HomeMy WebLinkAbout0028SUBDIVISION IMPROVEMENT AGREEMENT
TH IS AGREEMENT made this Z 3 j2.0 of ~~tAA-P--'1 , 2 o lS by
and between the CITY OF WHEAT RIDGE, COLORADO, a home rule municipal
corporation (the "City"), and William Fritz, (the "Developer"), together referred to as the
"Parties".
REC ITALS:
The Developer is the owner of certain real property located in the City of Wheat
Ridge, which is more particularly described in Exhibit A and made a part hereof (the
"Property"), commonly known as Yukon Grove Subdivision.
On December 8, 2014, the City Council of the City of Wheat Ridge, after holding
all required public hearings, approved the final plat for the Property titled
Yukon Grove Subdivision. A copy of the Final Plat is attached hereto as Exhibit B
and incorporated herein.
The approvals cited above are conti ngent upon the express condition that all
duties created by th is Agreement be faithfully performed by the Developer.
AGREEMENT
NOW, therefore, fo r and in consideration of the mutual promises and covenants
contained herein, the sufficiency of which are mutually acknowledged, the parties hereto
agree as follows:
1. Purpose. The purpose of this Agreement is to set forth the terms,
conditions, and fees to be paid by the Developer upon subdivision of the Property. All
conditions contained herein are in addition to any and all requirements of the City of
Wheat Ridge Subdivision Ordinance and Zoning Ordinance, the City of Wheat Ridge
Charter, any and all state statutes, and any other sections of the City of Wheat Ridge
Municipal Code and are not intended to supersede any requirements contained therein.
2. Other Requirements. Intentionally deleted.
3. Fees. The Developer hereby agrees to pay City Development Review
fees to the City for engineering, hydrological. surveying, legal, and other services
rendered in connection with the review of the subdivision of the Property.
4. Parkland dedication fee-in lieu. Fees in lieu of land dedication in the
amount of $49,945.80 were received on February 18, 2015.
SUBDIVISION IMPROVEMENT AGREEMENT 10/14
1 111M ~lrl llilllilll lilll llilllllilllllllillllilil lillllll ~ ~~~0~0
2015016466
02/23/2015 04:52:40 PM 16 Page(s)
JEFFERSON COUNTY. Colorado
5. Title Policy. Prior to recording of the final plat (or, if no plat is associated
with the development; prior to and as a condition of final approval of the development
by the City), title commitment for all those portions of the Property, as well as any other
interests in real property (easements, etc.) to be reserved for public purposes or
dedicated to the City shall be provided to the City. The title commitment shall show that
all such property is or shall be , subsequent to the execution and recording of this
Agreement. free and clear of all liens and encumbrances (other than real estate taxes
which are not yet due and payable) which would make the dedication or reservation
unacceptable as the City determines in its reasonable discretion. The City, in its sole
discretion, may accept any dedication regardless of encumbrances. The title policy
evidenced by the title commitment shall be provided within thirty (30) days after the
recording of this Agreement, in an amount equal to the fair market value of the property
so dedicated or reserved.
6. Breach by the Developer; the City's Remedies. In the event of a breach of
any of the terms and conditions of this Agreement by the Developer, the City Council
shall be notified immediately and the City may take such action as permitted and/or
authorized by law, this Agreement, or the ordinances and Charter of the City as the City
deems necessary to protect the public health, safety and welfare; to protect lot buyers
and builders; and to protect the citizens of the City from hardship and undue risk.
These remedies include, but are not limited to:
(a) The refusal to issue any building permit or certificate of occupancy;
(b) The revocation of any building permit previously issued under which
construction directly related to such building permit has not commenced,
except a building previously issued to a third party,
(c) A demand that the security given for the completion of the Public
Improvements be paid or honored, or
(d) Any other remedy available at law or in equity.
Unless necessary to protect the immediate health, safety and welfare of the City or to
protect the City's interest with regard to security given for the completion of the Public
Improvements, the City shall provide the Developer thirty (30) days written notice of its
intent to take any action under this paragraph during which thirty day period the
Developer may cure the breach described in the notice.
