Loading...
HomeMy WebLinkAbout0014 RECEPTIOti tiO. '~M'd4~~~3 PG: 001-015 11/18/2002 . '00 DOC FFE: 0.00 PAGE FEE: N r7E&FF"I=RSON t08NTY, COLORADO RECORDED I - - . "'-._~ SUBDIVISION IMPROVEMENT AGREEMENT THIS AGREEMENT made this 31 st day of October 2002, by and between the CITY OF WHEAT RIDGE, COLORADO, a home rule municipal corporation (the "City"), and Crosswire Investments, LLC, (the "Developer"), together referred to as the "Parties" RECITALS. \\ " ~\ \ The Developer is the owner of certain real property located in the City of Wheat Ridge, which is more particularly described in Exhibit A, if applicable, and made a part hereof (the "Property"), commonly known as / ... ;1> On AUQust 12. 2002, the City Council of the City of Wheat Ridge, after holding all required public hearings, approved the final plat for the Property titled Perrin's Row Subdivision A copy of the Final Plat is attached hereto as Exhibit B and incorporated herein The approvals cited above are contingent upon the express condition that all duties created by this Agreement be faithfully performed by the Developer AGREEMENT NOW, therefore, for and in consideration of the mutual promises and covenants contained herein, the sufficiency of which are mutually acknowledged, the parties hereto agree as follows 1 Purpose The purpose of this Agreement is to set forth the terms, conditions, and fees to be paid by the Developer upon subdivision of the Property All conditions contained herein are in addition to any and all requirements of the City of Wheat Ridge Subdivision Ordinance and Zoning Ordinance, the City of Wheat Ridge Charter, any and all state statutes, and any other sections of the City of Wheat Ridge Municipal Code and are not intended to supersede any requirements contained therein 2 Other Requirements NONE 3 Fees The Developer hereby agrees to pay City Development Review fees to the City for engineering, hydrological, surveying, legal, and other services rendered in connection with the review of the subdivision of the Property 4 Title Policy A title commitment for the Property shall be provided to the City The title commitment shall show that all property to be dedicated to the City is or shall be, subsequent to the execution and recording of this Agreement, free and clear of all liens and encumbrances (other than real estate taxes which are not yet due and payable) The City, in its sole discretion, may accept any dedication regardless of encumbrances The title policy evidenced by the title commitment shall be provided thirty (30) days after the recording of this Agreement. SUBDIVISION IMPROVEMENT AGREEMENT 5101 " I LI i f ./ t) 5 Breach by the Developer; the City's Remedies In the event of a breach of any of the terms and conditions of this Agreement by the Developer, the City Council shall be notified immediately and the City may take such action as permitted and/or authorized v by law, this Agreement, or the ordinances and Charter of the City as the City deems necessary to protect the public health, safety and welfare, to protect lot buyers and builders, and to protect the citizens of the City from hardship and undue risk. These remedies include, but are not limited to (a) The refusal to issue any building permit or certificate of occupancy; (b) The revocation of any building permit previously issued under which construction directly related to such building permit has not commenced, except a building previously issued to a third party, (c) A demand that the security given for the completion of the Public Improvements be paid or honored, or (d) Any other remedy available at law or in equity Unless necessary to protect the immediate health, safety and welfare of the City or to protect the City's interest with regard to security given for the completion of the Public Improvements, the City shall provide the Developer thirty (30) days written notice of its intent to take any action under this paragraph during which thirty day period the Developer may cure the breach described in the notice 6 Public Improvements and Warranty All storm sewer lines, drainage structures, paved streets, including curb, gutter and sidewalk, and necessary appurtenances as shown on the subdivision plat and the associated construction documents (the "Public Improvements" or "Improvements") as approved by the Director of Public Works or designee of the City, shall be installed and completed at the expense of the Developer within the time frames set forth on Exhibit C The Public Improvements required by this Agreement and