of any applicable gulation of this jurisdiction. Approval of work is subject to field inspection. Signature of Chief Building Official Date REQUESTS MUST BE MADE BY 11:59PM ANY BUSINESS DAY FOR INSPECTION THE FOLLOWING BUSINESS DAY. City of Wheat Ridge E -Res. Electrical Service Upgr PERMIT - 201900020 PERMIT NO: 201900020 ISSUED: 01/04/2019 JOB ADDRESS: 3845 Quay St EXPIRES: 01/04/2020 JOB DESCRIPTION: Electrical service change - 200 amps *** CONTACTS *** OWNER (303)968-5401 HENDRICKSON HENRY SUB (720)458-8411 Scott Berkman 080190 Current Installations *** PARCEL INFO *** ZONE CODE: UA / Unassigned USE: UA / Unassigned SUBDIVISION CODE: 2405 / BARTHS, COULEHAN GRANGE, WHEAT BLOCK/LOT#: 0 / *** FEE SUMMARY *** ESTIMATED PROJECT VALUATION: 2,250.00 FEES Total Valuation 0.00 Use Tax 47.25 Permit Fee 93.35 ** TOTAL ** 140.60 *** COMMENTS *** *** CONDITIONS *** Both the front and back of this permit are required to be posted on the job site at all times. If the complete permit is not present, inspections WILL NOT be performed. Work shall comply with 2012 IRC & 2017 NEC. Per IRC Sec. R314, smoke detectors are required to be installed in every sleeping room, in hallways outside of sleeping rooms, and on every level of the structure. I, by my signature, do hereby attest that the work to be performed shall comply with all accompanying approved plans and specifications, applicable building codes, and all applicable municipal codes, policies and procedures, and that I am the legal owner or have been authorized by the legal owner of the property and am authorized to obtain this permit and perform the work described and approved in conjunction with thispennit. I further attest that I am le ally authorized to include all entities named within this document as parties to the work to be performed and that all work to be performed Is disclosed in this document and/or its' accompanying approved plans and specifications. Signature of OWNER or CONTRACTOR (Circle one) Date I . This permit was issued based on the information provided in the permit application and accompanying plans and specifications and is subject to the compliance with those documents, and all applicable statutes, ordinances, regulations, policies and procedures. 2. This permit shall expire 365 days after the date of issuance regardless of activity. Requests for extension must be made in writing and received prior to the date of expiration. An extension of no more than 180 days made be granted at the discretion of the Chief Building Official and may be subject to a fee equal to one-half of the oriSinal permit fee. 3. If this permit expires, a new permit may be required to be obtained. issuance of a new permit shall be subject to the standard requirements, fees and procedures for approval of any new permit. Re -issuance or extension of expired permits is at the sole discretion of the Chief Building Official and is not guaranteed. 4. No work of any manner shall be performed that shall results in a change of the natural flow of water without prior and specific approval. 5. The permit holder shall notify the Building and Inspection Services Division in accordance with established policy of all required inspections and shall not proceed or conceal work without written approval of such work from the Building and Inspection Services Division. 6. The issuance or granting of a permit shall not be construed to be a permit for, or an approval of, an violation of any provision of any applicable code or any ordinance or regulation of this jurisdiction. Approval of work is subject to field inspection. Signature of Chief Building Official Date REQUESTS MUST BE MADE BY 11:59PM ANY BUSINESS DAY FOR INSPECTION THIS FOLLOWING BUSINESS DAY. Kimberly Cook c�4 From: no-reply@ci.wheatridge.co.us Sent: Friday, January 4, 2019 2:19 PM To: CommDev Permits Subject: Online Form Submittal: Residential Electrical Service Change/Upgrade Permit Application Categories: Kim Residential Electrical Service Change/Upgrade Permit Application This application is exclusively for RESIDENTIAL ELECTRICAL SERVICE CHANGE OR UPGRADE (200 amps or less). YOU MUST ATTACH A VALID CREDIT CARD AUTHORIZATION FORM IN ORDER FOR THE PERMIT TO BE PROCESSED. Your Permit will be emailed to the email address provided below once it is processed. THIS APPLICATION DOES NOT CONSTITUTE A PERMIT. DO NOT BEGIN WORK UNTIL PERMIT HAS BEEN ISSUED. Is this application for Yes electrical service change or upgrade - 200 amps or less? PROPERTY INFORMATION Property Address Property Owner Name Property Owner Phone Number (enter WITH dashes, eg 303-123-4567) Attach Credit Card Authorization Form - **DO NOT ATTACH RANDOM DOCUMENTS 3845 Quay St Henry Hendrickson 7204588411 Current Installations CC Authorization Form.pdf CONTRACTOR INFORMATION Contractor Business Current -Installations Name I Contractor's License 80190 Number (This is a 5 or 6 digit number for the City of Wheat Ridge) Contractor Phone 7204588411 Number (enter WITH dashes, eg 303-123-4567) Contractor Email Address gaby@current-installations.com Retype Contractor Email Address DESCRIPTION OF WORK Is this an electrical service upgrade or change? Number of Amps Location of upgrade/change (garage, house, etc) gaby@current-installations.com Change 200 house Provide additional details, n/a if needed. Project Value (contract 2000.00 value or cost of ALL materials and labor) SIGNATURE OF UNDERSTANDING AND AGREEMENT I assume full responsibility for compliance with applicable City of Wheat Ridge codes and ordinances for work under any permit issued based on this application. I understand that work may not begin on this property until a permit has been issued and posted on the property. Yes Yes z I certify that I have been Yes authorized by the legal owner of the property to submit this application and to perform the work described above. I attest that everything Yes stated in this application is true and correct and that falsifying information in this application is an act of fraud and may be punishable by fine, imprisonment, or both. Person Applying for Gaby Dominguez Permit Email not displaying correctly? View it in your browser. City of Wheat Ridge E -Res. Window Replacement PERMIT - 201803316 PERMIT NO: 201803316 ISSUED: 12/31/2018 JOB ADDRESS: 4014 Parfet St EXPIRES: 12/31/2019 JOB DESCRIPTION: Residential window replacement -one window in living room, U -factor is .32. *** CONTACTS *** OWNER (303)907-3823 COLONNADE REAL SUB (770)433-8211 Gary Cummings 170102 Home Depot U.S.A., Inc. *** PARCEL INFO *** ZONE CODE: UA / Unassigned USE: UA / Unassigned UBDIVISION CODE: 2403 / APPLEWOOD VILLAGES, PROSPECT V BLOCK/LOT#: 0 / *** FEE SUMMARY *** ESTIMATED PROJECT VALUATION: 799.00 FEES Window Replacement 50.00 Total Valuation 0.00 Use Tax 16.78 ** TOTAL ** 66.78 *** COMMENTS *** *** CONDITIONS *** Both the front and back of this permit are required to be posted on the job site at all times. If the complete permit is not present, inspections WILL NOT be performed. Work shall comply with 2012 IRC & 2017 NEC. Per IRC Sec. R314, smoke detectors are required to be installed in every sleeping room, in hallways outside of sleeping rooms, and on every level of the structure. I, by my signature, do hereby attest that the work to be performed shall comply with all accompanying approved plans and specifications, applicable building codes, and all applicable municipal codes, policies and procedures, and that I am the legal owner or have been authorized by the legal owner of the property and am authorized to obtain this permit and perform the work described and approved in conjunction with this ermit. I further attest that I am leggally authorized to include alI entities named within this document as parties to the work to be performed and that all work to be perf rmed is disclosed in this document and/or its' accompanying approved plans and specifications. Signature of OWNER or CONTRACTOR (Circle one) Date 1. This permit was issued based on the information provided in the permit application and accompanying plans and specifications and is subject to the compliance with those documents, and all applicable statutes, ordinances, regulations, policies and procedures. 2. Thispermit shall expire 365 days after the date of issuance regardless of activity. Requests for extension must be made in writing and received prior to the date of expiration. An extension of no more than 180 da s made be granted at the discretion of the Chief Building Official and may be subject to a fee equal to one-half of the original permit fee. 3. If this permit expires, a new permit may be required to be obtained. Issuance of a new permit shall be subject to the standard requirements, fees androcedures for approval of any new permit. Re -issuance or extension of expired permits is at the sole discretion of the Chief Building Offcial and is not guaranteed. 4. No work of any manner shall be performed that shall results in a changeof the natural flow of water without prior and specific approval. 5. The permit holder shall notify the Building and Inspection Services Division in accordance with established policy of all required inspections and shall not proceed or conceal work without written approval of such work from the Building and Inspection Services Division. The issuance or granting of a ermit shall not be construed to be a permit for, or an approval of, an violation of any provision of any applicable cor�any�ordm a or regulation of this jurisdiction. Approval of work is subject to field inspection. li Signature of Chief Building Official Date REQUESTS MUST BE MADE BY 11:59PM ANY BUSINESS DAY FOR INSPECTION THE FOLLOWING BUSINESS DAY. INSPECTION RECORD Inspection online form: http://www.ci.wheatridge.co.us/inspection Cancellations must be submitted via the online form before 8 a.m. the day of the inspection Inspections will not be performed unless this card is posted on the project site Request an inspection before MIDNIGHT (11:59 PM) to r ce' Zanspection the following business�ay /7 PERMIT: f `1°�lG' ADDRESS: JOB CODE: Foundation Inspections Date Inspector Initials � Comments 102 Caissons / Piers 103 Footing / P.E. Letter 104 Foundation Setback Cert. 105 Stem Walls 106 Foundation wall Insulation Do Not Pour Concrete Prior To Approval Of The Above Inspections Underground / Slab Inspections Date Inspector Initials Comments 201 Electrical / Cable/ Conduit 202 Sewer Underground Int. 203 Sewer Underground Ext. 204 Plumbing Underground Int. 205 Plumbing Underground Ext. 206 Water Underground Do Not Cover Underground or Below / In -Slab Work Prior To Approval Of The Above Inspections Rough Inspection Date Inspector Initials Comments 301 Rough Framing 302 Wall Sheathing 303 Roof Sheathing 304 Sheer Inspection 305 Insulation 306 Mid -Roof 307 Metal / Lath / Stucco 4 308 Rough Electrical Residential 309 Rough Electrical Commercial 310 Electrical Meter Residential 311 Electrical Meter Commercial 312 Temp. Const. Meter 313 Rough Plumbing Residential Rough Plumbing Commercial F135 S howerr Pan SEE OVER FOR ADDITIONAL INSPECTIONS PERMIT: C��`� ADDRESS:] ��� JOB CODE: eler Rough Inspection (continued) Date Inspector Initials Comments 316 Rough Mechanical Residential 317 Rough Mechanical Commercial 318 Boiler / Furnace 319 Hot water tank 320 Drywall screw and Nail 321 Moisture board / shower walls 322 Rough Grading 323 Miscellaneous l (117K Final Inspections Date Inspector Initials Comments 402 Gas Meter Release 403 Final Electrical Residential 404 Final Electrical Commercial 405 Final Mechanical Residential 406 Final Mechanical Commercial 407 Final Plumbing Residential 408 Final Plumbing Commercial 409 Final Roof l (117K 410 Final Window/Door 411 Landscape/Park/Planning* Inspections from these entities shall be requested one week in advance. "For landscaping and parking inspections please call 303-235-2846 **For ROW and drainage inspections please call 303-235-2861 ***For fire inspections please contact the Fire Protection District for your project. 