7. Public Improvements and Warranty. All storm sewer lines, drainage
structures, paved streets, curb, gutter and sidewalk, including the undergrounding of all
overhead utilities. and necessary appurtenances as shown on the subdivision plat and
the associated construction documents (the "Public Improvements" or "Improvements")
as approved by the Director of Public Works or designee of the City, shall be installed
and completed at the expense of the Developer within the timeframes set forth in
Section 10 of this Agreement. The itemized costs of the Public Improvements required
by this Agreement and shown on the construction documents approved by the Director
SUBDlVISION IMPROVEMENT AGREEMENT 10114
2
of Public Works of the City are set forth on Exhibit C. All Public Improvements covered
by this Agreement shall be made in accordance with the construction documents drawn
according to regulations and construction standards for such improvement and
approved by the Director of Public Works of the City. It is understood by the Parties that
the description of the Public Improvements may be general in nature, and that
reasonable modifications of the scope, nature, costs, and similar aspects of the Public
Improvements may be necessary to secure final approval of the Public Improvements.
The quantities and locations for the Public Improvements are based on information that
was available at the time of approval of the Final Plat. Additional Public Improvements
may be required , and Developer shall be responsible for submitting revisions to the
Final Plat approved by the City. The Public Improvements shall be substantially
complete, with only such exceptions as shall be approved in advance by the Director of
Public Works in the exercise of his or her sole discretion, prior to the issuance of the
first Building Permit.
The Developer shall also warrant any and all Public Improvements which are
conveyed to the City pursuant to this Agreement for a period of two (2) years from the
date the City's Director of Public Works certifies that the same conforms to the
specifications approved by the City. Specifically, but not by way of limitation, the
Developer shall warrant the following:
(a) That the title conveyed shall be marketable and its transfer rightful;
(b) Any and all facilities conveyed shall be free from any security interest or
other lien or encumbrance; and
(c) Any and all facilities so conveyed shall be free of defects in materials or
workmanship for a period of two (2) years as stated above.
(d) To the degree the Developer is required to install and maintain
landscaping on public or private property, it is the obligation of Developer
and its successors and assigns, to maintain the required landscaping in
perpetuity.
The City will finally accept for maintenance all Public Improvements, exclusive of
landscaping materials, after the warranty period has expired provided all warranty work
has been completed. The City shall accept for snow removal purposes only, all
dedicated public streets after the City issues the first certificate of occupancy.
8. Installation of Traffic Signal. A traffic signal may be required to serve this
development. Determination of the need for the signal shall be made by the City's
Public Works Director, hereinafter "Director'', prior to building permit issuance and
based upon a traffic study for this development approved by the City. The Developer
shall provide collateral for the estimated cost of installation of the traffic signal prior to
SUBDIVISION IMPROVEMENT AGREEMENT 10/14
3
}
building permit issuance, if the Director has determined that a signal is needed. Prior to
building permit issuance, the Developer shall provide traffic signal plans for approval by L/
the Developer and the Colorado Department of Transportation. 1
The Developer shall notify the City in writing, a minimum of one hundred sixty
(160) days prior to the desired time of installation/modification of the traffic signal in
order to allow the City to coordinate the timing of the traffic signal improvements. If the
Director approves installation of the signal based on meeting traffic warrants, the City
shall then notify the Developer in writing of the exact amount required for the traffic
signal improvements. The Developer shall then make payment to the City in cash for
the required amount within sixty (60) days of receipt of such letter. The City will not
commence traffic signal improvements until the Developer has paid to the City the total
amount determined by the Director to be the total cost of improvements.
9. Observation. Inspection and Testing. The City shall have the right to
require reasonable engineering observations and testing at the Developer's expense.
Observation and testing, acquiescence in, or approval by any engineering inspector of
the construction of physical facilities at any particular time shall not constitute the
approval by the City of any portion of the construction of such Public Improvements.
Such approval shall be made by the City, only after completion of construction and in
the manner hereinafter set forth .
The Director is designated by the City to exercise authority on its behalf under
this Agreement and to see that this Agreement is performed according to its terms.
Work under this Agreement may, without cost or claim against the City, be suspended
by the Director for substantial cause.
