Loading...
HomeMy WebLinkAbout3305-3307 Teller StreetCity of Wheat Ridge Residential Roofing PERMIT - 201702525 PERMIT NO: 201702525 ISSUED: 06/26/2017 JOB ADDRESS: 3305 Teller ST EXPIRES: 06/26/2018 JOB DESCRIPTION: Residential Re -roof for 3305 & 3307 Teller St. to install Duration Storm asphalt shingles with ROOF DECKING - 32 sq. (26 sq. pitched, 6 sq. flat) *** CONTACTS *** OWNER 720-220-9124 RICKET TANYA SUB (303)942-0732 Armando J. Boon 170162 A.J. Boone Exteriors *** PARCEL INFO *** ZONE CODE: UA / Unassigned USE: UA / Unassigned SUBDIVISION CODE: UA / Unassigned BLOCK/LOT#: 0 / *** FEE SUMMARY *** ESTIMATED PROJECT VALUATION: 10,724.00 FEES Total Valuation 0.00 Use Tax 225.20 Permit Fee 220.15 " { ** TOTAL ** 445.35 - - *** COMMENTS *** *** CONDITIONS *** Effective December 1, 2014, asphalt shingle installations require an approved midroof inspection, conducted when 25-75 percent of the roof covering is installed, prior to final approval. Installation of roof sheathing (new or overlay) requires an approved inspection prior to installation of ANY roof coverings and is require on the entire roof when spaced or board sheathing with ANY gap exceeding A3�-inch exists. Asphalt shingles are required to be fastened to the roof deck with a minimum of 6 nails per shingle. Ice and water shield is required. Eave and rake metal is required. A ladder extending 3 feet above the roof eave and secured in place is required to be provided for all roof inspections. Roof ventilation is required to comply with applicable codes and/or manufacturera€"s installation instructions, whichever is more stringent. In order to pass a final inspection of elastomeric or similar type roof coverings, a letter of inspection and approval from the manufacturer&#39;s technical representative stating that "the application of the roof at (project address) has been applied in accordance with the installation instruction for (roof material brand name) roof covering" is required to be on site at the time of final inspection. City of Wheat Ridge Residential Roofing PERMIT - 201702525 PERMIT NO: 201702525 ISSUED: 06/26/2017 JOB ADDRESS: 3305 Teller ST EXPIRES: 06/26/2018 JOB DESCRIPTION: Residential Re -roof for 3305 & 3307 Teller St. to install Duration Storm asphalt shingles with ROOF DECKING - 32 sq. (26 sq. pitched, 6 sq. flat) I, by in signature, do hereby attest that the work to be performed shall comply with all accompanying approved plans and specifications, applicable building codes, and all applicable municipal codes, policies and procedures, and that 1 am the legal owner or have been authorized by the legal owner of the property and am authorized to obtain this permit and perform the work described and approved in conjunction with this ermrt. I further attest that I am legally authorized to include alt entities named within this document as parnes to the work to be performed andJltttwork�to be performed �s disclosed in this document and/or its' accompanying approved plans and specifications. Signature of OWNER or CONTRACTOR (Circle one) Date I. This permit was issued based on the information provided in the permit application and accompanying )tans and specifications and is subject to the compliance with those documents, and all applicable statutes, ordinances, regulations, policies and procedures. 2. This. permit shall expire 365 days after the date of issuance regardless of activity. Requests for extension must be made in writing and received prior to the date of expiration. An extension of no more than 180 days made be granted at the discretion of the Chief Building Official and maybe subject to a fee equal to one-half of the original permit fee. 3. If this permit expires, a new pen -nit may be required to be obtained. Issuance of a new permit shall be subject to the standard requirements, fees and procedures for approval of any new permit. Re -issuance or extension of expired pennits is at the sole discretion of the Chief Building Official and is not guaranteed. 4, No work of any manner shall be performed that shall results in a change of the natural flow of water without prior and specific approval. 5. The permit holder shall notify the Building and Inspection Services Division in accordance with established policy of all required inspections and shall not proceed or conceal work without written approval of such work from the Building and Inspection Services Division, 6. The issuance or granting of a permit shall not be construed to be a permit for or an approval of, any violation of any provision of any applicable code or any ordinance or regulation of this jurisdiction. Approval of work is subject to field inspection. Signature of Chief Buildim-IrDT 6ial Date REQUESTS MUST BE MADE BY 11:59PM ANY BUSINESS PY FOR INSPECTION THE FOLLOWING BUSINESS DAY. Inspection time requests will be accepted by email only. Please email requests to insptimerequest@ci.wheatridge.co.us between 7:30am and 8:00am, the morning of the inspection. Please put the address of the inspection in the subject line. Dan Schultz From: no-reply@ci.wheatridge.co.us Sent: Wednesday, June 14, 2017 8:45 AM To: Permits CommDev Subject: Online Form Submittal: Residential Roofing Permit Application Categories: Danny Residential Roofing Permit Application This application is exclusively for new permits for residential roofs and for licensed contractors only. This type of permit is ONLY being processed online --do not come to City Hall to submit an application in person. Permits are processed and issued in the order they are received. YOU WILL BE CONTACTED WHEN YOUR PERMIT IS READY FOR PICK-UP AND WILL BE GIVEN A SPECIFIC DATE AND TIME WINDOW TO COMPLETE THE TRANSACTION. You will be notified if your contractor's license or insurance has expired, and you may update those documents at the time you are issued your permit. Permits are currently being processed within 3-5 business days, subject to change based on volume. For all other requests: Homeowners wishing to obtain a roofing permit must apply for the permit in person at City Hall. Revisions to existing permits (for example, to add redecking) must be completed in person at City Hall. All other non -roofing permits must be