412 Row/Drainage/Public Works** 413 Flood plain Inspection** 414 Fire Insp. / Fire Protection*** 415 Public Works Final** 416 Storm Water Mgmt.** 417 Zoning Final Inspection* 418 Building Final Inspection Note: All items must be completed and approved by Planning, Public Works, Fire and Building before a Certificate of Occupancy is issued. Approval of the Final Building Inspection does not constitute authorization of occupancy. For Low Voltage permits please be sure that rough inspections are completed by the Fire District and City of Wheat Ridge x �✓� Residential Roofing PERMIT - 201708876 PERMIT NO: 201708876 ISSUED: 11/06/2017 JOB ADDRESS: 4014 Parfet ST EXPIRES: 11/06/2018 JOB DESCRIPTION: Permit to reroof duplex, remove and replace 27 squares 4/12 pitch Certainteed Landmark IR Shingles *** CONTACTS *** OWNER (303)463-6787 HILDENBRAND CHRISTOPHER L SUB (303)798-0111 Larry Johnson 150247 My Home Solution Co., LLC *** PARCEL INFO *** ZONE CODE: UA / Unassigned USE: UA / Unassigned SUBDIVISION CODE: 2403 / APPLEWOOD VILLAGES, PROSPECT V BLOCK/LOT#: 0 / *** FEE SUMMARY *** ESTIMATED PROJECT VALUATION: 10,499.00 FEES Total Valuation 0.00 Use Tax 220.48 Permit Fee 220.15 ** TOTAL ** 440.63 *** COMMENTS *** *** CONDITIONS *** Midroof & Final Roof inspections for ROOFS 6/12 PITCH & OVER: 3rd party inspection will be required for both the midroof and final inspections. The 3rd party inspection report AND THE ORIGINAL PERMIT CARD needs to be dropped off to the Permit Desk at the City of Wheat Ridge. The report MUST BE SIGNED by the Homeowner. REGARDING ROOF VENTILATION: Roof ventilation shall comply with IBC Sec. 1203.2 or IRC Sec. R806. The installation of ridge venting requires the installation or existence of soffit venting. For calculation purposes, one hat or turtle vent equal to one-half of one square foot of opening. Effective December 1, 2014, asphalt shingle installations require an approved midroof inspection, conducted when 25-75 percent of the roof covering is installed, prior to final approval. Installation of roof sheathing (new or overlay) is required on the entire roof when spaced or board sheathing with ANY gap exceeding one half inch exists. Sheathing arid mid -roofs may be called in at the same time, one hundred percent of the sheathing must be complete and 25-75 percent of the mid -roof may be complete. Asphalt shingles are required to be fastened to the roof deck with a minimum of 6 nails per shingle. Ice and water shield is required. Eave and rake metal is required. A ladder extending 3 feet above the roof eave and secured in place is required to be provided for all roof inspections. Roof ventilation is required to comply with applicable codes and/or manufacturer installation instructions, whichever is more stringent. In order to pass a final inspection of elastomeric or similar type roof coverings, a letter of inspection and approval from the manufacturer technical representative stating that "the application of the roof at (project address) has been applied in accordance with the installation instruction for (roof material brand name) roof covering" is required to be on site at the time of final inspection. RESIDENTIAL ROOFING CONTRACT NO. MHC 17.108 191 University Blvd., #317 Denver, Colorado 80206 OFFICE: 303.798.0111 FAX: 303.798.5211 Owner's Name: uwner's Aaaress: Christopher Hildenbrand 9001 W. 38th Ave. Owner's City, State, Zip: Owner's Phone: Owner's Alt, Phone: Wheat Ridee. CO. 80033 303-907-4746 www.SUPEROOFS.com Cell Project Name & Address: Email: 4014 & 4034 Parfet Street. Wheat Ridge, CO. 80033 1 clhildenbrand@comcast.net I/WE, the Owner(s) of the premises described above authorize My Home Solution Colorado, LLC ciba Superoofs, hereinafter referred to as "Contractor , to furnish all materials and labor necessary to roof and/or improve these premises according to the following terms, specifications and provisions: PROPERTY OWNER IS INTENDING TO MAKE PAYMENT FROM THE PROCEEDS OF A PROPERTY AND CASUALTY INSURANCE POLICY. INITIALS a. scope of Roofing services and Materials to be Provided: Remove 27.60 squares of existing roofing material to clean deck on main dwell- ing; Replace with Certainteed Winterguard Ice & Water Shield on all eaves, valleys & penetrations; Certainteed Diamond Deck syn- thetic underlayment; 2" x4" drip edge on all eaves and rakes; CT Landmark shingles in (,,+c5Aw`,. ); Shadow Ridge cap; Replace all storm caps and collars, pipe jacks and chimney flashing's. $10,499.29 t� __- Owner may upgrade toLandmark lRClass-4shingles for $607.00 APPROVED \Q DECLINE Al. R&R,Prime& Paint 150 LF Gutter/ Downspout- aluminum -up to 5" $1,085.34: A2. Certainteed 4-Starextended Material warranty and 3-yearWorkmanship Warranty. No Charge SEE CONTINUATION PAGE *ACV & Deductible Due upon completion of roof. Depreciation Due When received from insurer. b. Description of any areas that will NOT be worked on: None This list of specifications may be continued on subsequent pages (see page number below). c. Approximate Costs of the Services for Damage Known at This Time: Contractor will perform the above, (subject to any additions and/or deductions pursuant to authorized change orders), for the Approximate Sum of $13,354.48+Permit Down Payment (if any) $ 6,048.49* INSURANCE: THIS AGREEMENT IS NULL AND VOID AND DOES NOT OBLIGATE ANY PARTY TO IT SHOULD THE INSURANCE COMPANY REFUSE COVERAGE UNDER THIS CLAIM OR SHOULD THE COVERAGE OFFERED BE INSUFFICIENT FOR CONTRACTOR TO PROPERLY DO THE WORK. THE ONLY COST TO THE PROPERTY OWNER IS THEIR DEDUCTIBLE, PLUS ANY UPGRADES CHOSEN OR ANY NON COVERED ITEMS THAT MUST BE REPLACED TO COMPLETE THE REPAIRS. THE CONTRACT BALANCE (ACTUAL CASH VALUE OF THE WORK) IS PAID BY YOUR INSURANCE COMPANY PER FINAL LOSS INVOICE. ALL PROCEEDS FROM THE INSURANCE COMPANY INCLUDING, BUT NOT LIMITED TO, PROCEEDS FOR SUPPLEMENTAL CLAIMS MADE BY CONTRACTOR ON BEHALF OF OWNER, PROCEEDS FOR PROFIT & OVERHEAD, AND PROCEEDS FOR RECOVERABLE DEPRECIATION, ARE GIVEN IN PAYMENT FOR THE WORK OF CONTRACTOR AND OWNER AGREES TO TIMELY, (WITHIN 24 HOURS OF RECEIPT BY OWNER), REMITALL SUCH PROCEEDS TO CONTRACTOR. PER COLORADO S1338, CONTRACTOR SHALL HOLD IN TRUST ANY PAYMENT FROM THE PROPERTY OWNER UNTIL CONTRACTOR HAS DELIVERED ROOFING MATERIALS AT THE RESIDENTIAL PROPERTY SITE OR HAS PERFORMED A MAJORITY OF THE ROOFING WORK ON THE RESIDENTIAL PROPERTY. d. Approximate Dates of Service: Substantial commencement of work shall mean either the physical delivery of materials onto the premises or the performance of any labor and shall be subject to any permissible delays as per provision (5) on the reverse side. Approximate Start Date: Oct 04, 2017 Approximate Completion Date: Oct 10, 2017 e. Acceptance: This contract is approved and accepted. I (we) understand there are no oral agreements or understandings between the parties of this agreement. The written terms, provisions, plans (if any) and specifications in this contract is the entire agreement between the parties. Changes in this agreement shall be done by written change order only and with the express approval of both parties. Changes may incur additional charges. Additional Provisions Of This Contract Are On The Reverse Side And May Be Continued On Subsequent Pages (see page number below). 1. app(oved an accepted (owner) date approved and accepted4owner) approved (contractor) date CANCELLATION POLICY: Your right to cancel this contract is limited to the following: You, the Buyer, may cancel this transaction at any time prior to midnight of the third business day after the date of this transaction. See the attached Notice of Cancellation form for an explanation of this right. Per Colorado SB38, you may also cancel this contract within 72 hours after being notified by your insurer that any part of or all: of your claim is denied. See the notice on the reverse side for an explanation of this right. NOTE: This contract may be withdrawn or renegotiated after NIA days from N/A if not approved and signed by BOTH parties. Form RC31-C Copyright © 1996-2016 ACT Contractors Forms (800) 820-5656 www.caltorm.com rage ewe or z iorai rages ADDITIONAL PROVISIONS- Unless otherwise specified herein, the following additional provisions are expressly incorporated into this contract: I. Contract, Plans, Specifications, Permits and Fees. The work described in this contract shall be done according to the plans and the plan specifica- tions (if any) except in the case of conflict when the provisions of this contract shall have control over both the plans and the plan specifications. All required building permits will be paid for by owner and obtained by Contractor. All other charges, taxes, assessments, fees etc., of any kind whatsoever, required by any government body, telephone or utility compa- ny or the like shall be paid for by Owner. 2.Installation. Contractor has the right to subcontract any part of, or all of, the work herein 3.Change Orders. Should Owner, construction lender, or any government body or inspector require any modification to the work covered under this contract, any cost incurred by Contractor shall be added to the contract price as extra work and Owner agrees to pay Contractor his normal selling price for such extra work. All extra work as well as any other modifications to the original contract shall be specified and approved by both parties in a written change order. All change orders as well as all insurance supple- ments, shall become a part of this contract and shall be incorporated herein. 4.Owner's Responsibility: Insurance etc. Owner is responsible for the fol- lowing: (1) to see that all necessary water, electrical power, access to premises, and toilet facilities are provided on the premises. (2) to provide a storage area on the premises for equipment and materials. (3) to relocate and protect any item that prevents Contractor from having free access to the work areas such as but not limited to TV or radio antennas, vehicles, tools or garden equipment. In the event that Owner fails to relocate such items, Contractor may relocate these items as required but in no way is Contractor responsible for damage to these items during their relocation and during the performance of the work. (4) to obtain permission from the owner(s) of adjacent property(ies) that Contractor must use to gain access to the work areas. Owner agrees to be responsible and to hold Contractor harmless and accept any risks resulting from the use of adjacent property(ies) by Contractor. (5) to correct any existing defects which are recognized during the course of the work. Contractor shall have no liability for correcting any existing defects such as, but not limited to, dry rot, structural defects, or code violations. (6) to maintain property insurance with Fire, Course of Construction, all Physical Loss with Vandalism and Malicious Mischief clauses attached, in a sum at least equal to the contract price, prior to and during performance of this contract. If the project is destroyed or damaged by an accident, disaster or calamity, or by theft or vandalism, any work or materials supplied by Contractor in reroofing or restoring the project shall be paid for by Owner as extra work. (7) to timely fill out and submit any documentation required by the insurance company. S.Delay. Contractor shall not be held responsible for any damage occa- sioned by delays resulting from: work done by Owner's subcontractors, extra work, acts of owner or owner's agent including failure of owner to make timelyrogress payments or payments for extra work, shortages of material andyor labor, bad weather, fire, strike, war, governmental regula- tions, or any other contingencies unforeseen by Contractor or beyond Contractor's reasonable control. 