The Director shall, within a reasonable time after presentation, make decisions in
writing on all claims of Developer and on all other matters relating to the execution and
progress of the work or the interpretation of this Agreement, the master plan and
specifications. All such decisions of the Director shall be final.
The Director shall make all determinations of amounts and quantities of work
performed hereunder. To assist him in this work Developer shall make available for
inspection any records kept by Developer.
The Director shall make all determinations of amounts and quantities of work
performed hereunder. To assist him in this work Developer shall make available for
inspection any records kept by Developer.
The Director and his authorized representatives shall have free access to the
work at all times, and Developer shall furnish them with facilities for ascertaining
whether the work being performed, or the work which has been completed, is in
accordance with the requirements of the Agreement.
SUBDIVISION IMPROVEMENT AGREEMENT 10/14
4
The Director will make periodic observations of construction (sometimes
commonly referred to as "supervision"). The purpose of these observations and
construction checking is to determine the progress of the work and to see if the work is
being performed in accordance with the plans and specifications. He will in no way be
responsible for how the work is performed, safety in, on, or about the job site, methods
of performance, or timeliness in the performance of the work.
Inspectors may be appointed to inspect materials used and work done.
Inspections may extend to all or any part of the work and to the preparation or
manufacture of the materials to be used. The inspectors will not be authorized to alter
the provisions of this Agreement or any specifications or to act as foreman for
Developer. The Inspector will have authority to reject defective materials and to
suspend any work that is being done improperly, subject to the final decision of the
Director.
10. Completion of Public Improvements. The obligations of the Developer
provided for in paragraph 6 of this Agreement, including the inspections hereof, shall be
performed on or before f) 2-Ira I 2.. 0 I" ' and
proper application for acceptance of the~Public Improvements shall be made on or
before such date. Upon completion of construction by the Developer of such
Improvements, the City's Director of Public Works or designee, shall inspect the
Improvements and certify with specificity its conformity or lack thereof to the City's
specifications. The Developer shall make all corrections necessary to bring the
Improvements into conformity with the City's specifications. Once approved by the
City's Director of Public Works, the City shall accept said Improvements upon
conveyance; provided, however, the City shall not be obligated to accept the Public
Improvements until the actual costs described in this Agreement are paid in full by the
Developer.
11 . Protection. Developer, at its expense, shall continuously maintain
adequate protection of all Improvements from damage prior to acceptance by the City
and shall protect the City's property from injury and loss arising in connection with this
Agreement. Developer shall make good any such damage, injury or loss except such
as may be caused directly by authorized agents or employees of the City. Developer
shall adequately protect adjacent property and shall provide and maintain all
passageways, guard fences, lights and other facilities for protection required by public
authority or local conditions.
Developer shall be responsible for damage to any public and private property on
and adjacent to the site of Developer's Improvements caused by negligent or willful acts
of Developer, its agents or subcontractors. Developer shall take all reasonable effort
necessary to prevent damage to pipes, conduits, and other underground structures and
to overhead wires, and to water quality. Developer shall protect carefully from
SUBDIVISION IMPROVEMENT AGREEMENT 10/14
5
disturbance or damage all land monuments and property marks until an authorized
agent of the City has witnessed or otherwise referenced their location, and shall not
remove them until directed. When any direct or indirect damage or injury is done to
public or private property by or on account of any act, omission. neglect or misconduct
in the construction of Improvements, or in consequence of the non-execution thereof on
his part, such damaged property shall be restored by Developer at its own expense to a
condition similar or equal to that existing before such damage or injury.
Developer shall at all times, whether or not so specifically directed by the
Director, take necessary precautions to insure the protection of the public. Developer
shall furnish, erect and maintain, at its own expense. all necessary barricades, suitable
and sufficient red lights, construction signs, provide a sufficient number of watchmen,
and take all necessary precautions for the protection of the work and safety of the public
through or around his construction operations as Developer and the Director shall deem
reasonably necessary.
12. Related Costs -Public Improvements. The Developer shall provide all
necessary engineering designs, surveys, field surveys, testing and incidental services
related to the construction of the Public Improvements at its sole cost and expense,
including final drainage study letter certified accurate by a professional engineer
registered in the State of Colorado.