completed in person at City Hall. The Building Division will be open from 7:30-10:30 a.m., Monday through Friday to process these types of requests. THIS APPLICATION DOES NOT CONSTITUTE A PERMIT. DO NOT BEGIN REROOFING UNTIL PERMIT HAS BEEN ISSUED. Is this application for a Yes residential roof? How many dwelling units Single Family Home are on the property? PROPERTY INFORMATION Property Address 3305 / 3307 TELLER ST WHEAT RIDGE CO Property Owner Name TANYA RICKET Property Owner Phone 720-220-9124 Number Property Owner Email Field not completed. $ &f q F. -3 -,C- Address Do you have a signed Yes contract to reroof this property? It will need to be provided at the time of permit pick-up. CONTRACTOR INFORMATION Contractor Name Contractor's License Number (for the City of Wheat Ridge) Contractor Phone Number ARMANDO J BOONE 170162 720-383-5677 Contractor Email Address aibooneexteriorsCo)gmail.com (permit pick-up instructions will be sent to this email) Retype Contractor Email Address DESCRIPTION OF WORK Are you re -decking the roof? Description of Roofing Material aibooneexteriors(a gmail.com Yes ✓ DURATON STORM Select Type of Material: Asphalt If "Other" is selected Field not completed. above, describe here: How many squares of the 26 material selected above? Does any portion of the Yes property include a flat roof? If yes, how many squares 6 SQUARE on the flat roof? 2 TOTAL SQUARES of all roofing material for this project Provide additional detail here on the description of work. (Is this for a house or garage? What is the roof pitch? Etc) REPLACE ROOF ON HOUSE, 4/12 PITCH Project Value (contract—g@oo-�--- lot value or cost of ALL materials and labor) SIGNATURE OF UNDERSTANDING AND AGREEMENT I assume full Yes responsibility for compliance with applicable City of Wheat Ridge codes and ordinances for work under any permit issued based on this application. I understand that this Yes application is NOT a permit. I understand I will be contacted by the City to pay for and pick up the permit for this property. I understand that work Yes may not begin on this property until a permit has been issued and posted on the property. I certify that I have been Yes authorized by the legal owner of the property to submit this application and to perform the work described above. Name of Applicant Daniel Boone Email not displaying correctly? View it in your browser. 3 4245 S. Cimarron Way Suite 416 Aurora, CO 80014 303-942-0732 Ajbooneexteriors@gmail.com SCC' AJ BOONE EXTERIORS Customer ;C c Street `— CityjSTzip Email Home SPECIFICATION ❑ Mfg. of Shingle '^ ❑ Style of Shingle ❑ Warranty ❑ Valley Vents _ ❑ Drip Edge 2x2 Color ❑ Modified Bit Color ❑ Decking 1/2 OSB ❑ Skylights: How many? Size ❑ Permit Furnished: ❑ Y ❑ N PAYMENT SCHEUDLE Contract Price Upon Delivery of Material and Balance Due Upon Completion of Each Trade Date b-) I 1 Consultant Estimated Start Date Finish Number of Squares Agent SPECIAL INSTRUCTIONS Debris Removal Tax Permit Overhead/Profit TOTAL PLUS PERMIT AND SUPPLEMENTS Terms: This agreement is for FULL SCOPE OF INSURANCE PROCEEDS and is subject to insurance company approval. This does not obligate client or AJ Boone Exteriors unless repairs are approved by homeowner's insurance company. By signing this agreement the homeowner authorizes AI Boone Exteriors to pursue homeowners best interest for all repairs at a price agreeable to the insurance company and AJ Boone Exteriors at NO COST TO THE CLIENT, EXCEPT FOR THE INSURANCE DEDUCTIBLE.The final price agreed on between the insurance company and AJ Boone Exteriors shall become the final contract price. The specifications INITIAL are set out herein and on the reverse side hereof to accomplish the replacement or repairAJ Boone Exteriors is hereby authorized to perform at their discretion all insurance prescribed repairs for the price of full scope of insurance proceeds agreed upon by my insurance company and AJ Boone Exteriors. The terms and specifications stated and special conditions are accepted. THREE DAY RIGHT OF RESCISSION: I have hereby been notified that I may cancel is agreement at anytime prior to midnigh f e thi business day after the date of this agreem ACCEPTED BY: DATE: ONSULTANT: DATE: e VERBAL COMMITMENTS WILL NOT BE HONORED AND MAKE ALL PAYMENTS TO AJ Boone Exteriors. THIS AGREEMENT CONSISTS OF THE FRONT AND BACKSIDE OF THIS DOCUMENT. CLIENTS RESPONSIBLE FOR H.O.A. OR COVENANT APPROVAL FOR SHINGLES. Drip Edge 2x4 Color ❑ Layers 2 Story ❑ Chimney Flash Pipe Boots ❑ Bath Vents Stepflash ❑ Ice & Water Shield Rows ❑ Modified Bit Color ❑ Decking 1/2 OSB ❑ Skylights: How many? Size ❑ Permit Furnished: ❑ Y ❑ N PAYMENT SCHEUDLE Contract Price Upon Delivery of Material and Balance Due Upon Completion of Each Trade Date b-) I 1 Consultant Estimated Start Date Finish Number of Squares Agent SPECIAL INSTRUCTIONS Debris Removal Tax Permit Overhead/Profit TOTAL PLUS PERMIT AND SUPPLEMENTS Terms: This agreement is for FULL SCOPE OF INSURANCE PROCEEDS and is subject to insurance company approval. This does not obligate client or AJ Boone Exteriors unless repairs are approved by homeowner's insurance company. By signing this agreement the homeowner authorizes AI Boone Exteriors to pursue homeowners best interest for all repairs at a price agreeable to the insurance company and AJ Boone Exteriors at NO COST TO THE CLIENT, EXCEPT FOR THE INSURANCE DEDUCTIBLE.The final price agreed on between the insurance company and AJ Boone Exteriors shall become the final contract price. The specifications INITIAL are set out herein and on the reverse side hereof to accomplish the replacement or repairAJ Boone Exteriors is hereby authorized to perform at their discretion all insurance prescribed repairs for the price of full scope of insurance proceeds agreed upon by my insurance company and AJ Boone Exteriors. The terms and specifications stated and special conditions are accepted. THREE DAY RIGHT OF RESCISSION: I have hereby been notified that I may cancel is agreement at anytime prior to midnigh f e thi business day after the date of this agreem ACCEPTED BY: DATE: ONSULTANT: DATE: e VERBAL COMMITMENTS WILL NOT BE HONORED AND MAKE ALL PAYMENTS TO AJ Boone Exteriors. THIS AGREEMENT