6.Surplus Materials and Salvage. Any surplus materials left over after this contract has been completed are the property of Contractor and will be removed by same. No credit is due Owner on returns for any surplus materials because this contract is based upon a complete job. All salvage resulting from work under this contract is the property of Contractor. 7.Cleanup &Advertising. Upon completion, and after removing all debris and surplus materials, wherever possible, Contractor will leave premises in a neat, broom clean condition. Any debris consisting of dust, dirt, asphalt, or small bits of materials that settle into attics, garage areas, or any other area being worked over with open beam ceilings or no attic, is unavoidable and Contractor shall not be responsible for this cleanup. Contractor recom- mends that Owner lay out drop cloths to protect such areas wherever owner discovers debris infiltration. Owner hereby grants to Contractor the right to display signs and advertise at the job site for the period of time starting at the date of signing of this contract and continuing uninterrupted until fourteen (14) days past the date the job is completed and payment in full has been made. Ownerrants Contractor the right to publish the project street address on a ' references" list and to take "before" and after' photos which may be given to prospective customers. 8.Concealed Damage & Dry Rot. Contractor will inform Owner of any dry rot or other sub -roof deterioration which is concealed and is discovered during the course of the work. Contractor is not responsible to repair any such discovered deterioration and any work done by Contractor to remedy such discovered deterioration will only be done as extra work in a written change order. 9.Termites, Pests & Hazardous Substances. Owner understands that Con- tractor is not qualified or licensed as an inspector or abatement contractor for Hazardous Materials (as defined by the government), or for Pests (in- cluding Termites). Should any such hazardous substances or Pest be sus- pected to be present on the premises, it is the Owners' responsibili to arrange and pay for inspection and abatement. Contractor cannot cert or warrant your building as being free of hazardous substances or pests. 10. Collection & Legal Fees. Owner agrees to pay all collection fees and charges that result should Owner default in payment of this contract. Overdue accounts are subject to interest charged at 18% per annum or at the highest rate allowed by law. In the event litigation or arbitration arises out of this contract, prevailing party(ies) are entitled to all legal, arbitration, and attorney fees. The court or arbitrator shall not be bound to award fees based on any set, fee schedule but shall if it so chooses, award the true amount of all costs, expenses and attorney fees paid or incurred. 11. Arbitration of Disputes. Any controversy or claim arising out of or relating to this proposal/contract, or the breach thereof, shall be settled by arbitration in accordance with the applicable Con- struction Industry Arbitration Rules of the American Arbitration Association which are in effect at the time the demand for arbitra- tion is filed. A judgment upon the award rendered by the arbitrator(s) may be entered in any court having jurisdiction there- of. Any arbitration award shall be subject to correction and/or vacation for the reasons stated in the law. The arbitrator shall award reasonable attorneys fees and expenses to the prevailing party. After being given due notice, should any party fail to appear at or participate in the arbitration proceedings, the arbitrator shall make an award based upon the evidence presented by the party(les) who do (does) appear and participate. Notwithstanding Contractor's right to arbitrate, Contractor does not waive any of its lien rights. Venue for arbitration hearings shall be the project county unless otherwise agreed to by the parties. NOTICE: By initialing in the space below you are agreeing to have any dispute arising out of the matters included in the "arbitration of disputes" provision decided by neutral arbitration as provided by law and you are giving up any rights you might possess to have the dispute litigated in a court or jury trial. By initialing in the space below you are giving up your judicial rights to discovery and ap- peal, unless those rights are specifically, included in the "arbitra- tion of disputes" provision. If you refuse to submit to arbitration after agreeing to this provision, you may be compelled to arbitrate under the authority of the applicable laws. Your agreement to this arbitration provision is voluntary. We have read and understand the foregoing and agree to submit disputes arising out of the matter luded in the "arbitration of disputes" provision ton ar ltrtion. I Agree to Arbitration f 0611; of Owner) (Initials of Owner) NOTICES PER COLORADO SB38 1) If the client plans to use the proceeds of a property or casualty insurance policy to pay for the roofing work, the roofing contractor cannot pay, waive, rebate, or promise to pay, waive, or rebate all or part of any deductible applicable to the claim for payment for roofing work on the covered residential property. 2) Owner may rescind this contract if the insurer denies the claim in whole or in part, as long as the person notifies Contractor within 72 hours after the claim is denied. Contractor will refund any moneys paid by the customer within 10 days after receipt of this notice of rescission. Owner may not rescind the contract when supplemental claims for additional roofing services not reasonably foreseen at the time of initial inspection for this contract, (concealed damage for example), are denied by the Insurance Company. See provision (8) in this contract for details about concealed damage. Owner may give notice of rescission in writing to Contractor at the address listed herein on page one or by email to Contractor at the email listed herein (if any). Email notice of rescission is effective on the date of the email. Standard mail notice of rescission is effective upon deposit in the United States Mail, postage pre -paid. Personal delivery of notice of rescission is effective upon delivery. 3) if Owner rescinds this contract, Contractor may retain all or a portion of any payments or deposits made by Owner to compen- sate Contractor for roofing work actually performed on the residen- tial property in a workmanlike manner consistent with standard roofing industry practices. Contractor, however, may retain only an amount required to compensate Contractor for the actual work performed. Page TWO of 2 Total Pages PERMIT NO: JOB ADDRESS: JOB DESCRIPTION City of Wheat Ridge Residential Roofing PERMIT - 201708876 201708876 ISSUED: 11/06/2017 4014 Parfet ST EXPIRES: 11/06/2018 Permit to reroof duplex, remove and replace 27 squares 4/12 pitch Certainteed Landmark IR Shingles I, by my signature, do hereby attest that the work to be performed shall comply with all accompanying approved plans and specifications. applicable building codes, and all applicable municipal codes, policies and procedures, and that 1 am the legal owner or have been authorized by the legal owner of the property and am authorized to obtain this permit and perform the work described and approved in conjunction with this permit- I further attest that I am le�ally authorized to include all entities named within this document as parties to the work to be performed and that all work to be per d is disclosed in this document and/or its' accompanying approved plans and specifications. Signature of OWNED' or CONTRACTOR (Circle one) Date I. This permit was issued based on the information provided in the permit application and accompanying plans and specifications and is subject to the compliance with those documents, and all applicable statutes, ordinances, regulations, policies and procedures. 2. This.permit shall expire 365 days after the date of issuance regardless of activity. Requests for extension must be made in writing and received prior to the date of expiration. An extension of no more than 180 days made be granted at the discretion of the Chief Building, Official and may be subject to a fee equal to one-half of the original ppermit fee. 3. If this permit expires, a new permit may be required to be obtained. Issuance of a new permit shall be subject to the standard requirements, fees andyrocedures for approval of any new permit. Re -issuance or extension of expired permits is at the sole discretion of' the Chief Building Official and is not guaranteed. 4, No work of any manner shall be performed that shall results in a change. of the natural flow of water without prior and specific approval. 5• The permit holder shall notify the Building and Inspection Services Division to accordance with established policy of all re uired inspections and shall not proceed or conceal work without written approval of such work from the Building and Inspection Services Division. 6• The issuance or granting of a permit shall not be construed to be a permit for, or an approval of, any violation of any provision of am applicable code or any ordinance or regulation of this jurisdiction. Approval of work is subject to field inspection. Signature of Chief Building Official Dhfe REQUESTS MUST BE MADE BY 11:59PM ANY BUSINESS DAY FOR INSPECTION THE FOLLOWING BUSINESS DAY. Antoinette Kulick Z, (D t -10 & 9 3 From: no-reply@ci.wheatridge.co.us Sent: Sunday, November 5, 2017 7:57 AM To: CommDev Permits Subject: Online Form Submittal: Residential Roofing Permit Application Residential Roofing Permit Application This application is exclusively for new permits for residential roofs and for licensed contractors only. This type of permit is ONLY being processed online --do not come to City Hall to submit an application in person. Permits are processed and issued in the order they are received and due to the volume of requests, time to process varies and is subject to change. YOU WILL BE CONTACTED WHEN YOUR PERMIT IS READY FOR PICK-UP AND WILL BE GIVEN A SPECIFIC DATE AND TIME WINDOW TO COMPLETE THE TRANSACTION. You will be notified if your contractor's license or insurance has expired, and you may update those documents at the time you are issued your permit. For all other requests: Homeowners wishing to obtain a roofing permit must apply for the permit in person at City Hall. Revisions to existing permits (for example, to add redecking) must be completed in person at City Hall. All other non -roofing permits must be completed in person at City Hall. The Building Division will be open from 7:30-10:30 a.m., Monday through Friday to process these types of requests. THIS APPLICATION DOES NOT CONSTITUTE A PERMIT. DO NOT BEGIN REROOFING UNTIL PERMIT HAS BEEN ISSUED. Is this application for a Yes residential roof? How many dwelling units Duplex are on the property? PROPERTY INFORMATION Property Address Property Owner Name