shown on the construction documents approved by the Director of Public Works of the City, the time frames for construction of the Improvements and the itemized costs of these Improvements are set forth on Exhibit C if applicable All Public Improvements covered by this Agreement shall be made in accordance with the construction documents drawn according to regulations and construction standards for such improvement and approved by the Director of Public Works of the City It is understood by the Parties that the description of the Public Improvements may be general in nature, and that reasonable modifications of the scope, nature, costs, and similar aspects of the Public Improvements may be necessary to secure final approval of the Public Improvements The quantities and locations forthe Public Improvements are based on information that was available at the time of approval of the Final Plat. Additional Public Improvements may be required, and Developer shall be responsible for submitting revisions to the Final Plat approved by the City The Developer shall warrant any and all Public Improvements which are conveyed to the City pursuant to this Agreement for a period of two (2) years from the date the City's Director of Public Works certifies that the same conform with specifications approved by the City Specifically, but not by way of limitation, the Developer shall warrant the following SUBDIVISION IMPROVEMENT AGREEMENT 05101 -2- (a) That the title conveyed shall be marketable and its transfer rightful, (b) Any and all facilities conveyed shall be free from any security interest or other lien or encumbrance, and (c) Any and all facilities so conveyed shall be free of defects in materials or workmanship for a period of two (2) years as stated above (d) To the degree the Developer is required to install and maintain landscaping on public or private property, it is the obligation of Developer to maintain the required landscaping for two (2) growing season(s) The City will finally accept for maintenance all Public Improvements after the warranty period has expired provided all warranty work has been completed The City shall accept for snow removal purposes only, all dedicated public streets after the City issues the first certificate of occupancy 7 Installation of Traffic Siqnal A traffic signal may be required to serve this development. Determination of the need for the signal shall be made by the City's Public Works Director, hereinafter "Director", prior to building permit issuance and based upon a traffic study for this development approved by the City The Developer shall provide collateral for the estimated cost of installation of the traffic signal prior to building permit issuance, if the Director has determined that a signal is needed Prior to building permit issuance, the Developer shall provide traffic signal plans for approval by the Developer and the Colorado Department of Transportation The Developer shall notify the City in writing, a minimum of one hundred sixty (160) days prior to the desired time of installation/modification of the traffic signal in order to allow the City to coordinate the timing of the traffic signal improvements If the Director approves installation of the signal based on meeting traffic warrants, the City shall then notify the Developer in writing of the exact amount required for the traffic signal improvements The Developer shall then make payment to the City in cash for the required amount within sixty (60) days of receipt of such letter The City will not commence traffic signal improvements until the Developer has paid to the City the total amount determined by the Director to be the total cost of improvements 8 Observation, Inspection and Testinq The City shall have the right to require reasonable engineering observations and testing atthe Developer's expense Observation and testing, acquiescence in, or approval by any engineering inspector of the construction of physical facilities at any particular time shall not constitute the approval by the City of any portion of the construction of such Public Improvements Such approval shall be made by the City, only after completion of construction and in the manner hereinafter set forth The Director is designated by the City to exercise authority on its behalf under this Agreement and to see that this Agreement is performed according to its terms Work under this Agreement may, without cost or claim against the City, be suspended by the Director for substantial cause SUBDIVISION IMPROVEMENT AGREEMENT 