CONSISTS OF THE FRONT AND BACKSIDE OF THIS DOCUMENT. CLIENTS RESPONSIBLE FOR H.O.A. OR COVENANT APPROVAL FOR SHINGLES. General Terms and Conditions rime for Acceptance of Agreement: This offer to enter into an Agreement must be unconditionally accepted and signed by the Customer (hereinafter, 'Customer" or "Homeowner" or "Owner"). The Original ofthis Contract, these General Terms and Conditions, the "How to Prepare & What To Expect For a Construction Job'; (collectively, the "Agreement") and the required deposit, in cleared funds, must be delivered to Contractor after signing by Customer If this Agreement is not delivered to Contractor, Contractor may reject this offer to enter into an Agreement and cancel it. Customer understands and agrees that Contractor's acceptance ofthis Agreement is conditioned upon approval of Customer by Contractor's Credit Department the Customer's Insurer's acceptance of this Agreement, if applicable, with any proposed changes/ additions/deletions as approved by Contractor, if any. Contingent Agreements are not accepted until final approval. Payment: Customer shall pay the Deposit upon delivery of materials. All progress payments shall be due within ten (10) days after invoice date. Payments not made within this time shall incur a late fee equal to five percent (5%) of payment as reflected on the invoice. Final payment shall be due upon when the Final invoice is received. Any sum not paid when due shall bear interest from the due date until paid in full at EIGHTEEN PERCENT (18%) per annum or the maximum legal rate until paid in full, compounded annually_ Warranties and Limitations on Liability: Contractor warrants to Customer that installation shall be free of defects in workmanship for a period oftwo (02) years only, reasonable wear and tear, and acts of God excepted. Claims of defective installation must be made in writing, signed, and describe the defect in workmanship with sufficient particularity to permit remedy, if covered. NOTICE TO CUSTOMER: Removal of a Construction system lifts a great weight from the building. This may cause uplift in the building, and may result in cracking of interior/exterior walls, ceilings, and floors. Such cracking may disappear upon roof replacement. Uplift is unavoidable and constitutes an accepted hazard by Customer. Contractor has no liability for uplift hazard. Re -Construction also requires removal ofthe membrane protecting the building from rainwater. Contractor will use reasonable efforts to coverthe roof if rain occurs during re -roofing. If rains occur (an Act of God) during reroofing, water intrusion and even mold infestations are inevitable. If rain incursion or mold infestation occurs, Contractor shall not be liable. Should Driveways, and Sidewalks become marked or cracked due to equipment and material, Contractor shall not be liable_ Should fire, casualty, vandalism, storms, or whole or partial destruction ofthe building occur during Re -Construction and such is not the direct result of Contractor's work, Customer shall look to other sources for recourse for resulting damage to building, and Contractor shall not be liable therefor. Change Orders: Any extra work which is requested, or which is reasonably required due to the condition of the building, or as a result in Building Code changes, or is the result of interpretation of Building Code requirements by government sponsored Building Inspectors, shall be performed only after a written Change Order is signed by Customer upon Contractor's Approved Change Order Form, delivered to Contractor, together with full payment in cleared funds for such change_ A Change Order may increase or decrease the agreed price, completion time, materials and labor required, and affect otherterms ofthis Agreement, all ofwhich Customer agrees to by Customer's signature hereto. Work Funded by Insurance Payments: in the event work Is to be funded from insurance proceeds, this Agreement is subject to the approval of Customer's Insurer. Changes approved by Customer's Insurer become a part ofthis Agreement and are specifically approved by Customer by Customer's signature hereto_ Contractor shall inspect the building and provide estimates and supporting documentation to assist Customer in obtaining Insurer's approval of Contractor's proposed work. Contractor shall be available to meetwith Customer's insurer and provide estimates ofthe value of property damaged and/orto be repaired upon request of Customer and/or Insurer. The Customer and his Insurer shall agree to the total price which funds are irrevocably assigned to Contractor_ Customer authorizes Contractorto provide estimates and supporting documentation to Customer's Insurer. if, in Contractor's opinion, Insurer refuses to adequately fund the work, Contractor may terminate this Agreement. Customer agrees to pay any deductible or outstanding charges reasonably incurred by Contractor in assisting Customer's solicitation of Insurer's approval. Customer's Covenant of Noninterference: Customer shall not attempt to direct Contractor or its employees, agents, or servants, exclude them from the site, demand work from them, remove from the work site the permit or any other documentation required to be on-site, or in any other manner interfere with Contractor's performance of the contracted work. Any fees, fines, or other charges imposed as a result of Owner's failure to abide by the terms ofthis Agreement, or interference in/with performance of Contractor's work, shall be borne solely by Owner, who agrees to same, by signing this Agreement. Customer's Required Insurance: Customer shall carry homeowner's insurance in the full replacement value of all improvements on the property and public liability insurance and shall provide evidence thereofto Contractor throughout the term hereof. Contractor's Required Insurance: Contractor shall carry all insurance, if any, required by law to be carried by Contractor. Removal of Screens, Gutters, Other Roof Obstructions, and Code issues: If screens, gutters, solar panels, or other objects obstruct access to or, prevent -ompletion of installation/repair of, facia or areas of the roof, Customer shall remove and replace any such