Property Owner Phone Number (enter WITH dashes, eg 303-123-4567) Property Owner Email Address 4014 Parfet St Christopher Hildenbrand 303-907-4746 clhildenbrand@comcast.net 17 0 vve 1 &3 Do you have a signed contract to reroof this property? Applications cannot be submitted without an executed contract attached below. Attach Copy of Executed Contract Yes Hildenbrand 4014 Roof Contract.pdf CONTRACTOR INFORMATION Contractor Business Name Contractor's License Number (This is a 5 or 6 digit number for the City of Wheat Ridge) Contractor Phone Number (enter WITH dashes, eg 303-123-4567) Contractor Address (Primary address of your business) My Home Solution Colorado, LLC d/b/a Superoofs 150247 303-947-1608 191 University Blvd., #317, Denver CO 80206 Contractor Email Address Larry@superoofs.com Retype Contractor Email Larry@superoofs.com Address DESCRIPTION OF WORK TOTAL SQUARES of the entire scope of work: Project Value (contract value or cost of ALL materials and labor) Are you re -decking the roof? Is the permit for a flat roof, pitched roof, or both? (check all that apply) 27 10499 No Pitched roof (2:12 pitch or greater) 18 What is the specific pitch of the PITCHED roof? How many squares are part of the PITCHED roof? Describe the roofing materials for the PITCHED roof: Type of material for the PITCHED roof: Provide any additional detail here on the description of work. (Is this for a house or garage? Etc) 4:12 27 Certainteed Landmark IR Shingles Asphalt Entire Duplex SIGNATURE OF UNDERSTANDING AND AGREEMENT I assume full responsibility for compliance with applicable City of Wheat Ridge codes and ordinances for work under any permit issued based on this application. I understand that this application is NOT a permit. I understand I will be contacted by the City to pay for and pick up the permit for this property. I understand that work may not begin on this property until a permit has been issued and posted on the property. I certify that I have been authorized by the legal owner of the property to submit this application Yes Yes Yes Yes 19 and to perform the work described above. I attest that everything Yes stated in this application is true and correct and that falsifying information in this application is an act of fraud and may be punishable by fine, imprisonment, or both. Name of Applicant Larry Johnson Email not displaying correctly? View it in your browser. 20 City of Wheat Ridge Residential Roofing PERMIT - 201708876 PERMIT NO: 201708876 ISSUED: 11/06/2017 JOB ADDRESS: 4014 Parfet ST EXPIRES: 11/06/2018 JOB DESCRIPTION: Permit to reroof duplex, remove and replace 27 squares 4/12 pitch Certainteed Landmark IR Shingles **Revision add redecking 27sq** *** CONTACTS *** OWNER (303)463-6787 HILDENBRAND CHRISTOPHER L SUB (303)798-0111 Larry Johnson 150247 My Home Solution Co., LLC *** PARCEL INFO *** ZONE CODE: UA / Unassigned USE: UA / Unassigned SUBDIVISION CODE: 2403 / APPLEWOOD VILLAGES, PROSPECT V BLOCK/LOT#: 0 / *** FEE SUMMARY *** Total Valuation Use Tax Permit Fee Misc. Fee ** TOTAL ** *** COMMENTS *** ESTIMATED PROJECT VALUATION: FEES 0.00 314.03 283.55 25.00 622.58 14,954.00 *** CONDITIONS *** Midroof & Final Roof inspections for ROOFS 6/12 PITCH & OVER: 3rd party inspection will be required for both the midroof and final inspections. The 3rd party inspection report AND THE ORIGINAL PERMIT CARD needs to be dropped off to the Permit Desk at the City of Wheat Ridge. The report MUST BE SIGNED by the Homeowner. REGARDING ROOF VENTILATION: Roof ventilation shall comply with IBC Sec. 1203.2 or IRC Sec. R806. The installation of ridge venting requires the installation or existence of soffit venting. For calculation purposes, one hat or turtle vent equal to one-half of one square foot of opening. Effective December 1, 2014, asphalt shingle installations require an approved midroof inspection, conducted when 25-75 percent of the roof covering is installed, prior to final approval. Installation of roof sheathing (new or overlay) is required on the entire roof when spaced or board sheathing with ANY gap exceeding one half inch exists. Sheathing and mid -roofs may be called in at the same time, one hundred percent of the sheathing must be complete and 25-75 percent of the mid -roof may be complete. Asphalt shingles are required to be fastened to the roof deck with a minimum of 6 nails per shingle. Ice and water shield is required. Eave and rake metal is required. A ladder extending 3 feet above the roof eave and secured in place is required to be provided for all roof inspections. Roof ventilation is required to comply with applicable codes and/or manufacturer installation instructions, whichever is more stringent. In order to pass a final inspection of elastomeric or similar type roof coverings, a letter of inspection and approval from the manufacturer technical representative stating that "the application of the roof at (project address) has been applied in accordance with the installation instruction for (roof material brand name) roof covering" is required to be on site at the time of final inspection. City of Wheat Ridge Residential Roofing PERMIT - 201708876 PERMIT NO: 201708876 ISSUED: 11/06/2017 JOB ADDRESS: 4014 Parfet ST EXPIRES: 11/06/2018 JOB DESCRIPTION: Permit to reroof duplex, remove and replace 27 squares 4/12 pitch Certainteed Landmark IR Shingles **Revision add redecking 27sq** I, by my signature, do hereby attest that the work to be performed shall comply with all accompanying approved plans and specifications, applicabble building codes, and all applicable municipal codes, policies and procedures, and that I am the legal owner or have been authorized by the legal owner of the property and am authorized to obtain this permit and perform the work described and approved in conjunction with this permit. I further attest that I am legally authorized to include al[ entities named within this document as partes to the work toe performed and that,all work to be performed is disclosed in this document and/or its' accompanying approved plans and specifications. Signature of OWNER or CONTRACTOR (Circle one) Date 1. This permit was issued based on the information provided in the permit application and accompanying plans and specifications and is subject to the compliance with those documents, and all applicable statutes, ordinances, regulations, policies and procedures. 2. This permit shall expire 365 days after the date of issuance regardless of activity. Requests for extension must be made in writing and received prior to the date of expiration. An extension of no more than 180 days made be granted at the discretion of the Chief Building Official and may be subject to a fee equal to one-half of the originalpermit fee. 3. If this permit expires, a new permit may be required to be obtained. issuance of a new permit shall be subject to the standard requirements, fees androcedures for approval of any new permit. Re -issuance or extension of expired permits is at the sole discretion of the Chief Building Official and is not guaranteed. 4. No work of an manner shall be performed that shall results in a change of the natural flow of water without prior and specific approval. 5. The permit holder shall notify the Building and Inspection Services Division in accordance with established policy of all required inspections and shall not proceed or conceal work without written approval of such work from the Building and Inspection Services D1vlSion. 6. The issuance or granting of a permit shall not be construed to be a permit for, or an approval of, any violation of any provision of any applicable code,pr any ordinance or regulation of this jurisdiction. Approval of work is subject to field inspection. 447�y 11 Signature of Chief Building Official Date REQUESTS MUST BE MADE BY 11:59PM ANY BUSINESS DAY FOR INSPECTION THE FOLLOWING BUSINESS DAY. City of Wheat Ridge Residential Roofing PERMIT - 201708876 PERMIT NO: 201708876 ISSUED: 11/06/2017 JOB ADDRESS: 4014 Parfet ST EXPIRES: 11/06/2018 JOB DESCRIPTION: Permit to reroof duplex, remove and replace 27 squares 4/12 pitch Certainteed Landmark IR Shingles **Revision add redecking 27sq** *** CONTACTS *** OWNER (303)463-6787 HILDENBRAND CHRISTOPHER L SUB (303)798-0111 Larry Johnson 150247 My Home Solution Co., LLC *** PARCEL INFO *** ZONE CODE: UA / Unassigned USE: UA / Unassigned SUBDIVISION CODE: 2403 / APPLEWOOD VILLAGES, PROSPECT V BLOCK/LOT#: 0 / *** FEE SUMMARY *** Total Valuation Use Tax Permit Fee Misc. Fee ** TOTAL ** *** COMMENTS *** ESTIMATED PROJECT VALUATION: FEES 0.00 314.03 283.55 25.00 622.58 14,954.00 *** CONDITIONS *** Midroof & Final Roof inspections for ROOFS 6/12 PITCH & OVER: 3rd party inspection will be required for both the midroof and final inspections. The 3rd party inspection report AND THE ORIGINAL PERMIT CARD needs to be dropped off to the Permit Desk at the City of Wheat Ridge. The report MUST BE SIGNED by the Homeowner. REGARDING ROOF VENTILATION: Roof ventilation shall comply with IBC Sec. 1203.2 or IRC Sec. R806. The installation of ridge venting requires the installation or existence of soffit venting. For calculation purposes, one hat or turtle vent equal to one-half of one square foot of opening. Effective December 1, 2014, asphalt shingle installations require an approved midroof inspection, conducted when 25-75 percent of the roof covering is installed, prior to final approval. Installation of roof sheathing (new or overlay) is required on the entire roof when spaced or board sheathing with ANY gap exceeding one half inch exists. Sheathing and mid -roofs may be called in at the same time, one hundred percent of the sheathing must be complete and 25-75 percent of the mid -roof may be complete. Asphalt shingles are required to be fastened to the roof deck with a minimum of 6 nails per shingle. Ice and water shield is required. Eave and rake metal is required. A ladder extending 3 feet above the roof eave and secured in place is required to be provided for all roof inspections. Roof ventilation is required to comply with applicable codes and/or manufacturer installation instructions, whichever is more stringent. In order to pass a final inspection of elastomeric or similar type roof coverings, a letter of inspection and approval from the manufacturer technical representative stating that "the application of the roof at (project address) has been applied in accordance with the installation instruction for (roof material brand name) roof covering" is required to be on site at the time of final inspection. City of Wheat Ridge Residential Roofing PERMIT - 201708876 PERMIT NO: 201708876 ISSUED: 11/06/2017 JOB ADDRESS: 4014 Parfet ST EXPIRES: 11/06/2018 JOB DESCRIPTION: Permit to reroof duplex, remove and replace 27 squares 4/12 pitch Certainteed Landmark IR Shingles **Revision add redecking 27sq** I, by my signature, do hereby attest that the work to be performed shall comply with all accompanying approved plans and specifications, applicabble building codes, and all applicable municipal codes, policies and procedures, and that I am the legal owner or have been authorized by the legal owner of the property and am authorized to obtain this permit and perform the work described and approved in conjunction with this permit. I further attest that I am legally authorized to include al[ entities named within this document as partes to the work toe performed and that,all work to be performed is disclosed in this document and/or its' accompanying approved plans and specifications. Signature of OWNER or CONTRACTOR (Circle one) Date 1. This permit was issued based on the information provided in the permit application and accompanying plans and specifications and is subject to the compliance with those documents, and all applicable statutes, ordinances, regulations, policies and procedures. 