13. Improvements to be the Property of the City. All Public Improvements for
roads, concrete curb and gutters, public storm sewers and public drainage
improvements accepted by the City shall be dedicated to the City and warranted for a
period of twenty-four (24) months following acceptance by the City, as provided above.
14. Performance Guarantee. In order to secure the construction and
installation of the Public Improvements the Developer shall, prior to record ing the Final
Plat, if applicable, in the real estate records of Jefferson County, which recording shall
occur no later than ninety (90) days after the execution of this Agreement, furnish the
City, at the Developer's expense, with the Performance Guarantee described herein.
The Performance Guarantee provided by the Developer shall be an irrevocable letter of
credit in which the City is designated as beneficiary, for one hundred twenty-five percent
(125%) of the estimated costs of the Public Improvements to be constructed and
installed as set forth in Exhibit C, if applicable to secure the performance and
completion of the Public Improvements as required by Section 26-418 Security for
Required Improvements, of the Wheat Ridge Subdivision Regulations. The Developer
agrees that approval of this Agreement by the City is contingent upon the Developer's
provision of an irrevocable letter of credit to the City within ninety (90) days of the
execution of this Agreement in the amount and form provided herein. Failure of the
Developer to provide an irrevocable letter of credit to the City in the manner provided
herein shall negate the City's approval of this Agreement. Letters of credit shall be
substantially in the form and content set forth in Exhibit D, if applicable, and shall be
SUBDIVlSION IMPROVEMENT AGREEMENT 10/14
6
subject to the review and approval of the City Attorney. The Developer shall not start
any construction of any public or private improvement on the Property including, but not 1
limited to. staking, earthwork, overlot grading or the erection of any structure, temporary
or otherwise, until the City has received and approved the irrevocable letter of credit.
The estimated costs of the Public Improvements shall be a figure mutually
agreed upon by the Developer and the City's Director of Public Works, as set forth in
Exhibit C if applicable. If, however, they are unable to agree, the Director of Public
Works' estimate shall govern after giving consideration to information provided by the
Developer including, but not limited to, construction contracts and engineering
estimates. The purpose of the cost estimate is solely to determine the amount of
security. No representations are made as to the accuracy of these estimates, and the
Developer agrees to pay the actual costs of all such Public Improvements.
The estimated costs of the Public Improvements may increase in the future.
Accordingly, the City reserves the right to review and adjust the cost estimate on an
annual basis. If the City adjusts the cost estimate for the Public Improvements, the City
shall give written notice to the Developer. The Developer shall, within thirty (30) days
after receipt of said written notice, provide the City with a new or amended letter of
credit in the amount of the adjusted cost estimates. If the Developer refuses or fails to
so provide the City with a new or amended letter of credit, the City may exercise the
remedies provided for in this Agreement; provided, however, that prior to increasing the
amount of additional security required, the City shall give credit to the Developer for all
required Public Improvements which have actually been completed so that the amount
of security required at all time shall relate to the cost of required Public Improvements
not yet constructed.
In the event the Public Improvements are not constructed or completed within the
period of time specified by paragraph 9 of this Agreement or a written extension of time
mutually agreed upon by the parties to this Agreement, the City may draw on the letter
of credit to complete the Public Improvements called for in this Agreement. In the event
the letter of credit is to expire within fourteen (14) calendar days and the Developer has
not yet provided a satisfactory replacement, the City may draw on the letter of credit and
either hold such funds as security for performance of this Agreement or spend such
funds to finish Public Improvements or correct problems with the Public Improvements
as the City deems appropriate.
Upon completion of performance of such improvements, conditions and
requirements within the required time, the Developer shall issue an irrevocable letter of
credit to the City in the amount of twenty-five percent (25%) of the total cost of
construction and installation of the Public Improvements, to be held by the City during
the warranty period. If the Public Improvements are not completed within the required
time, the monies may be used to complete the improvements.