05101 --'- The Director shall, within a reasonable time after presentation, make decisions in writing on all claims of Developer and on all other matters relating to the execution and progress of the work or the interpretation of this Agreement, the master plan and specifications All such decisions of the Director shall be final The Director shall make all determinations of amounts and quantities of work performed hereunder To assist him in this work Developer shall make available for inspection any records kept by Developer The Director shall make all determinations of amounts and quantities of work performed hereunder To assist him in this work Developer shall make available for inspection any records kept by Developer The Director and his authorized representatives shall have free access to the work at all times, and Developer shall furnish them with facilities for ascertaining whether the work being performed, or the work which has been completed, is in accordance with the requirements of the Agreement. The Director will make periodic observations of construction (sometimes commonly referred to as "supervision") The purpose of these observations and construction checking is to determine the progress of the work and to see if the work is being performed in accordance with the plans and specifications He will in no way be responsible for how the work is performed, safety in, on, or about the job site, methods of performance, or timeliness in the performance of the work. Inspectors may be appointed to inspect materials used and work done Inspections may extend to all or any part of the work and to the preparation or manufacture of the materials to be used The inspectors will not be authorized to alter the provisions of this Agreement or any specifications or to act as foreman for Developer The Inspector will have authority to reject defective materials and to suspend any work that is being done improperly, subject to the final decision of the Director 9 Completion of Public Improvements The obligations of the Developer provided for in paragraph 6 of this Agreement, including the inspections hereof, shall be performed on or before October 31, 2003, and proper application for acceptance of the Public Improvements shall be made on or before such date Upon completion of construction by the Developer of such Improvements, the City's Director of Public Works or designee, shall inspect the Improvements and certify with specificity its conformity or lack thereof to the City's specifications The Developer shall make all corrections necessary to bring the Improvements into conformity with the City's specifications Once approved by the City's Director of Public Works, the City shall accept said Improvements upon conveyance, provided, however, the City shall not be obligated to accept the Public Improvements until the actual costs described in this Agreement are paid in full by the Developer 10 Protection Developer, at its expense, shall continuously maintain adequate protection of all Improvements from damage prior to acceptance by the City and shall SUBDIVISION IMPROVEMENT AGREEMENT 05101 -4- protect the City's property from injury and loss arising in connection with this Agreement. Developer shall make good any such damage, injury or loss except such as may be caused directly by authorized agents or employees of the City Developer shall adequately protect adjacent property and shall provide and maintain all passageways, guard fences, lights and other facilities for protection required by public authority or local conditions Developer shall be responsible for damage to any public and private property on and adjacent to the site of Developer's Improvements caused by negligent or willful acts of Developer, its agents or subcontractors Developer shall take all reasonable effort necessary to prevent damage to pipes, conduits, and other underground structures and to overhead wires, and to water quality Developer shall protect carefully from disturbance or damage all land monuments and property marks until an authorized agent of the City has witnessed or otherwise referenced their location, and shall not remove them until directed When any direct or indirect damage or injury is done to public or private property by or on account of any act, omission, neglect or misconduct in the construction of Improvements, or in consequence of the non-execution thereof on his part, such damaged property shall be restored by Developer at its own expense to a condition similar or equal to that existing