2. This permit shall expire 365 days after the date of issuance regardless of activity. Requests for extension must be made in writing and received prior to the date of expiration. An extension of no more than 180 days made be granted at the discretion of the Chief Building Official and may be subject to a fee equal to one-half of the originalpermit fee. 3. If this permit expires, a new permit may be required to be obtained. issuance of a new permit shall be subject to the standard requirements, fees androcedures for approval of any new permit. Re -issuance or extension of expired permits is at the sole discretion of the Chief Building Official and is not guaranteed. 4. No work of an manner shall be performed that shall results in a change of the natural flow of water without prior and specific approval. 5. The permit holder shall notify the Building and Inspection Services Division in accordance with established policy of all required inspections and shall not proceed or conceal work without written approval of such work from the Building and Inspection Services D1vlSion. 6. The issuance or granting of a permit shall not be construed to be a permit for, or an approval of, any violation of any provision of any applicable code,pr any ordinance or regulation of this jurisdiction. Approval of work is subject to field inspection. 447�y 11 Signature of Chief Building Official Date REQUESTS MUST BE MADE BY 11:59PM ANY BUSINESS DAY FOR INSPECTION THE FOLLOWING BUSINESS DAY. i CITY OF WHEAT RIDGE Building Inspection Division (303) 234-5933 Inspection line (303) 235-2855 Office • (303) 237-8929 Fax INSPECTION NOTICE Inspection Type: I:-- ( i , r- Job Address: n 1.4- 45,,r Permit Number: 2A 1 "1 p hq.�n UJ i sX ❑ No one available for inspection: Time '�'3AM P Re -Inspection required: Yes No When corrections have been made, call f r -inspection 303-234- 33 Date: Z Inspector: c Y DO NOT REMOVE THIS NOTICE i CITY OF WHEAT RIDGE Building Inspection Division (303) 234-5933 Inspection line (303) 235-2855 Office • (303) 237-8929 Fax INSPECTION NOTICE Inspection Type: Mto Job Address: Ac)('4 Permit Number: "'42DII D ❑ No one available for inspection: Time AM/`M Re -Inspection required: Yes No When corrections have been made, call foryf-inspection at 303 -234- Date: - 03 -234 - Date: iIt 2 Inspector: �,Yn► `�) C DO NOT REMOVE THIS NOTICE City of Wheat Ridge Residential Roofing PERMIT - 201708876 PERMIT NO: 201708876 ISSUED: 11/06/2017 JOB ADDRESS: 4014 Parfet ST EXPIRES: 11/06/2018 JOB DESCRIPTION: Permit to reroof duplex, remove and replace 27 squares 4/12 pitch Certainteed Landmark IR Shingles **Revision add redecking 27sq** *** CONTACTS *** OWNER (303)463-6787 HILDENBRAND CHRISTOPHER L SUB (303)798-0111 Larry Johnson 150247 My Home Solution Co., LLC *** PARCEL INFO *** ZONE CODE: UA / Unassigned USE: UA / Unassigned SUBDIVISION CODE: 2403 / APPLEWOOD VILLAGES, PROSPECT V BLOCK/LOT#: 0 / *** FEE SUMMARY *** ESTIMATED PROJECT VALUATION: 14,954.00 FEES Total Valuation 0.00 Use Tax 314.03 Permit Fee 283.55 ** TOTAL ** 597.58 *** COMMENTS *** *** CONDITIONS *** Midroof & Final Roof inspections for ROOFS 6/12 PITCH & OVER: 3rd party inspection will be required for both the midroof and final inspections. The 3rd party inspection report AND THE ORIGINAL PERMIT CARD needs to be dropped off to the Permit Desk at the City of Wheat Ridge. The report MUST BE SIGNED by the Homeowner. REGARDING ROOF VENTILATION: Roof ventilation shall comply with IBC Sec. 1203.2 or IRC Sec. R806. The installation of ridge venting requires the installation or existence of soffit venting. For calculation purposes, one hat or turtle vent equal to one-half of one square foot of opening. Effective December 1, 2014, asphalt shingle installations require an approved midroof inspection, conducted when 25-75 percent of the roof covering is installed, prior to final approval. Installation of roof sheathing (new or overlay) is required on the entire roof when spaced or board sheathing with ANY gap exceeding one half inch exists. Sheathing and mid -roofs may be called in at the same time, one hundred percent of the sheathing must be complete and 25-75 percent of the mid -roof may be complete. Asphalt shingles are required to be fastened to the roof deck with a minimum of 6 nails per shingle. Ice and water shield is required. Eave and rake metal is required. A ladder extending 3 feet above the roof eave and secured in place is required to be provided for all roof inspections. Roof ventilation is required to comply with applicable codes and/or manufacturer installation instructions, whichever is more stringent. In order to pass a final inspection of elastomeric or similar type roof coverings, a letter of inspection and approval from the manufacturer technical representative stating that "the application of the roof at (project address) has been applied in accordance with the installation instruction for (roof material brand name) roof covering" is required to be on site at the time of final inspection. City of Wheat Ridge Residential Roofing PERMIT - 201708876 PERMIT NO: 201708876 ISSUED: 11/06/2017 JOB ADDRESS: 4014 Parfet ST EXPIRES: 11/06/2018 JOB DESCRIPTION: Permit to reroof duplex, remove and replace 27 squares 4/12 pitch Certainteed Landmark IR Shingles **Revision add redecking 27sq** I, by my signature, do hereby attest that the work to be performed shall comply with all accompanying approved plans and specifications, applicable building codes, and all applicable municipal codes, policies and procedures, and that I am the legal owner or have been authorized by the legal owner of the property and am authorized to obtain this permit and perform the work described and approved in conjunction with this permit. I further attest that I am legally authorized to include all entities named within this document as parties to the work to be performed and that all work t=bee rmed is disclosed in this document and/or its' accompanying approved plans and specifications. Cyk_(2-� kC------- I I (22 Signature of OWNER or CONTRACTOR (Circle one) Date 1. This permit was issued based on the information provided in the permit application and accompanyingplans and specifications and is subject to the compliance with those documents, and all applicable statutes, ordinances, regulations, policies and procedures. 2. This. permit shall expire 365 days after the date of issuance regardless of activity. Requests for extension must be made in writing and received prior to the date of expiration. An extension of no more than 180 days made be granted at the discretion of the Chief Building Official and may be subject to a fee equal to one-half of the originalpermit fee. 3. If this permit expires, a new permit may be required to be obtained. Issuance of a new permit shall be subject to the standard requirements, fees and procedures for approval of any new permit. Re -issuance or extension of expired permits is at the sole discretion of the Chief Building Official and is not guaranteed. 4_ No work of an manner shall be performed that shall results in a change of the natural flow of water without prior and specific approval. 5. The permit holder shall notify the Building and Inspection Services Division in accordance with established policy of all required inspections and shall not proceed or conceal work without written approval of such work from the Building and Inspection Services Division. 6. The issuance or granting of a permit shall not be construed to be a permit for, or an approval of, an violation of any provision of any applicable code or any ordinance or regulation of this jurisdiction. Approval of work is subject to field inspection. ._, Signature of Chief Building Official Date REQUESTS MUST BE MADE BY 11:59PM ANY BUSINESS DAY FOR INSPECTION THE FOLLOWING BUSINESS DAY. City of Air W heat Midge COMMUNITY DEVELOPMENT Building & Inspection Services Division 7500 W. 29th Ave., Wheat Ridge, CO 80033 Office: 303-235-2855 * Fax: 303-237-8929 Inspection Line: 303-234-5933 Email: permits(o)_ci.wheatridge.co.us I FOR OFFICE USE ONLY Date:17 Add to Permit # C10 gg-7 Building Permit Revision/Amendment Application *** Please complete all highlighted areas on both sides of this form. Incomplete applications may not be processed. *** Property Address: � 6 t `i d A, C i. �-c- Property Owner (please print): e c,-aOt Phone: 1 o -7 Z G - Z-7- 1 Property Owner Email: c- L L, I ste-s Mailing Address: (if different than property address) Address: , State, Zip: Submitting Company: "!I Su �vr , C-0 ILC e(( �0 t e, �'-� (�ti•�C'Cs Contact Person: C-✓ +�-�J V l�-S & " Phone: 3--j 9 -5-d l t Contractor: � OL'— " Contractors City License #: _ O 2-11 --7 Phone: Contractor E-mail Address: Please Note: Additional valuation must include all general and subcontracted work to be performed related to the revisions and/or amendments declared in the description of work and which were not included in the original permit valuation. If revisions or amendments increase the original valuation, additional fees will be due at the time of approval. Depending on the scope of work, additional plan review fees may be due upon approval ($60.00 an hour - 2 hour minimum). Description of revised/amended work: Sq. Ft./LF Btu's Amps Squares Gallons Other Additional Project Value: (Must include all general and subcontracted work to be performed related to revisions/amendments described above) $ OWNER/CONTRACTOR SIGNATURE OF UNDERSTANDING AND AGREEMENT 1 hereby certify that the setback distances proposed by this permit application are accurate and do not violate applicable ordinances, rules or regulations of the City of Wheat Ridge or covenants, easements or restrictions of record; that all measurements shown and allegations made are accurate; that I have read and agree to abide by all conditions printed on this application and that I assume full responsibility for compliance with applicable City of Wheat Ridge codes and ordinances for work under any permit issued based on this application; that I am the legal owner or have been authorized by the legal owner of the property to perform the described work and am also authorized by the legal owner of any entity included on this application to list that entity on this application. CIRCLE ONE: (OWNER �ACTOR) or (AUTHORIZED REPRESENTATIVE"f (OWNER) (CONTRACTOR) PRINT NAME: ZONING COMMMENTS: Reviewer: BUILDING DEPARTMENT COMMENTS. Reviewer - PUBLIC WORKS COMMENTS. Reviewer SIGNATURE: PROOF OF SUBMISSION FORMS Fire Department ❑ Received ❑ Not Required Water District ❑ Received ❑ Not Required Sanitation District ❑ Received ❑ Not Required DEPARTMENT USE ONLY DATE: Z OCCUPANCY CLASSIFICATION: Building Division Valuation: $ City of Wheat Ridge x �✓� Residential Roofing PERMIT - 201708876 PERMIT NO: 201708876 ISSUED: 11/06/2017 JOB ADDRESS: 4014 Parfet ST EXPIRES: 11/06/2018 JOB DESCRIPTION: Permit to reroof duplex, remove and replace 27 squares 4/12 pitch Certainteed Landmark IR Shingles *** CONTACTS *** OWNER (303)463-6787 HILDENBRAND CHRISTOPHER L SUB (303)798-0111 Larry Johnson 150247 My Home Solution Co., LLC *** PARCEL INFO *** ZONE CODE: UA / Unassigned USE: UA / Unassigned SUBDIVISION CODE: 2403 / APPLEWOOD VILLAGES, PROSPECT V BLOCK/LOT#: 0 / *** FEE SUMMARY *** ESTIMATED PROJECT VALUATION: 10,499.00 FEES Total Valuation 