SUBDIVISION IMPROVEMENT AGREEMENT 10/14
7
15. Indemnification. The Developer shall indemnify and hold harmless the
City and its officers, employees, agents or servants from any and all suits, actions, and
claims of every nature and description caused by, arising from or on account of this
Agreement any act or omission of the Developer, or of any other person or entity for
whose act or omission the Developer is liable, with respect to the Public Improvements;
and the Developer shall pay any and all judgments rendered against the City as a result
of any suit, action, or claim, together with all reasonable expenses and attorney's fees
and costs incurred by the City in defending any such suit, action or claim.
The Developer shall pay all property taxes on the Property dedicated to the City
and shall indemnify and hold harmless the City for any property tax liability.
16. Waiver of Defects. In executing this Agreement, the Developer waives all
objections it may have concerning defects, if any, in the formalities whereby it is
executed , or concerning the power of the City to impose conditions on the Developer as
set forth herein, and concerning the procedure, substance, and form of the ordinances
or resolutions adopting this Agreement.
17. Third Party Beneficiaries. There are and shall be no third party
beneficiaries to this Agreement.
18. Modifications. This instrument embodies the whole agreement of the
Parties. There are no promises, terms, conditions, or obligations other than those
contained herein; and this Agreement shall supersede all previous communications,
representations, or agreements, either verbal or written , between the parties. There
shall be no modification of this Agreement except in writing , executed with the same
formalities as this instrument. Subject to the conditions precedent herein, this
Agreement may be enforced in any court of competent jurisdiction.
19. Release of Liability. It is expressly understood that the City cannot be
legally bound by the representations of any of its agents or their designees except in
accordance with the City of Wheat Ridge Code of Ordinances and the laws of the State
of Colorado.
20. Captions. The captions to this Agreement are inserted only for the
purpose of convenient reference and in no way define, limit, or prescribe the scope or
intent of this Agreement or any part thereof.
21 . Binding Effect. This Agreement shall be binding upon and inure to the
benefit of the parties hereto and their respective heirs, successors, and assigns as the
case may be.
22. No Waiver. No waiver of any of the provisions of this Agreement shall be
deemed or constitute a waiver of any other provisions herein, nor shall such waiver
SUBDIVISION IMPROVEMENT AGREEMENT 10/14
8
constitute a continuing waiver unless otherwise expressly provided, nor shall the waiver
of any default hereunder be deemed a waiver of any subsequent default hereunder.
23. Invalid Provision. If any provision of this Agreement shall be determined
to be void by any court of competent jurisdiction, then such determination shall not
affect any other provision hereof, all of the other provisions shall remain in full force and
effect. It is the intention of the Parties that if any provision of this Agreement is capable
of two constructions, one of which would render the provision void , and the other which
would render the provision valid, then the provision shall have the meaning which
renders it valid.
24. Governing Law. The laws of the State of Colorado shall govern the
validity, performance and enforcement of this Agreement. Should either party institute
legal suit or action for enforcement of any obligation contained herein, venue of such
suit or action shall be in Jefferson County, Colorado.
25. Attorneys Fees. Should this Agreement become the subject of litigation to
resolve a claim of default of performance or payment by the Developer and a court of
competent jurisdiction finds in favor of the City, the Developer shall pay the City's
attorney's fees and court costs.
26. Notice. All notices required under this Agreement shall be in writing and
shall be hand delivered or sent by registered or certified mail, retum receipt requested ,
postage prepaid , to the addresses of the parties herein set forth. All notices so given
shall be considered effective seventy-two (72) hours after deposit in the United States
mail with the proper address as set forth below. Either party by notice so given may
change the address to which future notices shall be sent.
Notice to Developer:
Notice to City: Scott Brink
Director of Public Works
7500 West 29th Avenue
Wheat Ridge, CO 80033
27. Force Majeure. Whenever the Developer is required to complete the
construction, repair, or replacement of Public Improvements by an agreed deadline, the
Developer shall be entitled to an extension of time equal to a delay in completing the
SU8DIVISION IMPROVEMENT AGREEMENT 10/14
9
foregoing due to unforeseeable causes beyond the control and without the fault or
negligence of the Developer including, but not restricted to, acts of God, weather, fires /0
and strikes.
28. Assignment or Assignments. There shall be no transfer or assignment of
any of the rights or obligations of the Developer under this Agreement without the prior
written approval of the City.