obstruction at Customer's sole expense. Any uncovered defects, rotten decking, facia, rafters, siding which was not included in the original contract will be at the sole expense ofthe Customer. Default: In the event either party hereto defaults in performing any covenant hereof, the non -defaulting party shall deliverto the defaulting party a dated 'Notice of Default'; specifying the default and requesting correction thereof. In the event the default is not corrected within fourteen (14) days after receipt of such Notice of Default, the non- defaulting party shall have all remedies at law and in equity for said default. In addition to any other remedy for default provided herein or at Colorado law, Contractor shall have the right, but not the obligation, to suspend or terminate its work, to retain all deposits then held, to peacefully repossess all Materials previously delivered or installed for which payment has not been made in full, to remove its equipment from the Job Site, and to terminate this Agreement. Notices: Any notice to Customer shall be sufficient if delivered to the address ofthe Customer given in this Agreement, by hand -delivery or Certified U.S. Mail. Any and all notices to the Contractor shall be deemed effective only if mailed to the Contractor at 4245 S. Cimarron Way Ste. 416, Aurora, Co 80014 and shall be effective only if actually received by Contractor at such address. Assignment: Neither this Agreement nor any warranty granted herein is assignable by Customer. Acts of God and Delays: In the event the completion of the work is prevented or delayed due to damage or destruction ofthe building, fire, accident, vandal- ism, earth movement, tornado, windstorm, or any Act of God whatsoever, theft, labor strikes, warfare, materials shortages, delay occasioned by any governmen- tal agency in issuing any required permit or certificate, or in failing/refusing to perform required inspections, litigation, or any other matter not the sole fault of Contractor, or beyond Contractor's control, any act of neglect of the owner or any representative or employee of owner, delivery delays, unavoidable casualties or other causes beyond the Contractor's control, then the completion of work shall be delayed until a reasonable later date and Contractor and Customer shall sign a Change Order so providing. In accordance herewith, or If Customer declines to sign the Change Order, then this Agreement may be terminated by Contractor, whereupon all sums then due to Contractor for work completed shall be due and payable to Contractor immediately. rime is Of The Essence: Time is ofthe essence in this Agreement for payment only. Cancellation of This Agreement: In the event of termination by owner after three (3) days, Owner shall pay Contractor (a) amounts due at the time based on the payment schedule for the work completed; (b) any amounts due In any Change Order; (c) amounts due for allowances or finish selections which have been made; (d) all expenses incurred by Contractor in connection with the Project that are not otherwise covered under this subparagraph; and (e) all ofthe amounts to be paid to Contractor as set forth in the preceding sentence, plus any profit Contractor would have earned under the Agreement in the absence of such default by Owner. Contractor will accept 25% ofthe contract amount as long as no material or labor have been furnished. Governing Law, Venue, Waiver of Jury Trial, and Attorney's Fees: This Agreement is to be governed by the laws of Colorado. Venue for any action other than a lien foreclosure may, at Contractor's option, lie in Denver, Colorado, at Contractor's election. The parties Intentionally waive the right ofjury trial. In any litigation arising under this Agreement, customer is responsible for all attorney fees and court cost for AJ Boone Exteriors Entire Agreement: No Prior Representations: Amendment: This is the entire agreement between Contractor and Customer. There is no representation, past or present, by Contractor or any person acting for Contractor, which does not appear herein. This Agreement may not be amended except by a written Change Order or Amendment executed and paid for as provided herein. Severability: In the event that any provision ofthis Agreement is found by a court of competent jurisdiction to be invalid or unenforceable for any reason whatsoever, then the remaining provisions hereof shall remain in full force and effect. Commencement and Completion Dates: The Increase in frequency of storms, and the resulting increased demand for Construction and other materials, has resulted in shortages of such materials. In addition, the and shingle types are sometimes simply not immediately available, or are discontinued_ In addition, hail and windstorms cause incredible demand for roof repairs which are needed to prevent serious roof leaks and even loss of a home. Contractor has no control over these events. Therefore, the Contractor agrees to commence, and complete, the work within a reasonable time after the signing ofthe contract, dependent upon the availability of materials. Acceptance of this Contract constitutes agreement to these general terms and conditions. 1) If property owner plans to pay for the roofing services through an insurance claim, the contractor cannot pay, waive or rebate the homeowner's insurance deductible in whole or part. 2) AJ Boone Exteriors shall hold in trust any payment from the property owner until AJ Boone Exteriors has delivered materials to the job site or has performed a majority of the work on the property. 4245 S. Cimarron Way Suite 416 Aurora, CO 80014 303-942-0732 Ajbooneexteriors@gmail.com /so 100 or \ AJBOONE EXTERIORS SPECIFICATION ❑ Mfg. of Shingle CX.OQ-Ac ► 1 f t ❑ Style of Shingle ❑ Warranty ❑ Valley Vents ❑ Drip Edge 2x2 Color ❑ Drip Edge 2x4 Layers Chimney Flash ❑ Bath Vents Color 2 Story Pipe Boots Stepfiash ❑ Ice & Water Shield Rows ❑ Modified Bit Color Decking '/z OSB Skylights: How many?_ Permit Furnished: ❑ Y OWL Size PAYMENT SCHEUDLE '/z Contract Price Upon Delivery of Material and Balance Due Upon Completion of Each Trade PQ,r�f Date 17 Consultant Estimated Start Date Finish Number of Squares Agent SPECIAL INSTRUCTIONS r + �Q- �C-- 'C �. c ✓LCA S i �.t) f ?'