before such damage or injury Developer shall at all times, whether or not so specifically directed by the Director, take necessary precautions to insure the protection of the public Developer shall furnish, erect and maintain, at its own expense, all necessary barricades, suitable and sufficient red lights, construction signs, provide a sufficient number of watchmen, and take all necessary precautions for the protection of the work and safety of the public through or around his construction operations as Developer and the Director shall deem reasonably necessary 11 Related Costs - Public Improvements The Developer shall provide all necessary engineering designs, surveys, field surveys, testing and incidental services related to the construction of the Public Improvements at its sole cost and expense, including final drainage study letter certified accurate by a professional engineer registered in the State of Colorado 12 Improvements to be the Property of the City All Public Improvements for roads, concrete curb and gutters, public storm sewers and public drainage improvements accepted by the City shall be dedicated to the City and warranted for a period of twenty- four (24) months following acceptance by the City, as provided above 13 Performance Guarantee In orderto secure the construction and installation of the Public Improvements the Developer shall, prior to recording the Final Plat, if applicable, in the real estate records of Jefferson County, which recording shall occur no later than ninety (90) days after the execution of this Agreement, furnish the City, at the Developer's expense, with the Performance Guarantee described herein The Performance Guarantee provided by the Developer shall be an irrevocable letter of credit in which the City is designated as beneficiary, for one hundred twenty-five percent (125%) of the estimated costs of the Public Improvements to be constructed and installed as set forth in Exhibit C, if applicable, to secure the performance and completion of the Public SUBDIVISION IMPROVEMENT AGREEMENT 05101 -5- Improvements as required by Section 26-413 of the Wheat Ridge Subdivision Regulations The Developer agrees that approval of this Agreement by the City is contingent upon the Developer's provision of an irrevocable letter of credit to the City within ninety (90) days of the execution of this Agreement in the amount and form provided herein Failure of the Developer to provide an irrevocable letter of credit to the City in the manner provided herein shall negate the City's approval of this Agreement. Letters of credit shall be substantially in the form and content set forth in Exhibit D, if applicable, and shall be subject to the review and approval of the City Attorney The Developer shall not start any construction of any public or private improvement on the Property including, but not limited to, staking, earth work, overlot grading or the erection of any structure, temporary or otherwise, until the City has received and approved the irrevocable letter of credit. ; , The estimated costs of the Public Improvements shall be a figure mutually agreed upon by the Developer and the City's Director of Public Works, as set forth in Exhibit C if applicable If, however, they are unable to agree, the Director of Public Works' estimate shall govern after giving consideration to information provided by the Developer including, but not limited to, construction contracts and engineering estimates The purpose of the cost estimate is solely to determine the amount of security No representations are made as to the accuracy of these estimates, and the Developer agrees to pay the actual costs of all such Public Improvements The estimated costs of the Public Improvements may increase in the future Accordingly, the City reserves the right to review and adjust the cost estimate on an annual basis If the City adjusts the cost estimate for the Public Improvements, the City shall give written notice to the Developer The Developer shall, within thirty (30) days after receipt of said written notice, provide the City with a new or amended letter of credit in the amount of the adjusted cost estimates If the Developer refuses or fails to so provide the City with a new or amended letter of credit, the City may exercise the remedies provided for in this Agreement; provided, however, that prior to increasing the amount of additional security required, the City shall give credit to the Developer for all required Public Improvements which have actually been completed so