0.00 Use Tax 220.48 Permit Fee 220.15 ** TOTAL ** 440.63 *** COMMENTS *** *** CONDITIONS *** Midroof & Final Roof inspections for ROOFS 6/12 PITCH & OVER: 3rd party inspection will be required for both the midroof and final inspections. The 3rd party inspection report AND THE ORIGINAL PERMIT CARD needs to be dropped off to the Permit Desk at the City of Wheat Ridge. The report MUST BE SIGNED by the Homeowner. REGARDING ROOF VENTILATION: Roof ventilation shall comply with IBC Sec. 1203.2 or IRC Sec. R806. The installation of ridge venting requires the installation or existence of soffit venting. For calculation purposes, one hat or turtle vent equal to one-half of one square foot of opening. Effective December 1, 2014, asphalt shingle installations require an approved midroof inspection, conducted when 25-75 percent of the roof covering is installed, prior to final approval. Installation of roof sheathing (new or overlay) is required on the entire roof when spaced or board sheathing with ANY gap exceeding one half inch exists. Sheathing arid mid -roofs may be called in at the same time, one hundred percent of the sheathing must be complete and 25-75 percent of the mid -roof may be complete. Asphalt shingles are required to be fastened to the roof deck with a minimum of 6 nails per shingle. Ice and water shield is required. Eave and rake metal is required. A ladder extending 3 feet above the roof eave and secured in place is required to be provided for all roof inspections. Roof ventilation is required to comply with applicable codes and/or manufacturer installation instructions, whichever is more stringent. In order to pass a final inspection of elastomeric or similar type roof coverings, a letter of inspection and approval from the manufacturer technical representative stating that "the application of the roof at (project address) has been applied in accordance with the installation instruction for (roof material brand name) roof covering" is required to be on site at the time of final inspection. PERMIT NO: JOB ADDRESS: JOB DESCRIPTION City of Wheat Ridge Residential Roofing PERMIT - 201708876 201708876 ISSUED: 11/06/2017 4014 Parfet ST EXPIRES: 11/06/2018 Permit to reroof duplex, remove and replace 27 squares 4/12 pitch Certainteed Landmark IR Shingles I, by my signature, do hereby attest that the work to be performed shall comply with all accompanying approved plans and specifications. applicable building codes, and all applicable municipal codes, policies and procedures, and that 1 am the legal owner or have been authorized by the legal owner of the property and am authorized to obtain this permit and perform the work described and approved in conjunction with this permit- I further attest that I am le�ally authorized to include all entities named within this document as parties to the work to be performed and that all work to be per d is disclosed in this document and/or its' accompanying approved plans and specifications. Signature of OWNED' or CONTRACTOR (Circle one) Date I. This permit was issued based on the information provided in the permit application and accompanying plans and specifications and is subject to the compliance with those documents, and all applicable statutes, ordinances, regulations, policies and procedures. 2. This.permit shall expire 365 days after the date of issuance regardless of activity. Requests for extension must be made in writing and received prior to the date of expiration. An extension of no more than 180 days made be granted at the discretion of the Chief Building, Official and may be subject to a fee equal to one-half of the original ppermit fee. 3. If this permit expires, a new permit may be required to be obtained. Issuance of a new permit shall be subject to the standard requirements, fees andyrocedures for approval of any new permit. Re -issuance or extension of expired permits is at the sole discretion of' the Chief Building Official and is not guaranteed. 4, No work of any manner shall be performed that shall results in a change. of the natural flow of water without prior and specific approval. 5• The permit holder shall notify the Building and Inspection Services Division to accordance with established policy of all re uired inspections and shall not proceed or conceal work without written approval of such work from the Building and Inspection Services Division. 6• The issuance or granting of a permit shall not be construed to be a permit for, or an approval of, any violation of any provision of am applicable code or any ordinance or regulation of this jurisdiction. Approval of work is subject to field inspection. Signature of Chief Building Official Dhfe REQUESTS MUST BE MADE BY 11:59PM ANY BUSINESS DAY FOR INSPECTION THE FOLLOWING BUSINESS DAY. Antoinette Kulick Z, (D t -10 & 9 3 From: no-reply@ci.wheatridge.co.us Sent: Sunday, November 5, 2017 7:57 AM To: CommDev Permits Subject: Online Form Submittal: Residential Roofing Permit Application Residential Roofing Permit Application This application is exclusively for new permits for residential roofs and for licensed contractors only. This type of permit is ONLY being processed online --do not come to City Hall to submit an application in person. Permits are processed and issued in the order they are received and due to the volume of requests, time to process varies and is subject to change. YOU WILL BE CONTACTED WHEN YOUR PERMIT IS READY FOR PICK-UP AND WILL BE GIVEN A SPECIFIC DATE AND TIME WINDOW TO COMPLETE THE TRANSACTION. You will be notified if your contractor's license or insurance has expired, and you may update those documents at the time you are issued your permit. For all other requests: Homeowners wishing to obtain a roofing permit must apply for the permit in person at City Hall. Revisions to existing permits (for example, to add redecking) must be completed in person at City Hall. All other non -roofing permits must be completed in person at City Hall. The Building Division will be open from 7:30-10:30 a.m., Monday through Friday to process these types of requests. THIS APPLICATION DOES NOT CONSTITUTE A PERMIT. DO NOT BEGIN REROOFING UNTIL PERMIT HAS BEEN ISSUED. Is this application for a Yes residential roof? How many dwelling units Duplex are on the property? PROPERTY INFORMATION Property Address Property Owner Name Property Owner Phone Number (enter WITH dashes, eg 303-123-4567) Property Owner Email Address 4014 Parfet St Christopher Hildenbrand 303-907-4746 clhildenbrand@comcast.net 17 0 vve 1 &3 Do you have a signed contract to reroof this property? Applications cannot be submitted without an executed contract attached below. Attach Copy of Executed Contract Yes Hildenbrand 4014 Roof Contract.pdf CONTRACTOR INFORMATION Contractor Business Name Contractor's License Number (This is a 5 or 6 digit number for the City of Wheat Ridge) Contractor Phone Number (enter WITH dashes, eg 303-123-4567) Contractor Address (Primary address of your business) My Home Solution Colorado, LLC d/b/a Superoofs 150247 303-947-1608 191 University Blvd., #317, Denver CO 80206 Contractor Email Address Larry@superoofs.com Retype Contractor Email Larry@superoofs.com Address DESCRIPTION OF WORK TOTAL SQUARES of the entire scope of work: Project Value (contract value or cost of ALL materials and labor) Are you re -decking the roof? Is the permit for a flat roof, pitched roof, or both? (check all that apply) 27 10499 No Pitched roof (2:12 pitch or greater) 18 What is the specific pitch of the PITCHED roof? How many squares are part of the PITCHED roof? Describe the roofing materials for the PITCHED roof: Type of material for the PITCHED roof: Provide any additional detail here on the description of work. (Is this for a house or garage? Etc) 4:12 27 Certainteed Landmark IR Shingles Asphalt Entire Duplex SIGNATURE OF UNDERSTANDING AND AGREEMENT I assume full responsibility for compliance with applicable City of Wheat Ridge codes and ordinances for work under any permit issued based on this application. I understand that this application is NOT a permit. I understand I will be contacted by the City to pay for and pick up the permit for this property. I understand that work may not begin on this property until a permit has been issued and posted on the property. I certify that I have been authorized by the legal owner of the property to submit this application Yes Yes Yes Yes 19 and to perform the work described above. I attest that everything Yes stated in this application is true and correct and that falsifying information in this application is an act of fraud and may be punishable by fine, imprisonment, or both. Name of Applicant Larry Johnson Email not displaying correctly? View it in your browser. 20 RESIDENTIAL ROOFING CONTRACT NO. MHC 17.108 191 University Blvd., #317 Denver, Colorado 80206 OFFICE: 303.798.0111 FAX: 303.798.5211 Owner's Name: uwner's Aaaress: Christopher Hildenbrand 9001 W. 38th Ave. Owner's City, State, Zip: Owner's Phone: Owner's Alt, Phone: Wheat Ridee. CO. 80033 303-907-4746 www.SUPEROOFS.com Cell Project Name & Address: Email: 4014 & 4034 Parfet Street. Wheat Ridge, CO. 80033 1 clhildenbrand@comcast.net I/WE, the Owner(s) of the premises described above authorize My Home Solution Colorado, LLC ciba Superoofs, hereinafter referred to as "Contractor , to furnish all materials and labor necessary to roof and/or improve these premises according to the following terms, specifications and provisions: PROPERTY OWNER IS INTENDING TO MAKE PAYMENT FROM THE PROCEEDS OF A PROPERTY AND CASUALTY INSURANCE POLICY. INITIALS a. scope of Roofing services and Materials to be Provided: Remove 27.60 squares of existing roofing material to clean deck on main dwell- ing; Replace with Certainteed Winterguard Ice & Water Shield on all eaves, valleys & penetrations; Certainteed Diamond Deck syn- thetic underlayment; 2" x4" drip edge on all eaves and rakes; CT Landmark shingles in (,,+c5Aw`,. ); Shadow Ridge cap; Replace all storm caps and collars, pipe jacks and chimney flashing's. $10,499.29 t� __- Owner may upgrade toLandmark lRClass-4shingles for $607.00 APPROVED \Q DECLINE Al. R&R,Prime& Paint 150 LF Gutter/ Downspout- aluminum -up to 5" $1,085.34: A2. Certainteed 4-Starextended Material warranty and 3-yearWorkmanship Warranty. No Charge SEE CONTINUATION PAGE *ACV & Deductible Due upon completion of roof. Depreciation Due When received from insurer. b. Description of any areas that will NOT be worked on: None This list of specifications may be continued on subsequent pages (see page number below). c. Approximate Costs of the Services for Damage Known at This Time: Contractor will perform the above, (subject to any additions and/or deductions pursuant to authorized change orders), for the Approximate Sum of $13,354.48+Permit Down Payment (if any) $ 6,048.49* INSURANCE: THIS AGREEMENT IS NULL AND VOID AND DOES NOT OBLIGATE ANY PARTY TO IT SHOULD THE INSURANCE COMPANY REFUSE COVERAGE UNDER THIS CLAIM OR SHOULD THE COVERAGE OFFERED BE INSUFFICIENT FOR CONTRACTOR TO PROPERLY DO THE WORK. THE ONLY COST TO THE PROPERTY OWNER IS THEIR DEDUCTIBLE, PLUS ANY UPGRADES CHOSEN OR ANY NON COVERED ITEMS THAT MUST BE REPLACED TO COMPLETE THE REPAIRS. THE CONTRACT BALANCE (ACTUAL CASH VALUE OF THE WORK) IS PAID BY YOUR INSURANCE COMPANY PER FINAL LOSS INVOICE. ALL PROCEEDS FROM THE INSURANCE COMPANY INCLUDING, BUT NOT LIMITED TO, PROCEEDS FOR SUPPLEMENTAL CLAIMS MADE BY CONTRACTOR ON BEHALF OF OWNER, PROCEEDS FOR PROFIT & OVERHEAD, AND PROCEEDS FOR RECOVERABLE DEPRECIATION, ARE GIVEN IN PAYMENT FOR THE WORK OF CONTRACTOR AND OWNER AGREES TO TIMELY, (WITHIN 24 HOURS OF RECEIPT BY OWNER), REMITALL SUCH PROCEEDS TO CONTRACTOR. PER COLORADO S1338, CONTRACTOR SHALL HOLD IN TRUST ANY PAYMENT FROM THE PROPERTY OWNER UNTIL CONTRACTOR HAS DELIVERED ROOFING MATERIALS AT THE RESIDENTIAL PROPERTY SITE OR HAS PERFORMED A MAJORITY OF THE ROOFING WORK ON THE RESIDENTIAL PROPERTY. d. Approximate Dates of Service: Substantial commencement of work shall mean either the physical delivery of materials onto the premises or the performance of any labor and shall be subject to any permissible delays as per provision (5) on the reverse side. Approximate Start Date: Oct 04, 2017 Approximate Completion Date: Oct 10, 2017 e. Acceptance: This contract is approved and accepted. I (we) understand there are no oral agreements or understandings between the parties of this agreement. The written terms, provisions, plans (if any) and specifications in this contract is the entire agreement between the parties. Changes in this agreement shall be done by written change order only and with the express approval of both parties. Changes may incur additional charges. Additional Provisions Of This Contract Are On The Reverse Side And May Be Continued On Subsequent Pages (see page number below). 