� �� i Debris Removal Tax Permit l j Overhead/Profit I'�f T�1 IG.r M TOTAL 3 . 0 PLUS PERMIT AND SUPPLEMENTS INITIAL Terms: This agreement is for FULL SCOPE OF INSURANCE PROCEEDS and is subject to insurance company approval. This does not obligate client or AJ Boom Exteriors unless repairs are approved by homeowner's insurance company. By signing this agreement the homeowner authorize AJ Boone Exteriors to pursue homeowners best interest for all repairs at a price agreeable to the insurance company and AJ Boone Exteriors at NO COST TO THE CLIENT EXCEPT FOR THE INSURANCE DEDUCTIBLE.The final price agreed on between the insurance company and AJ Boone Exteriors shall become the final contract price. The specifications INITIAL are set out herein and on the reverse side hereof to accomplish the replacement or repairAJ Boone Exteriors is hereby authorized to perform at their discretion all insurance prescribed repairs for the price of full scope of insurance proceeds agreed upon by my insurance company and AJ Boone Exteriors. The terms and specifications stated and special conditions are accepted. THREE DAY RIGHT OF RESCISSION: I have hereby been notified that I may cancel this agreement at any time prior to mid Ight f he t ' business day after the date of this agreement. / ACCEPTED BY:� � 4 DATE: 7 CONSULTAN :� DATE: *� VERBAL COM ITMENTS WILL NOT JBE HONORED AND MAKE ALL PAYMENTS TO AJ Boone Exteriors. THIS AGREEMENT CONSISTS OF THE FRONT AND BACKSIDE OF THIS DOCUMENT. CLIENTS RESPONSIBLE FOR H.O.A. OR COVENANT APPROVAL FOR SHINGLES. General Terms and Conditions rime for Acceptance of Agreement: This offer to enter into an Agreement must be unconditionally accepted and signed by the Customer (hereinafter, 'Customer" or "Homeowner" or "Owner"). The Original of this Contract, these General Terms and Conditions, the "How to Prepare & What To Expect For a Construction Job'; (collectively, the "Agreement") and the required deposit, in cleared funds, must be delivered to Contractor after signing by Customer_ If this Agreement is not delivered to Contractor, Contractor may reject this offer to enter into an Agreement and cancel it. Customer understands and agrees that Contractor's acceptance ofthis Agreement is conditioned upon approval of Customer by Contractor's Credit Department, the Customer's Insurer's acceptance of this Agreement, if applicable, with any proposed changes/ additions/deletions as approved by Contractor, if any. Contingent Agreements are not accepted until final approval. Payment: Customer shall pay the Deposit upon delivery of materials. All progress payments shall be due within ten (10) days after Invoice date. Payments not made within this time shall incur a late fee equal to five percent (5%) of payment as reflected on the invoice. Final payment shall be due upon when the Final invoice is received. Any sum not paid when due shall bear interest from the due date until paid in full at EIGHTEEN PERCENT (18%) per annum or the maximum legal rate until paid in full, compounded annually. Warranties and Limitations on Liability: Contractor warrants to Customer that installation shall be free of defects in workmanship for a period of two (02) years only, reasonable wear and tear, and acts of God excepted. Claims of defective installation must be made in writing, signed, and describe the defect in workmanship with sufficient particularity to permit remedy, if covered. NOTICE TO CUSTOMER: Removal of a Construction system lifts a great weight from the building. This may cause uplift in the building, and may result in cracking of interior/exterior walls, ceilings, and floors. Such cracking may disappear upon roof replacement Uplift is unavoidable and constitutes an accepted hazard by Customer. Contractor has no liability for uplift hazard. Re -Construction also requires removal ofthe membrane protecting the building from rainwater. Contractor will use reasonable efforts to cover the roof If rain occurs during re -roofing. If rains accur (an Ad of God) during reroofing, water intrusion and even mold infestations are inevitable. If rain incursion or mold infestation occurs, Contractor shall not be !cable. Should Driveways, and Sidewalks become marked or cracked due to equipment and material, Contractor shall not be liable. Should fire, casualty, vandalism, storms, or whole or partial destruction ofthe building occur during Re -Construction and such is not the direct result of Contractor's work, Customer shall look to other sources for recourse for resulting damage to building, and Contractor shall not be liable therefor. Change Orders: Any extra work which is requested, or which is reasonably required due to the condition of the building, or as a result in Building Code changes, or is the result of interpretation of Building Code requirements by government sponsored Building Inspectors, shall be performed only after a written Change Drder is signed by Customer upon Contractor's Approved Change Order Form, delivered to Contractor, together with full payment in cleared funds for such change_ A Change Order may increase or decrease the agreed price, completion time, materials and labor required, and affect other terms ofthis Agreement, all Df which Customer agrees to by Customer's signature hereto. Work Funded by Insurance Payments: In the event work is to be funded from insurance proceeds, this Agreement is subject to the approval of Customer's Insurer. Changes approved by Customer's Insurer become a part ofthis Agreement and are specifically approved by Customer by Customer's signature hereto. Contractor shall inspect the building and provide estimates and supporting documentation to assist Customer in obtaining Insurer's approval of Contractor's proposed work. Contractor shall be available to meet with Customer's Insurer and provide estimates ofthe value of property damaged and/or to be repaired upon request of Customer and/or Insurer. The Customer and his insurer shall agree to the total price which funds are irrevocably assigned to Contractor. Customer authorizes Contractorto provide estimates and supporting documentation to Customer's Insurer. If, in Contractor's