that the amount of security required at all time shall relate to the cost of required Public Improvements not yet constructed In the event the Public Improvements are not constructed or completed within the period of time specified by paragraph 9 of this Agreement or a written extension of time mutually agreed upon the parties to this Agreement, the City may draw on the letter of credit to complete the Public Improvements called for in this Agreement. In the event the letter of credit is to expire within fourteen (14) calendar days and the Developer has not yet provided a satisfactory replacement, the City may draw on the letter of credit and either hold such funds as security for performance of this Agreement or spend such funds to finish Public Improvements or correct problems with the Public Improvements as the City deems appropriate Upon completion of performance of such improvements, conditions and requirements within the required time, the Developer shall issue an irrevocable letter of credit to the City in the amount of twenty-five percent (25%) of the total cost of construction and installation of the Public Improvements, to be held by the City during the warranty SUBDIVISION IMPROVEMENT AGREEMENT 05/01 -(,- period If the Public Improvements are not completed within the required time, the monies may be used to complete the improvements i" ~~ 14 Indemnification The Developer shall indemnify and hold harmless the City and its officers, employees, agents or servants from any and all suits, actions, and claims of every nature and description caused by, arising from or on account of this Agreement any act or omission of the Developer, or of any other person or entity for whose act or omission the Developer is liable, with respect to the Public Improvements, and the Developer shall pay any and all judgments rendered against the City as a result of any suit, action, or claim, together with all reasonable expenses and attorney's fees and costs incurred by the City in defending any such suit, action or claim The Developer shall pay all property taxes on the Property dedicated to the City and shall indemnify and hold harmless the City for any property tax liability 15 Waiver of Defects In executing this Agreement, the Developer waives all objections it may have concerning defects, if any, in the formalities whereby it is executed, or concerning the power of the City to impose conditions on the Developer as set forth herein, and concerning the procedure, substance, and form of the ordinances or resolutions adopting this Agreement. 16 Third Party Beneficiaries There are and shall be no third party beneficiaries to this Agreement. 17 Modifications This instrument embodies the whole agreement of the Parties There are no promises, terms, conditions, or obligations other than those contained herein, and this Agreement shall supersede all previous communications, representations, or agreements, either verbal or written, between the parties There shall be no modification of this Agreement except in writing, executed with the same formalities as this instrument. Subject to the conditions precedent herein, this Agreement may be enforced in any court of competent jurisdiction 18 Release of Liability It is expressly understood that the City cannot be legally bound by the representations of any of its agents or their designees except in accordance with the City of Wheat Ridge Code of Ordinances and the laws of the State of Colorado 19 Captions The captions to this Agreement are inserted only for the purpose of convenient reference and in no way define, limit, or prescribe the scope or intent of this Agreement or any part thereof 20 Bindinq Effect. This Agreement shall be binding upon and inure to the benefit of the parties hereto and their respective heirs, successors, and assigns as the case may be 21 No Waiver No waiver of any of the provisions of this Agreement shall be deemed or constitute a waiver of any other provisions herein, nor shall such waiver SUBDIVISION IMPROVEMENT AGREEMENT 05101 -7- constitute a continuing waiver unless otherwise expressly provided, nor shall the waiver of any default hereunder be deemed a waiver of any subsequent default hereunder 22 Invalid Provision If any provision of thiS Agreement shall be determined to be void by any court of competent jurisdiction, then such determination shall not affect any other provision hereof, all of the other provisions shall remain in full force and effect. It is the intention of the Parties that if any provision of this