1. app(oved an accepted (owner) date approved and accepted4owner) approved (contractor) date CANCELLATION POLICY: Your right to cancel this contract is limited to the following: You, the Buyer, may cancel this transaction at any time prior to midnight of the third business day after the date of this transaction. See the attached Notice of Cancellation form for an explanation of this right. Per Colorado SB38, you may also cancel this contract within 72 hours after being notified by your insurer that any part of or all: of your claim is denied. See the notice on the reverse side for an explanation of this right. NOTE: This contract may be withdrawn or renegotiated after NIA days from N/A if not approved and signed by BOTH parties. Form RC31-C Copyright © 1996-2016 ACT Contractors Forms (800) 820-5656 www.caltorm.com rage ewe or z iorai rages ADDITIONAL PROVISIONS- Unless otherwise specified herein, the following additional provisions are expressly incorporated into this contract: I. Contract, Plans, Specifications, Permits and Fees. The work described in this contract shall be done according to the plans and the plan specifica- tions (if any) except in the case of conflict when the provisions of this contract shall have control over both the plans and the plan specifications. All required building permits will be paid for by owner and obtained by Contractor. All other charges, taxes, assessments, fees etc., of any kind whatsoever, required by any government body, telephone or utility compa- ny or the like shall be paid for by Owner. 2.Installation. Contractor has the right to subcontract any part of, or all of, the work herein 3.Change Orders. Should Owner, construction lender, or any government body or inspector require any modification to the work covered under this contract, any cost incurred by Contractor shall be added to the contract price as extra work and Owner agrees to pay Contractor his normal selling price for such extra work. All extra work as well as any other modifications to the original contract shall be specified and approved by both parties in a written change order. All change orders as well as all insurance supple- ments, shall become a part of this contract and shall be incorporated herein. 4.Owner's Responsibility: Insurance etc. Owner is responsible for the fol- lowing: (1) to see that all necessary water, electrical power, access to premises, and toilet facilities are provided on the premises. (2) to provide a storage area on the premises for equipment and materials. (3) to relocate and protect any item that prevents Contractor from having free access to the work areas such as but not limited to TV or radio antennas, vehicles, tools or garden equipment. In the event that Owner fails to relocate such items, Contractor may relocate these items as required but in no way is Contractor responsible for damage to these items during their relocation and during the performance of the work. (4) to obtain permission from the owner(s) of adjacent property(ies) that Contractor must use to gain access to the work areas. Owner agrees to be responsible and to hold Contractor harmless and accept any risks resulting from the use of adjacent property(ies) by Contractor. (5) to correct any existing defects which are recognized during the course of the work. Contractor shall have no liability for correcting any existing defects such as, but not limited to, dry rot, structural defects, or code violations. (6) to maintain property insurance with Fire, Course of Construction, all Physical Loss with Vandalism and Malicious Mischief clauses attached, in a sum at least equal to the contract price, prior to and during performance of this contract. If the project is destroyed or damaged by an accident, disaster or calamity, or by theft or vandalism, any work or materials supplied by Contractor in reroofing or restoring the project shall be paid for by Owner as extra work. (7) to timely fill out and submit any documentation required by the insurance company. S.Delay. Contractor shall not be held responsible for any damage occa- sioned by delays resulting from: work done by Owner's subcontractors, extra work, acts of owner or owner's agent including failure of owner to make timelyrogress payments or payments for extra work, shortages of material andyor labor, bad weather, fire, strike, war, governmental regula- tions, or any other contingencies unforeseen by Contractor or beyond Contractor's reasonable control. 6.Surplus Materials and Salvage. Any surplus materials left over after this contract has been completed are the property of Contractor and will be removed by same. No credit is due Owner on returns for any surplus materials because this contract is based upon a complete job. All salvage resulting from work under this contract is the property of Contractor. 7.Cleanup &Advertising. Upon completion, and after removing all debris and surplus materials, wherever possible, Contractor will leave premises in a neat, broom clean condition. Any debris consisting of dust, dirt, asphalt, or small bits of materials that settle into attics, garage areas, or any other area being worked over with open beam ceilings or no attic, is unavoidable and Contractor shall not be responsible for this cleanup. Contractor recom- mends that Owner lay out drop cloths to protect such areas wherever owner discovers debris infiltration. Owner hereby grants to Contractor the right to display signs and advertise at the job site for the period of time starting at the date of signing of this contract and continuing uninterrupted until fourteen (14) days past the date the job is completed and payment in full has been made. Ownerrants Contractor the right to publish the project street address on a ' references" list and to take "before" and after' photos which may be given to prospective customers. 8.Concealed Damage & Dry Rot. Contractor will inform Owner of any dry rot or other sub -roof deterioration which is concealed and is discovered during the course of the work. Contractor is not responsible to repair any such discovered deterioration and any work done by Contractor to remedy such discovered deterioration will only be done as extra work in a written change order. 9.Termites, Pests & Hazardous Substances. Owner understands that Con- tractor is not qualified or licensed as an inspector or abatement contractor for Hazardous Materials (as defined by the government), or for Pests (in- cluding Termites). Should any such hazardous substances or Pest be sus- pected to be present on the premises, it is the Owners' responsibili to arrange and pay for inspection and abatement. Contractor cannot cert or warrant your building as being free of hazardous substances or pests. 10. Collection & Legal Fees. Owner agrees to pay all collection fees and charges that result should Owner default in payment of this contract. Overdue accounts are subject to interest charged at 18% per annum or at the highest rate allowed by law. In the event litigation or arbitration arises out of this contract, prevailing party(ies) are entitled to all legal, arbitration, and attorney fees. The court or arbitrator shall not be bound to award fees based on any set, fee schedule but shall if it so chooses, award the true amount of all costs, expenses and attorney fees paid or incurred. 11. Arbitration of Disputes. Any controversy or claim arising out of or relating to this proposal/contract, or the breach thereof, shall be settled by arbitration in accordance with the applicable Con- struction Industry Arbitration Rules of the American Arbitration Association which are in effect at the time the demand for arbitra- tion is filed. A judgment upon the award rendered by the arbitrator(s) may be entered in any court having jurisdiction there- of. Any arbitration award shall be subject to correction and/or vacation for the reasons stated in the law. The arbitrator shall award reasonable attorneys fees and expenses to the prevailing party. After being given due notice, should any party fail to appear at or participate in the arbitration proceedings, the arbitrator shall make an award based upon the evidence presented by the party(les) who do (does) appear and participate. Notwithstanding Contractor's right to arbitrate, Contractor does not waive any of its lien rights. Venue for arbitration hearings shall be the project county unless otherwise agreed to by the parties. NOTICE: By initialing in the space below you are agreeing to have any dispute arising out of the matters included in the "arbitration of disputes" provision decided by neutral arbitration as provided by law and you are giving up any rights you might possess to have the dispute litigated in a court or jury trial. By initialing in the space below you are giving up your judicial rights to discovery and ap- peal, unless those rights are specifically, included in the "arbitra- tion of disputes" provision. If you refuse to submit to arbitration after agreeing to this provision, you may be compelled to arbitrate under the authority of the applicable laws. Your agreement to this arbitration provision is voluntary. We have read and understand the foregoing and agree to submit disputes arising out of the matter luded in the "arbitration of disputes" provision ton ar ltrtion. I Agree to Arbitration f 0611; of Owner) (Initials of Owner) NOTICES PER COLORADO SB38 1) If the client plans to use the proceeds of a property or casualty insurance policy to pay for the roofing work, the roofing contractor cannot pay, waive, rebate, or promise to pay, waive, or rebate all or part of any deductible applicable to the claim for payment for roofing work on the covered residential property. 2) Owner may rescind this contract if the insurer denies the claim in whole or in part, as long as the person notifies Contractor within 72 hours after the claim is denied. Contractor will refund any moneys paid by the customer within 10 days after receipt of this notice of rescission. Owner may not rescind the contract when supplemental claims for additional roofing services not reasonably foreseen at the time of initial inspection for this contract, (concealed damage for example), are denied by the Insurance Company. See provision (8) in this contract for details about concealed damage. Owner may give notice of rescission in writing to Contractor at the address listed herein on page one or by email to Contractor at the email listed herein (if any). Email notice of rescission is effective on the date of the email. Standard mail notice of rescission is effective upon deposit in the United States Mail, postage pre -paid. Personal delivery of notice of rescission is effective upon delivery. 