opinion, Insurer refuses to adequately fund the work, Contractor may terminate this Agreement Customer agrees to pay any deductible or outstanding charges reasonably incurred by Contractor in assisting Customer's solicitation of Insurer's approval. Customer's Covenant of Noninterference: Customer shall not attempt to direct Contractor or its employees, agents, or servants, exclude them from the site, demand work from them, remove from the work site the permit or any other documentation required to be on-site, or in any other manner interfere with Contractor's performance ofthe contracted work. Any fees, fines, or other charges imposed as a result of Owner's failure to abide by the terms ofthis Agreement :)r interference in/with performance of Contractor's work, shall be borne solely by Owner, who agrees to same, by signing this Agreement. Customer's Required Insurance: Customer shall carry homeowner's insurance in the full replacement value of all improvements on the property and public :lability insurance and shall provide evidence thereofto Contractor throughout the term hereof. Contractor's Required Insurance: Contractor shall carry all insurance, if any, required by law to be carried by Contractor. Removal of Screens, Gutters, Other Roof Obstructions, and Code Issues: If screens, gutters, solar panels, or other objects obstruct access to or, prevent completion of installation/repair of, facia or areas of the roof, Customer shall remove and replace any such obstruction at Customer's sole expense. Any uncovered defects, rotten decking, facia, rafters, siding which was not included in the original contract will be at the sole expense ofthe Customer. Default: In the event either party hereto defaults in performing any covenant hereof, the non -defaulting party shall deliverto the defaulting party a dated 'Notice of Default'; specifying the default and requesting correction thereof. In the event the default is not corrected within fourteen (14) days after receipt of such Notice of Default, the non- defaulting party shall have all remedies at law and in equity for said default_ In addition to any other remedy for default provided herein or at Colorado law, Contractor shall have the right, but not the obligation, to suspend or terminate its work, to retain all deposits then held, to peacefully repossess all Materials previously delivered or installed for which payment has not been made in full, to remove its equipment from the Job Site, and to terminate this Agreement. Notices: Any notice to Customer shall be sufficient if delivered to the address of the Customer given in this Agreement, by hand -delivery or Certified U.S. Mail. Any and all notices to the Contractor shall be deemed effective only if mailed to the Contractor at 4245 S. Cimarron Way Ste. 416, Aurora, Co 80014 and shall be effective only if actually received by Contractor at such address. Assignment: Neitherthis Agreement nor any warranty granted herein is assignable by Customer. Acts of God and Delays: In the event the completion ofthe work is prevented or delayed due to damage or destruction ofthe building, fire, accident, vandal- ism, earth movement, tornado, windstorm, or any Act of God whatsoever, theft, labor strikes, warfare, materials shortages, delay occasioned by any governmen- tal agency in issuing any required permit or certificate, or in failing/refusing to perform required inspections, litigation, or any other matter not the sole fault of Contractor, or beyond Contractor's control, any act of neglect ofthe owner or any representative or employee of owner, delivery delays, unavoidable casualties or other causes beyond the Contractor's control, then the completion of work shall be delayed until a reasonable later date and Contractor and Customer shall sign a Change Order so providing. In accordance herewith, or If Customer declines to sign the Change Order, then this Agreement may be terminated by Contractor, whereupon all sums then due to Contractor for work completed shall be due and payable to Contractor immediately. rime Is Of The Essence: Time is ofthe essence in this Agreement for payment only. Cancellation of This Agreement: In the event of termination by owner after three (3) days, Owner shall pay Contractor (a) amounts due at the time based on the payment schedule for the work completed; (b) any amounts due In any Change Order; (c) amounts due for allowances or finish selections which have been made; (d) all expenses incurred by Contractor in connection with the Project that are not otherwise covered under this subparagraph; and (e) all ofthe amounts to be paid to Contractor as set forth in the preceding sentence, plus any profit Contractor would have earned under the Agreement in the absence of such default by Owner. Contractor will accept 25% of the contract amount as long as no material or labor have been furnished. Governing Law, Venue, Waiver of Jury Trial, and Attorney's Fees: This Agreement is to be governed by the laws of Colorado. Venue for any action other than a lien foreclosure may, at Contractor's option, lie in Denver, Colorado, at Contractor's election_ The parties intentionally waive the right of jury trial. In any litigation arising under this Agreement, customer is responsible for all attorney fees and court cost for AJ Boone Exteriors Entire Agreement: No Prior Representations: Amendment: This is the entire agreement between Contractor and Customer. There is no representation, past or present, by Contractor or any person acting for Contractor, which does not appear herein. This Agreement may not be amended except by a written Change Order or Amendment executed and paid for as provided herein. Severability: In the event that any provision ofthis Agreement is found by a court of competent jurisdiction to be invalid or unenforceable for any reason whatsoever, then the remaining provisions hereof shall remain in full force and effect. Commencement and Completion Dates: The increase in frequency of storms, and the resulting increased demand for Construction and other materials, has resulted in shortages of such materials. In addition, tile and shingle types are sometimes simply not immediately available, or are discontinued. In addition, hail and windstorms cause incredible demand for roof repairs which are needed to prevent serious roof leaks and even loss of a home. Contractor has no control over these events. Therefore, the Contractor agrees to commence, and complete, the work within a reasonable time after the signing of the contract, dependent upon the availability of materials. Acceptance of this Contract constitutes agreement to these general terms and conditions. 