29. Recording of Agreement. This Agreement shall be recorded in the real
estate records of Jefferson County and shall be a covenant running with the Property in
order to put prospective purchases or other interested parties on notice as to the terms
and provisions hereof.
30 . Title and Authority. The Developer, William Fritz for Yukon Grove, LLC,
expressly warrants and represents to the City that it is the record owner of the property
constituting the Property and further represents and warrants, together with the
undersigned individual(s) that the undersigned individual(s) has or have full power and
authority to enter into this Subdivision Improvement Agreement. The Developer and the
undersigned individual(s) understand that the City is relying on such representations
and warranties in entering into this Agreement.
WHEREFORE, the parties hereto have executed this Agreement on the day and
year first above written.
CITY OF WHEAT RIDGE, COLORADO
By:
ATIEST:
Joyce Jjt. Ma/Pf / v
SUBDIVISION IMPROVEMENT AGREEMENT 10/14
10
GeraidDahi, CitYttQmey
DEVELOPER
STATE OF COLORADO
COUNTY OF \_)e-f-\e_,v 'SLrV\
)
)
)
SS.
The foregoing instrument was acknowledged before me this __lK_ day of
_1fi..X..:L..\?J;...XVUA~II\J\'4--' 20 _1$... by ~h l \ liMY\ fu f:z_ , as \ _\Vti,..II....Lo<.·-\~"'~o...&,.'ou..r....L.v ____ of ~tdkeo &vr 1'-L LLL-
(SEAL )
Witness my hand and official seal.
My commission expires: __ 0_7_/J_q_/_J.rJ_I_7..:......_ ______ _
KIM WAGGONER
NOTAAY PUBLIC
STATE OF COLORADO
Notary 10 20134045648
My Comrnls81on Exptm 07/1912017
11
SUBDIVISION IMPROVEMENT AGREEMENT 10/14
1(
EXHIBIT A
LEGAL DESCRIPTION
A PARCEL OF LAND LOCATED IN THE NORTHWEST QUARTER OF SECTION 26,
TOWNSHIP 3 SOUTH, RANGE 69 WEST, OF THE 6TH PRINCIPAL MERIDIAN, CITY
OF WHEAT RIDGE, COUNTY OF JEFFERSON, STATE OF COLORADO AS
DESCRIBED IN THE DOCUMENTS RECORDED AT RECEPTION NO. F2156985
(DEED) AND RECEPTION NO. 2015005269 (BOUNDARY AGREEMENT) IN THE
OFFICIAL RECORDS OF SAID COUNTY OF JEFFERSON, AND BEING MORE
PARTICULARLY DESCRIBED AS FOLLOWS:
COMMENCING AT THE CENTER QUARTER CORNER OF SAID SECTION 26,
THENCE S89°45'02'W, 423.03 FEET ALONG THE SOUTHERLY LINE OF SAID
NORTHWEST QUARTER OF SECTION 26; THENCE DEPARTING SAID SECTION
LINE N00°14'58'W, 25.00 FEET TO THE NORTHERLY RIGHT-OF-WAY LINE OF
32ND AVENUE, AND THE POINT OF BEGINNING; THENCE S89°45'02'W, 111 .41
FEET ALONG SAID NORTHERLY RIGHT-OF-WAY LINE; THENCE DEPARTING SAID
NORTHERLY RIGHT-OF-WAY LINE N00°19'27'W, 10.00' TO A POINT ON THE
EASTERLY LINE OF RIDGEVIEW ESTATES SUBDIVISION; THENCE ALONG THE
EASTERLY LINE OF SAID RIDGEVIEW ESTATES SUBDIVISION N00°19'27'W,
360.00 FEET; THENCE CONTINUING ALONG SAID EASTERLY LINE N89°45'02"E,
106.41 FEET; THENCE N00°19'27'W, 469.71 FEET; THENCE S53°44'06"E, 285.21
FEET; THENCE S00°19'27"E, 300.00 FEET; THENCE N89°45'02"E, 184.00 FEET TO
THE WESTERLY RIGHT-OF-WAY LINE OF WADSWORTH BOULEVARD; THENCE
S00°19'27"E, 60.00 FEET ALONG SAID RIGHT-OF-WAY LINE; THENCE DEPARTING
SAID RIGHT-OF-WAY LINE S89°45'02'W, 408.00 FEET; THENCE S00°19'27"E,
310.00 FEET TO THE NORTHERLY RIGHT-OF-WAY LINE OF 32ND AVENUE AND
THE POINT OF BEGINNING. SAID PARCEL CONTAINS 153,832 SF (3.5315 ACRES)
MORE OR LESS.