Agreement is capable of two constructions, one of which would render the provision void, and the other which would render the provision valid, then the provision shall have the meaning which renders it valid 23 Governinq Law The laws of the State of Colorado shall govern the validity, performance and enforcement of this Agreement. Should either party institute legal suit or action for enforcement of any obligation contained herein, venue of such suit or action shall be in Jefferson County, Colorado 24 Attorneys Fees Should this Agreement become the subject of litigation to resolve a claim of default of performance or payment by the Developer and a court of competent jurisdiction finds in favor of the City, the Developer shall pay the City's attorney's fees and court costs 25 Notice All notices required under this Agreement shall be in writing and shall be hand delivered or sent by registered or certified mail, return receipt requested, postage prepaid, to the addresses of the parties herein set forth All notices so given shall be considered effective seventy-two (72) hours after deposit in the United States mail with the proper address as set forth below Either party by notice so given may change the address to which future notices shall be sent. Notice to Developer' Richard Oneslaqer, Jr, Crosswire Investments, LLC 5271 South Yampa Street Centennial. Colorado 80015 Notice to City Greq Knudson Interim Director of Public Works 7500 West 29th Avenue Wheat Ridge, CO 80215 26 Force Maieure Whenever the Developer is required to complete the construction, repair, or replacement of Public Improvements by an agreed deadline, the Developer shall be entitled to an extension of time equal to a delay in completing the foregoing due to unforeseeable causes beyond the control and without the fault or negligence of the Developer including, but not restricted to, acts of God, weather, fires and strikes 27 Assiqnment or Assiqnments There shall be no transfer or assignment of any of the rights or obligations of the Developer under this Agreement without the prior written SUBDIVISION IMPROVEMENT AGREEMENT 05101 -x- approval of the City 28 Recordinq of Aqreement. This Agreement shall be recorded in the real estate records of Jefferson County and shall be a covenant running with the Property in order to \../' put prospective purchases or other interested parties on notice as to the terms and provisions hereof 29 Title and Authority The Developer, Crosswire Investments. LLC, expressly warrants and represents to the City that it is the record owner of the property constituting the Property and further represents and warrants, together with the undersigned individual(s) that the undersigned individual(s) has or have full power and authority to enter into this Subdivision Improvement Agreement. The Developer and the undersigned individual(s) understand that the City is relying on such representations and warranties in entering into this Agreement. WHEREFORE, the parties hereto have executed this Agreement on the day and year first above written CITY OF WHEAT RIDGE, COLORADO By' ATTEST ./ - 1,,' U .~,.,:';":....-." W~nda Sang, City Chqrk SUBDIVISION IMPROVEMENT AGREEMENT 05/01 -9- By' DEVELOPER /~ C~ ~/"~ Richard Oneslager, Jr --- ~ Managing Member STATE OF COLORADO COUNTY OF ) ) ) ss The foregoing instrument was 2002, by of , " acknowledged before me this day of , as :.r <., I Witness my hand and official seal My commission expires "I ' ; .J Notary Public (S EA L) SUBDIVISION IMPROVEMENT AGREEMENT 05/01 10- EXHIBIT A DESCRIPTION A PARCEL OF LAND SITUATED IN THE NE 1/4 OF SECTION 25, TOWNSHIP 3 SOUTH, I \ RANGE 69 WEST OF THE 6TH PRINCIPAL MERIDIAN, IN THE CITY OF WHEAT RIDGE, COUNTY OF JEFFERSON, STATE OF COLORADO, MORE PARTICULARLY DESCRIBED AS FOLLOWS COMMENCING AT THE NW CORNER OF THE NE 1/4 OF SAID SECTION 25, THENCE N89059'58"E ALONG THE NORTH LINE OF SAID NE 1/4 A DISTANCE OF 99306 FEET, THENCE SOoo 17'55"E ALONG THE WEST LINE OF THE E Y2 OF THE NE 1/4 OF THE NW 1/4 OF THE NE 1/4 OF SAID SECTION 25 A DISTANCE OF 30 00 FEET TO A POINT LYING ON THE SOUTHERLY RO W LINE OF WEST 38TH AVENUE, SAID POINT BEING THE POINT OF BEGINNING, THENCE N89059'58"E ALONG SAID SOUTHERLY RO W LINE PARALLEL WITH THE NORTH LINE OF SAID NE 1/4 A DISTANCE OF 29109 FEET TO A POINT OF CURVE, THENCE ALONG A CURVE TO THE RIGHT WHOSE CHORD BEARS S45008'46"E A DISTANCE OF 2116 FEET, SAID CURVE HAVING A CENTRAL ANGLE OF 89042'32", A RADIUS OF 15 00 FEET, AN ARC LENGTH OF 2349 FEET TO A POINT OF TANGENT LYING ON THE WESTERLY