1) If property owner plans to pay for the roofing services through an insurance claim, the contractor cannot pay, waive or rebate the homeowner's insurance deductible in whole or part. 2) AJ Boone Exteriors shall hold in trust any payment from the property owner until AJ Boone Exteriors has delivered materials to the job site or has performed a majority of the work on the property. i CITY OF WHEAT RIDGE _:�9�Building Inspection Division (303) 234-5933 Inspection line (303) 235-2855 Office • (303) 237-8929 Fax INSPECTION NOTICE Inspection Type: MT6 Job Address: Permit Number: mol `70 �5a5 ❑ No one available for inspection: Time AM/PI Re -Inspection required: Yes / No When corrections have been made, call for re -inspection at 303-234-593 Date: �q Inspector: �o r__X1d= DO NOT REMOVE THIS NOTICE City of Wheat Ridge ow Residential Electric PERMIT - 070299 PERMIT N0: 070299 . . ISSUED: 04/10/2007 JOB ADDRESS: 3305-07 TELLER ST EXPIRES: 10/07/2007 DESCRIPTION: electric panel replacement fo r Unit 3307 r«. CONTAC'i'$.."*«•. . . . . . . . gc ~303/431-8015 . 01-9402 Aaark Heating & Air Conditioni owner 720/939-9410 MePherson PARCEL INFO ZONE CODE: . UA USE: UA SUBDIVISION: UA BLOCK/LOT#: 0/ FEE SUMMARY . ESTTMATSD PROJECT VALUATION: 975.00 FE&S Permit Fee . 50.40 . . . Total Valuation .00 Use Tax 17.55 TOTAL 67.95 Comments : Electrical must meet 2005 .NEC Subject to field inspection i hereby certify that the eetback diatancee propoeed by thie pemit application are accurate, and do not.violate applicable ordinancee,rulee or regulatione ol.the City of Wheat Ridge or covenante, eaeemente on reetrictione of iCCOrd; that all measusemente ehown, and allegationa made are accurate; that I have read and agree to abide by all conditione printed on thie application and Chat I aeeume full reeponeiDility for compllance wi[h the Wheat Ridge Building Code (I.B.C) and all other applicable WheatRidgeOrdinancee; for work under thie permit. Plana eubject to field inepeceion. . Signature of con[ractor/owner date i. Thie pemit wae ieaued in accordance with Che provieione eet forth in your application and ie eubject to the laws of the State of Colorado andto theZOnin9 xe9ulatione and Euilding Codee of Wheat Ridge, Colorado or any other applicable ordinancee of the Ci[y. 2. Thie pemit ahall expire 180days from the ieeue date. Requeete foz an extenelon mueC be received prior to expiration date. An exteneionmay be 9ranted at the diecretion of the euilding OLficial. 3. if thie pemit expires, a aew pemit may be acquired for a fee of one-half the amount normally requiced, provided no chan9ee have been oz will bemade in the original plana and apecificatione and anyeuepeneion or abandonment has not exceeded one (1) year. If changee have been or if suepeneion or abandonment exceede one (1) yeaz,. fuli. Eeee ehall be paid for a new yermit. 4. No.work of any mannereM1all be done thaG will change the natural flow of water caueing a drainage problem. 5. Contractor ehall notify the Building Inapector twenty-four (24) houra in advance for all inepectione and ahall receive written approvalon inspection card before proceeding with eucceaeive phaeee of the job. 6. The Seauance bf a pemit or the ro al of drawinge and epeciflcatione ehall not be conetrued to.bea.permit Eor, nor an approvalof, viola U n~,1~ app,a~viCeione of the building codee or any other ordinance, lav; ruleor regulation. All plan rev i eubje to x 1 tione. _Signature date INSPSCTION RBQUSST LINB: (303)234-5933 BUILDING OFFICE: (303)235-2855 - REQUESTS MUST BE MADE BY 3PM ANY BUSINESS DAY FOR INSPECTION THE FOLLOWINQ SUSINESS DAY. DEPARTAAENT OF PLANNIN(i AND DEVELOPMENT Building Permft Number : BUILDING INSPECTION DIVISION - 235-28b6 Date : CITY OF WHEAT RlDCiE 7600 WEST 28TH AVENUE VYHEAT RIDCiE, CO 80218 Property Owner : ProperryAddress: b 7 Phone: ContracWr License No. Company y3s - Pnone OWNERICONTRACTOR SIGNATURE OF UNDERSTANDINO AND AOREEMENT Constructlon Value : ,7 Permit Fee : Sv • y~ Use Tax : l 7. rohal : 6 7 ~i APPtovel: ZoNno: APWwaI : Approval: BUILDING pccupancy : Walls : Roof USE ONLY Stories : Residential Unib : Ekctrkal License No : Plumbing Ucense No : Mechanical Ucense No : Company : Company : CompanY : .ExIDir_aflon .Rate : ExPir$ticn Aate.:._ . _ ExpIratlon Date : A . pproval : MProval : MDroval : ■ ~ ~ ~ , (1) m.v.ffAw.rN,.ah.ooa"=wInn.FMISWw.«aro+Nyowr.Ppmmn .ror.e~abin.wr. aursue. acaa.ao .~enwz«~u W~upeYq Cod~dlMwRRW~, CWonOOauyatlw~~pkaW adM~rwwd Clb. Aw~wdor . (2) ~WIl6xpn~WYrwakrp~aWdMnotmmw~aWwMNnWy(a0) aMUan YwA Gqa(O)tlrWIWWw7aW Y oDrdarabra d190yy~, m ~~~~p~mN ffW peaWu4Wa.w.aarn.rer.mwuewmuYr~w~+b.~n p.wmw.vrw~wMwoor.erwomrM nd rnd ora0andomwitlwnol~xaW~damfllyrc ..a.war(1)rw.w...naapa"~Or". wD~ (4) No rw~c a.ry mvuw wr a aa,. nrwl tlww tl»~'^•mal aow awaur . aalnw~ aoDm CaW~cbr WII rqUfY IM BWIdYqy~p~ppf W~N~ (24) Iwun M advana br atl ~n0 NU nWv~ rnW~n ~DGra'al on YWp~Gfon taN DWam wph uKa+dw Wrus d IM ~a1 ar ~ a. peffA a~~w~~ wu ~wc a muw.a a wa o«mn a, nor.n.vawy a..nv wrua+a m. vrowWa+. Chlef BuUd(np Inspactor Fw Mayor SIGNED CHIEF THE BUILDING THIS PERMIT VAUD CONLY ALL 2H34-6833 24 HOU S PRIOR TO INSPECTION INSPECTOR AND 1AAYOR (pyyPlERxCpNTRACTOR) SIGNED DATE DescripUon : DEPARTMENT OF PLANNING AND DEVELOPMENT , BUILDING INSPECTION DIVISION - 235-2855 CITY OF WHEAT RIDGE 7500 WEST 29TH AVENUE WHEAT RIDGE, CO 80215 Building Permit Number : Date : Properry Owner :Ma+'c1a r2`~ 1>4 r r~ Property Address : 3"305 ' 330:1 'r¢It2r 5-~Yez~l Contractor License No. : Company : Construction Value Permit Fee Use Tax Total OWNEWCONTRACTOR SIGNATURE OF UNDERSTANDING AND AGREEMENT i hereby certify lhat the sethack distanr,es proposed by this pertnit a001ication are accurate, and do not violate applicable ordinances, rules ot regulations ot the Ciry o( VJheat Ridge or covenanls, easements or reslrictions of record; that alt measurements shown, and allegations made are accurate; that I have tead and agree to abide by all conditions printed on this appliwtion, and that 1 assume full responsibillity for compliance with the Wheat Ridge Building Code (U.B.C.) and all ofher appliwble Whe Ridge ordin P~ s, for work under this pertnit. (OWNER)(CONTRACTOR) SIGNEO DATE 'fc/ - DescriDtion : 'LYew'zy'I o'1' 3~~/~ ~S. ~ o,~cr1.