BASIS OF BEARINGS: BEARINGS ARE BASED ON THE SOUTHERLY LINE OF THE
NORTHWEST QUARTER OF SECTION 26, TOWNSHIP 3 SOUTH, RANGE 69 WEST
OF THE SIXTH PRINCIPAL MERIDIAN BEARING N89°45'02"E BETWEEN THE WEST
QUARTER CORNER BEING A FOUND 3 Y." ALUMINUM CAP PLS # 132121N RANGE
BOX AND THE CENTER QUARTER CORNER BEING A FOUND 3 Y." ALUMINUM
CAP PLS # 132121N RANGE BOX.
FEBRUARY 10, 2015
~
EXHIBIT B
YUKON GROVE SUBDIVISION, FILING NO. 1
A PARCEL OF LAND LOCATED IN THE NW 1/4 OF SECTION 26 T 3S R 69W OF THE 6TH PM
CllY OFWHEAT RIDGE. COUNlY OF JEFFERSON, STATE OF COLORADO
-·
,
/
SHEET 01 OF 03
. .,.."" , I
~ ' __ .....
I e n ··'"--~ i ~ ~ f'),.....-r APPROX SlfF:lOC:AtlO'j
~
"" ,... &n.O..... .\
• . l
,. ~ .l ... •
~!"···~--····r.....-------·--------···
{.
.J'
~ -
. ,,
..
YUKON GROVE SUBDIVISION, FILING NO. 1
A PARCEL OF LAND LOCATED IN THE NW 1/4 OF SECTION 26. T 3S R 69W OF THE 6TH PM
CITY OFV'MEAT RIDGE COUNTY OF JEFFERSON. STATE OF COLORADO
r ·',
SHEET 02 OF 03
<1-
' I I
Co ,-
/t
--N-io=-
..,
_.,
~-··-__ ... .,_ , .... -----··-------·---·· -·····-·--···--
\.n
YUKON GROVE SUBDIVISION, FILING NO. 1
A PARCEL OF LAND LOCATED IN THE NW 1/4 OF SECTION 26. T 3S R 69W OF THE 6TH PM
CITY OFWHEAT RIDGE COUNTY OF JEFFERSON. STATE OF COLORADO
SHEET 03 OF 03
~-...... .,-----·--------·----··
CITY OF 'MiEAT RIDGE
PUBUCWORKS
DATE 01/2212015
RECEIVED 01/2212015
EXHIBIT C CITY OF WHEAT RIDGE
PUBLIC WORKS. ENGINEERING
APPROVED FOR:
2nd Submittal YUKON GROVE SUBDMSION ODRAINAGE O SIDEWN.J(
I
I
I
MARTIN I MARTIN
Client: YUKON GROVE, LLC ·BILL FRITZ
No.. Arri .,._,.of pnco pr-~ pr~ C<»>l 0t COI'lll\letoon to sis renclere4 by MARn~ MARnN
fep,-e<~ef'!l ... be:l\ ~ •nd art futf'IISI'ted tor 9ltMf'8 QUIOatKe MA.Rl'IN1MARTIN ,. ..... no
,....,.yolptlf\tH t•llttt""t•M<I 0t-0010 h accncyol -.n .,._,. U ....,.,_.,
10 t>d Ot-COli
lttmNo lltm Dncrlptlon
SITE CLEARING
I CltAAING AND GRUBBlNG
2 POTHOLING
EROSION CONTROL
3 SILT FENCE
4 CONCRETE WASHOUT STRUCTURE
5 VEHICLE rRACI<ING CONTROL
6 STABILIZED STAGING AREA
7 INLET PROTECTION
8 TEMPORARY SEEDING
9 SEDIMENT CONTROL LOG
10 SVRFACE ROUGHENING
II ROCK SOCKS