3) if Owner rescinds this contract, Contractor may retain all or a portion of any payments or deposits made by Owner to compen- sate Contractor for roofing work actually performed on the residen- tial property in a workmanlike manner consistent with standard roofing industry practices. Contractor, however, may retain only an amount required to compensate Contractor for the actual work performed. Page TWO of 2 Total Pages ♦ i CITY OF WHEAT RIDGE Bung Inspection Division (303) 234-5933 Inspection line (303) 235-2855 Office • (303) 237-8929 Fax INSPECTION NOTICE Inspection Type: P/J,/ `&g Job Address: /-abjW - 4,L2 g 1~ 2t =T ~ Permit Number: CJ~e~9 I- c ❑ No one available for inspection: Time 1ST AM~M Re-Inspection required: es No ' When corrections have been made, call for re-inspection at 303-234-5933 Date: /2',,"r/ -,4 Inspector: 13✓ DO NOT REMOVE THIS NOTICE ~ 4 ♦ r'ity nf'Whn-at IR -PERMIT NO: 094295 JOB 1ADDRESS: 4014-.< DESCRIPTION:T/o: f. ISSUED:` 12/01/2009 EXPIRES: 05/30/2010 Gary Theriaqu4 yr !shingle, Colanade Reat Estate 02-1170 Bear Brothers Roofing USE: UA ;BLOCK/LOT#: 0/ ESTIMATED PROJECT VALUATION: ?9,000.00: FEES Permit Fee 217 .50 Total Valuation 00 ---`y'` . i ) Use Tax 162 .00 L Ql L ° # # ~ / * * TOTAL * * 379 50 X.~ f . Conditions:. 6 nail installation & mid-roof inspection required.` Board sheathing spaced more thana 1/2 of an inch apart requires plywood overlay on entire roof. Ice and water, shieldrequired from eave edge to 2' inside exteriorwalls. i ***Contractor/Property owner shall provideladder(s) secured in place for inpsectlons..` Subject to field inspection.' I hereby certify that the setback distances proposed by this permit application are accurate, and do not violate. applicable ordinances, rules.. or regulations of the City of Wheat Ridge or covenants, easements or restrictions of record; that all measurements shown, and allegations made are accurate; that I have read and agree to abide by all conditions printed on this application and that I assume full responsibility for compliance with the Wheat Ridge Building Code. (i.B.C) and all other:.' applicable wheat R e Ordinances, for work under this permit. Plans subject to field inspection Signatu of contracto owner :date 1. This permit was issued in accordance with the provisionsset forth in your application and is subject to the laws of the'. State of Colorado and to the Zoning.:. Regulations and Building Codes of Wheat Ridge, Colorado or any'.. other applicable ordinances of the City...: 2. This permit shall expire .180 days from the issue date. Requests fore. an extension must be received prior to expiration date. A extension may. be granted at the discretion of the Building Official. 3. If this permit:. expires, a new permit may be acquired fora fee of one-half the. amount normally recuired nrnvided nn cnange Lae natural flow of water causing a drainage problem. :tor shall notify the Buildmg,lnspector: twenty-four (24) hours in advance for all inspections and shall receive i approval on inspection card before proceeding with successive phases of the job. Lance of a permit or the approval of drawings and ;specifications shall not be construed to be a permit for, nor oval of any violation of the provisions of the building codes or any other ordinance, law, rule or regulation. m revis. is ject to field inspections. BUILDINGOFFICE: .:(303)235 2855 1Y FOR INSPECTION THE FOLLOWING:. BUSINESS DAY. ~OFW HEArq'o City of Wheat Ridge Building Division m 7500 W. 29t" Ave., Wheat Ridge, CO 80033 Office: 303-235-2855 * Fax: 303-237-8929 (~o~orxnoo Inspection Line: 303-234-5933 Building Permit Application Property Address: 9~114lZ tl)-3q -P AIZJ1 -:5r' Property Owner (please print):(', ,t[U NADe _ 4_f:l( 65' ATC_ Phone: :3o3 qo-7 38Z 3 Mailing Address: (if different than property address) Address: E b g7 -317 C- City, State, Zip: W t-2-. ~,-O y 3 3 Contractor PL(~ ~~~psn t Contractor License Phone: -3e e t Z,Z -L) ZZS Sub:Contractors; Electrical City License Company: Plumbing City License Company [Date'* lan Permit Mechanical City License Company: Exp. Date: Exp. Date: Exp. Date: Approval: Approval: Approval: Use of space (description)--_'~j-Ck/L A~ -JL3 Construction Value: $ Fl DO Description of work: aht (as calculated per the Building Valuation Data sheet) -3 n S ~ ` 1 I Plan Review (due at time of submittal): b Sq. Ft./L.Ft added: Squares '3 ~ BTU's Gallons Amps OWNER/CONTRACTOR SIGNATURE OF UNDERSTANDING AND AGREEMENT I hereby certify that the setback distances proposed by this permit application are accurate, and do not violate applicable ordinances, rules or regulations of the City of Wheat Ridge or covenants, easements or restrictions of record; that all measurements shown, and allegations made are accurate; that 1 have read and agree to abide by all conditions printed on this application and that I assume full responsibility for compliance with the Wheat Ridge Building Code (I.B.C) and all other applicable Wheat Ridge Ordinances, for work under this permit. Plans subject to field inspection. CIRLCE ONE:: (OWNER) (CONTRACTOR) or PERSONAL REPRENTATIVE of (OW 00 NTRATOR) PRINT NAME ~s9/ZVI /y F/LiAYiI/A SIGNATURspate: l z l -O g - DEPARTMENT OF PLANNING AND DEVELOPMENT BUILDING INSPECTION LINE - 303-234-5933 CITY OF WHEAT RIDGE 7500 WEST 29TH AVENUE WHEAT RIDGE, CO 80215 - (303-235-2855) 12783 9/13/01 Property Owner : Property Address : 4014 PARFET ST Contractor License No. : 17174 Company : Bell Plumbing & Heating Phone: 463-6787 Phone: 757-5661 OWNER/CONTRACTOR SIGNATURE OF UNDERSTANDING AND AGREEMENT I hereby certiry that the setback distances proposed by this permit application are acwrate, and do not violate applicable ordinances, rules or regulations of the City of Wheat Ridge or covenants, easements or restrictions of record; that all measurements shown, and allegations made are accurate; that I have read and ayree to abide by all conditions printed on this application, and that I assume full responsibility for compliance with the Wheat Ridge Building Code (U.B.C.) and all other applicable Wheat Ridge ordinances, for work under this permit. (OWNER)(CONTRACTOR) SIGNED DATE Use: Description : GAS WATER HEATER REPLACEMENT 40 GALLON. 40,000 BTU BUILDING DEPARTMENT USE ONLY sic . r „ . Approval: Zoning : Building Permit Number Date Construction Value : $494.00 Permit Fee : $23.50 Plan Review Fee : $0.00 Use Tax : $7.41 Total: $30.91 ~~111010~~~~~.~,w•.e~e . Approval: Approval : Occupancy : Walls Roof Sq. Ft. : Stories : Residential Units : Electrical License No : Company : Expiration Date : Approval: Plumbing License No : Company: Expiration Date : Approval: Mechanical License No : 17174 Company : Bell Plumbing R Heating Expiration Date : 9/13101 Approval: (1) This permit was issued in accortlance with the provisions sel forth in yopur application and is subject ro the laws of the State of Coloratlo antl ro the Zoning Re9ulations and Building Cotle of Wheat Rid9e, Colorado or any other applicable ordinances of the City. (2) This permit shall expire if (A) the work authorized is nol commenced within sixty (60) days from issue date or (B) the Duiltling authorized is suspended or abantlonetl for a period of 120 days. (3) If this permit expires, a new permit may be acquiretl for a fee of one-half the amounl normally requireQ provided no changes have been or will be made in the original plans antl specifications and any suspension or abandonment has not exceeded one (1) year. If changes are made or if suspension or abandonment exceeds one (1) year, full fees shall be paia for a new permit (4) No work of any manner shall be done that will change the natural Flow of water causing a drainage problem. (5) Contractor shall notify the Building Inspeclor twenty-four (24) hours in advance for all inspec6ons and shall receive written approval on inspection card before proceed with successive phases of the1'ob. (e) T ' an ot per or the approval ot drawings and specifcations shall not be consimed ro be a permil for, nor an approval o( any violalion of the provisions of uil n ny other ordinance, law, rule or regulation. ~ Chief Building spector DEPARTMENT OF PLANNING AND DEVELOPMENT Application Number : BUILDING INSPECTION DIVISION - 235-2855 CITY OF WHEAT RIDGE Date : 7500 WEST 29TH AVENUE WHEAT RIDGE, CO 80215 PropBrty Owner: COLONADE REAL ESTATE SQRVICES Phone: 303/463-6787 Property Address: 4014 PARFET STREET Contractor License No. : 179078 Company: BELL PLUMBING & HEATING Phone:303/757-5661 OWNER/CONTRACTOR SIGNATURE OF UNDERSTANDING AND AGREEMENT I hereby certify that the setbadc distances proposed by this permrt application are accurate. and do not violate applicable ordinances. rules or regulations of the City of Wheat Ridge or coveqants, easements w restnctions of rewrd: that all measurements shown, and allegations made are accurate; that 1 have read an gre e to abide by I onditions printed on this appliwtion, and that I assume full res on ibJity for compl ce wdh th Wheat Ridge Building Code (U.B.CJ and all Wher applicab eat Ridge ordV nces for rk under this p mit. (OWNER)(CONTRACTOR) SIGN I~ DATE Construction Value : 494. 00 Permit Fee : Use Tax : Total : Description: GAS WATER HEATER REPLACEMENT 40 GALLON 40,000 BTU BUILDING DEPARTMENT USE ONLY Z~'tlqn~i~Fit~tent~ ApprovaB : Zoning : BIlRltf6t$~'mtr~enf~ Approval: Pfffi_I~_fMdrlar,Ccmrttents: Approval : Occupancy : Walls : Roof : Stories : Residential Units : Electrical License No : Company : Plumbing License No Company : Mechanical License No : Company : Expiration Date : Expiretion Date : Expiration Date : Approval Approval: Approval: Plans Required ; JffIYMPYm~~ (1) Thia pertnit was issuetl in accordance wrth the pronsions se[ fonn in yopur appfiwtion and is subjec[ to the laws of the SfaM of Colomtlo and to ihe Zoning Regulatlons and B~g Code af VMeat Fiidge. Coio2tlo or any other applirable ortlinances ol the Ciy. (2) This pertnit shall eapre d(A) Me work autnonzetl rs not commencetl within sixry (60) Eays fmm issue date or (B) Ihe Ouiltling authonzed is suspended a ahanOOneE ror a permE ot 120 aays. (3) If Mis pertnit exphes, a new pertnit may Oe acquiretl for a fee of one-Oaif the amount normally requireC, provitleC no changes have been ar wiN De matle in the onginal plans and specifirafions and any suspension or abantlonment nas not exceetletl one (1) year. If Uanges are matle or if suspension or abanEOnment exCeetls ane (1) ye9L full feEe shall be paitl for a new permrt. (4) No wark of any ~er shall be done Nat will Uange the naturai Bow of waler causing a drainage Droblem. (5) Contractor shall na1Yy Me Bulltlin9 Inspeclor twenry-four (24) hocrs in atlvance for all inspections and snall receive wntten approval on inspeclion card 6efore praceeEiing wlth wwrssive phases of t~e job. (8) The issuance of a pertnR or the approvai of tlrawings and speaf:cations shall not Ce consttue0 to be a permit for. nor an approval o( any violaUOn of Me provisions ot Ihe building coOes or any olner ordmance. law. mie or re9uiavon. Chief Building fnspector For Mayor THIS PERMIT VALID ONLY WHEN SIGNED BY THE CHIEF BUILDING INSPECTOR AND MAYOR CALL: 234-5933 24 HOURS PRIOR TO INSPECTION W.O. #259224