~G W:~h+•bPr ~~~c1G AJ.or `r L~a✓~Q (7 ' I "lQ, n Approval : Zoning : U]rdMgM~ Approval : Pnmigwa~~ Approval : Occupancy : Walis Electrical License No : Company : Expiration Date : Approval : Use: BUILDING DEPARTMENT USE ONLY Phone : 303 , 23 4. S! 5--7 Phone S5 , ao -qa") S $0.00 SIC : Sq. FL : Roof Plumbing License No : Company: Expiration Date : Approval: Mechanical License No : Company: Expiration Date : Approvai: (1) This permil was lasued In acadance with the piovisions set tonh in yopur avWication and is suCjeci m the laws of the Sute ol CobnCO aiM to the Zoninq Re9ulaUona and BuiWing Code of WTeal RNge, CobnCa w any oNer a001lode adimncea of Vu Giry. (2) Thu permit stull acpire if (A) Ne wofk auVaf+zed'u rrot wmmenceE wXnin sixty (60) Oaya from Issue Eale or (8) Na 6uilEinp auNaizeE is auspended u aOarWOned fw a peAad o( 120 days. (7) If Nis pemrl'xpircs, a new pemut maY De acQulrcd (w a lee ol ono-Aatt Ne amounl namaiy reQuired, povideC no Wnqes luva Deen w will De rtuEe in the original pqm and spedfica6ons aM aM suspension w aEanEOnmenl tus rwt esceeded ona (1) year. If Uan9es are rtuEe or if suspension a aWMOnmenl ezceetli ax (1) y<ar, lull (ees sAall be paW tot a new pemiL (a) No work ol any mann<r snall be Eone Uut wdl change the naturol flow ot wa4r nusinq a dninage pro0km. (5) ConUactw shall no6y the BuilEinp Inspector lwenry-lour (24) twurs in aEvance br ail inspectioiu and snan receive wnnen aDOroval on Inspcctioo mrd befwe proceeCiing wM successive phaxa af the ~b. (b) The iswanra~6(1 pemN a Ma apqnval o(drawinps and specGratipu shall nol Oe caiswcd to De a pefmit for, nor an a00ro'l+l o( arry vldaUon o(1M pravisbna of Ne buil~p ~dCS Of-aOAQhCr polndnCG, law, NI< W rcquWliOn. Chief Building Insp tor For Mayor THIS PERMIT ALID ONLY WHEN SIGNED BY THE CHIEF BUILDING INSPECTOR AND MAYOR CALL: 234-5933 24 HOURS PRIOR TO INSPECTION Stories : . Residential Units : "Please complete both sides of application form with submittal" TERivIS AND CONDITIONS As applicant for a building permit in the City of Wheat Ridge, I do hereby agree to the terms and conditions set forth below for the issuance of a Certificate of Occupancy in connection with this building permit. The issuance of a Certificate of Occupancy requires: L The completion and approval of final inspections and any necessary corrections of electrical, plumbing, mechanical and framing systems. Inspections aze performed by the Building Division. ' 2. The completion of site drainage/grading requirements per the approved site grading plan and/or final drainape report and plan, if such report and plan is applicable. For all residential and nonresidential projects with an approved final drainage report and plan, a letter of ceRification is required from the project's civil engineer of record. Inspections are performed by the Public Works Department. 3. The comp(etion and acceptance by the City of Wheat Ridge of all required public improvements, or a Development Covenant may be processed in lieu of constructing said improvements. The Public Works Department performs these inspections or provides the Development Covenant. 4. The completion of all required landscaping and related site improvements. Inspections aze performed by the Planning and Zoning Division. All thc above itcros must bc completed and sioned off by Planning and Zoning, Building and Public Worl-s before a Ccrtificatc of Occupancy is issucd. Final inspection by the Building Division does not constitute authorization of a Certificate of Occupancy aor permission for occupancy. Occupancy of the structure is not permitted uiltil the Certificate of Occupancy is issucd. The City is not responsible for any real estate closings or other agreements conceming the propeRy which may be affected by failure to complete the above items and obtain a Certificate of Occupancy. The City is undcr no obli ;ation to issuc a Temporary Certifcatc o( Occupancy. I have read, understand, and agree to the foregoing terms and conditions. Name (Please Pcinp) 1"~ °rc,areT f-a Signature: ir~~, - ~ffDate: c~'S-/`r- 9~✓ L-4223 SFIEET 1 OF 2 FLOOD 70NF C MAY 13, 199F3 J /C,P I N-3Rs'bn~ . w G f• - 9 ~ RL r ~ I GUN~.~ ~i4•~~ ~ `~,...-~'"~~/P~_`` ` i 3 e~+~~ ' ~ I\ ( M, ~ 1 _ i g.. ~ I ~r I ,1 ~ `5. 4 d y z ~ y 30'~ r I U v 3~s -s 4S R ~7 tll ,r J a.y \ 6"t ~ Q`•c'f N N J X ? ~ - ~ f I SZCJ J GU ~~..T1J F I I- v ~ 0 N I ~ ~ v=_r~~_ - - - ' S ' t T%4% ~ ~«M2AlT ~Ol- UO ~ ~\/[.~JIJ1.;E\MI~IIIiV i'_' t?&61 E. AMHERS'i DR. #F Denver, Colorado 80231 750-6242 a,o ~'rar° 7 I ~ ~ r 1 N O O d^ V SEE SHEET 2 FOR LEGAL AND CERTIFICATE ~ BJI SURVEYING 8661 E. AMHERST DR. #F Denver, Colorado 80231 750 6242 L4223 MAY 13, 1998 SHEET 2 OF 2 STREET ADDRESS: 3305 3307 TELLER STREET, WHEAT RIDGE, CO. LEGAL DESCRIPTION: LOT 14, CONNELLEE SUBDIVISION COUNTY OF JEFFERSON, STATE OF COLROADO. IMPROVEMENT LOCATION CERTIFICATE: PREPARED FOR MARGARET PARRY I HEREBY CERTIFY THAT THIS IMPROVEMENT LOCATION CERTIFICATE WAS PREPARED BY ME, THAT IT IS NOT AN IMPROVEMENT SURVEY PLAT, AND THAT IT IS NOT TO BE RELIED ON FOR THE ESTABLISHMENT OF FENCE, BUILDING OR OTHER FUTURE IMPROVEMENT LINES. I FURTHER CERTIFY THAT THE IMPROVEMENTS ON THE ABOVE DESCRIBED PARCEL ON THIS DATE, MAY 13, 1998, EXCEPT UTILITY CONNECTIONS, ARE ENTIRELY WITHIN THE BOUDARIES OF THE PARCEL, EXCEPT AS SHOWN, THAT THERE ARE NO ENCROACHMENTS UPON THE DESCRIBED PREMISES BY IMPROVEMENTS ON ANY ADJOINING PREMISES, EXCEPT AS INDICATED, THAT THERE IS NO APPARENT EVIDENCE OR SIGN OF ANY EASEMENT CROSSING OR BURDENING ANY PART OF SAID PARCEL EXCEPT AS NOTED. I ALSO CERTIFY THAT THIS PARCEL IS NOT IN A 100-YEAR FLOOD PLAIN ACCORDING TO FEDERAL INSURANCE RATE MAP COMMUNITY PANEL NO. 085079 0005.