12 OUTLET PROTECTION
EARTHWORK
13 SITE GRADING
FRONTAGE IMPROVEMENTS
14 ASPHAlT
15 CURB ~ GUTTER
16 SIDEWAlK
17 CURB RAMPS
ROAD IMPROVEMENTS
18 ASPHALT
19 AGGREGATE BASE COURSE
20 CURB~ GUTTER
21 SIDEWALK
STORM SEWER
22 \2 INCH RCP CLASS Ill
23 15 INCH PVC (To Roc:J<y Min 01teh)
24 18 INCH RCP CLASS Ill
26 STORM SEWER MANHOLE
26 WHEAT RIDGE SINGLE COMBINATION INLET
27 WHEAT RIDGE TRIPLE COMBINATION INLET
28 OUTLET STRUCTURE
29 CONNECT TO EX 32NO STORM INLET
30 CONCRETE TRICKLE CHANNEL
31 24" NYLOPLAST INLET
32 CAST-IN-PLACE CONCRETE WAll
SANITARY MAIN
33 8-IN PVC SEWER PIPE
34 4·FT DIA SSMH
35 CONNECT TO 32NO AVE SEWER
36 4-PVC SEWER SERVICE
MISC CONSTRUCTION ITEMS
37 CONSTRUCTION SURVEY STAKING
38 MOBILIZATION
39 TEMP CONSTRUCTION FENCING
Rtmart<•'
""'Cl.ate 1·'22/'20'5 11 06AM
Units
LS
LS
LF
EA
EA
EA
EA
LS
LF
SY
EA
SY
LS
TN
LF
SY
EA
TN
TN
LF
SY
LF
LF
LF
EA
EA
EA
EA
EA
LF
EA
SF
LF
EA
EA
LF
LS
LS
LF
0 CURB & GUTTER OSTRfET
JZI MISCELLANEOUS 0 PLAT
COMMENT -.. tnao-•C001ht-
Date: 22-Jen-15
Job No.: 13 0606
Prep. By: MAT CAM
Ckd. By: MDT
.t.2 . .t44c
CML ENGINEER • ...... 011Jl/J01f
~T£
SUBJECT TO FIELD INSP£CTIOHS
Quantity Unit Price Item Cost
I s 10.00000 $ 10.00000
I s 80000 $ 80000
1515 s 400 s 6,06000
I s 1 50000 $ 1,500 00
I s 2 200 00 s 2.200 00
I s HOOOO s 4,50000
8 s 16500 $ 1.320 00
I $ 3.00000 $ 300000
950 $ 200 $ 190000
1250 s 200 s 2.500 00
21 $ 1500 $ 31500
10 s 6000 s 60000
\ $ 7.500 00 s 7500 00
24 s 95 00 $ 2,280 00
54 $ 3000 s 1.620 00
30 s 4500 s 1,350 00
2 $ 1 000 00 s 2.00000
690 $ 9500 $ 65.55000
988 s 2000 $ 19.76000
1722 s 3000 $ 51.66000
781 s 4500 $ 35.14500
39 s 6500 $ 2,535 00
61 s 6500 s 3,965.00
259 $ 75.00 s 19,425 00
2 $ 4.000 00 $ 8000.00
2 s 3,000 00 $ 8,000.00
2 s 600000 s 12.000 00
2 s 10.000 00 $ 2000000
I $ 5.00000 s 5.00000
69 s 4500 s 3.10500
I s I 50000 s 1.50000
1599 s 4000 $ 63.96000
784 $ 6000 s 47 040.00
5 s 4.00000 $ 20.00000
1 s I 000.00 $ 1,000.00
668 $ 2000 s 13,360 00
I $ 25.00000 s 25,000.00
I $ 5.000.00 s 5,00000
250 $ 1000 s 2.50000
Cost of Items: s 480.95000
25"!. City Contlnoencv S 12023700
Total Cost: $ 601,187.00
Page 1 or 1