RO W LINE OF DEPEW STREET; THENCE SOool7'30"E ALONG SAID WESTERLYR.O.W LINE BEING PARALLEL WITH AND 25 00 FEET WESTERLY OF THE EAST LINE OF THE E Y2 OF THE NE1/4 OF THE NW 1/4 OF THE:t-..'E 1/4 OF SAID SECTION 25 A DISTANCE OF 185 08 FEET; THENCE S89059'58"W PARALLEL WITH AND 230 FEET SOUTHERLY OF THE NORTH LINE OF THE NE 1/4 OF SAID SECTION 25 A DISTANCE OF 305,99 FEET TO A POINT LYING ON WEST LINE OF THE E Y2 OF THE NE 1/4 OF THE NW 1/4 OF THE NE 1/4 OF SAID SECTION 25, THENCE NOool7'55"W ALONG SAID WEST LINE A DISTANCE OF 200 00 FEET TO THE POINT OF BEGINNING, EXHIBIT C COST ESTIMATE FOR PUBLIC IMPROVEMENTS PERRIN'S ROW SUBDIVISION WHEAT RIDGE, COLORADO ITEM UNIT QUANTITY UNIT PRICE TOTAL . '7/ \ ROADWAY IMPROVEMENTS ALONG DEPEW STREET SAWCUT EXISTING ASPHALT LF 167 1.00 167.00 REMOVE EXISTING ASPHALT SY 37 2300 851.00 REMOVE EXISTING COMBINATION CURB GUTTER & SIDEWALK LF 144 6,50 936.00 REMOVE EXISTING CONCRETE CURB CUT SF 72 3,00 216,00 9" FULL DEPTH ASPHALT PATCH BACK TON 23 45.00 1035.00 4" THICK CONCRETE SIDEWALK SF 824 2.50 2060.00 8" THICK CONCRETE DRIVEWAY SF 193 5.25 1013,25 DOUBLE 4" SOLID YELLOW LANE LINE LF 72 5,50 396,00 8" SOLID WHITE LANE LINE LF 35 5.50 192.50 SINGLE LANE USE ARROW EA 1 150,00 150.00 DOUBLE LANE USE ARROW EA 1 150.00 150,00 "NO PARKING, HERE TO CORNER" SIGN EA 1 175,00 175,00 TRAFFIC CONTROL EA 1 2500.00 2500.00 TRAFFIC CONTROL EA 1 2500 00 2500 00 $ 12341 75 + 25% CONTINGENCY $ 3085.44 TOTAL $ 1542719 EXHIBIT B PERRIN'S A RESUBDMSION OF LC SITUATED IN THE NE 1/4 l CIlY OF' WHEAT RIDGE, )3 ~ __ _ _ _ _ ~&3 _,-.---- __ _ _ - - - --- -- - - - - - - - - _~~1iI'58~ - _2~!l' ~Of' ~ ---rrPO.lVT OF 9.06 I I<<)lffii LI\lE OF M HE 1;4 or SEC:nOI<l :z], Us.., fijW., Of" THi iTH~ - - - - - -- ~ 1/4 ~! WEST 3~TH AVENUE Of' ~ ~~ ~~ 3 1/4- ~Ici ~ ~:~ ~~t,~~ i 1~""~~~~ N89059'S8'"E 291.09'~) II " I CASE HISTORY.- WC411-01 ~ 3.Q!J ~ ;- o I I r----~---- N~/!i~f_~_22~-,~ ----I-4~-- S1fIo.so _ :~~~-_-1Q.!__~~:.-. I I .00 , , , ' , , ' , , ' , , ' , , ' , ' , ' , .. I 1m: I it , ' , ' I \ ~ :~~~ra \ : l~ , , I , 1 i f";i:%:, ~.OO.. "91"[ \, LJ~~W'-----~~:"'_-- [g ',-_ _-+' l-Jl'" ~ ;'" ___.+_i........."___..,,.______________w>"jO'io---..:if------~ " , , , , , , , , u--~o:;:~~~ I I (e~,M1-PG.D6) , , , , , , , , , i ~ , ~ WZ.QZ-OtI t:=][BDD r 38TH AVE II 41ST AVE \ D I ~~D~ 32ND AVE lJ U -= I II r--I VICINITY MAP _m=r - ;';(8-~~ -W~':;(..;-N5g.W58f:~- -17~O~~- (REe ,rlj?Q70J) ~ t '8 ~ 15.JJ' 15.!!! LOT 1 50.1115(1 FT " 111M .rata r-------, I &.:5'IoIQH-~ I (S!:1 , J , >---<>Em, / ['\sO N2\~"E: ,/ , i ~L /' ~~ ---T---- ~;r BLOCK 1 ------------------------r----- -------------- ~25.l.AN05C/lPEW['"ENT (Erri>lJ.,f} Ifo/E:REBY'Iil.CArED BY~IS PV\TDOCUld€NT) , , ~Ol.Ifolb S/S. p.-. eN' 1..S-IoIO.llCl0(Q.tO'W ~""""'^= """"" SB9"59'5B"W 305,99' UKl'tAf1llJ 1f-3.l'01W"fO IWC ar ......-w I1LU ~1JIIIIa(""f - RlCMMD O. ~ Jfl. 1ae..1EAST~COIJlilT.sum:3700 ~~~tlOI12 -- ."""'" SIOOEAST_WtC1E.RtWl El'oICllLWOOO,CCUJR,.OOOlIO\12 ?l-<<ltlE:JOJ-1olO-22f;!!i """""1- ~L"Il.UII.f'\,S"O.Z7S:N FtlR/INl ON II&WJ'OF ~ SIJMC[ OOW'...,.,.. 1.300Sl:llJ1'HPOTOIIlACSTRffl".SIJlT(\211 ~CC/tOItIlDOllOO12 PKlNE;303-3J7-1Ja3 ROW SUBDIVISION <T 1, BlOCK 1, IlAI.MAR CONSOLJ()ATION PLAT )f SECllON 25, T.35., R.69W.. Of' THE 6TH P.Iol. COUNTY Of' JEfFERSON. STATE Of' COLORADO SHEET10fl LEGEND (8T' 1"U.1'J I'DI:"fIoiC PW OF kAWt COMSOLJo...TIONPlAT -- -- - ----- - - - - - --- - - - r-- -- ~ rouNOCHlSEUDCllOSS :=:~,~~~It.~., ~, o.l1"f fJ( 89'42'32- or 1l<< mi P~'JOVND .1 1/4' ALSO~~l ~1500': =~)LS. 132121H ~..eM>L...S.MO. . I IICHI (urs.t' ".12"11' L.z2J.+9 I C# ClU:lJL.ATED POSl'l'lON) Chd_S4!5'08'46"e: 21.115' , , , . , , 1 , . " " " LOT SlIMMARY TABL/f - ,..,. 50,911 '" ,.. '" '" "" 1113 1,113 '" 1.. 1.. '" ---+ .osv5f'~"r 15.00' 0' 15.00' t -r- LOT 8 , I 1.11J SQ. FT. , OR , ...".""" , , S89"59.5S..... 51.00' , I ... , OJ ~ LOT V ~ , OJ 7tliSO.FT. , ..~ ~ OR ~ , .... CUll78,r.alEl; , i ",0 i: .' " SIlr"'5e S1.00' ~, I ~k gg LOT 10 gal - 78llSQ.FT. ~ -: .. OR \!l O.o11'lrCAES , l' S89'5958 !5I.(IQ' wI . N' ~8 LOT 11 80' 8- TIl5SQ.I'T. ori8:. '" ~- ll.OlnACllES -a:~ _5958"'" 51.00' ,0 Q lOr if I I~ I" ~ 78$SQ..FT. ~ ,Y '" I B 1l.011lo1C1lES S89'::.g5fl"'N 51.00' :, LOT 13 ~ Ii ~ 1,11J$O.FT, '" N 0-02~ACI'IC$ ,. '" ---:;.-~~-~-- I. ----------- (SfI~) SlI9"Si5& SloOO' 00' pdPARED IY: ~~~ c.......... ~s.JIII\'l, 1306~G:O~)l31-1"'1 _~ ~~.:~:.~...-: ,~~loat ... l'WNt'.ATnII'<'c:rA.~. 1. RlCl-IARO D. DNESLAGER, JR.. eElHG TIiE OWNER Of REAL PROPERTY COtfTNHING (51,15J SQUARE FEET) 1.<4039 ACR(S OCSCRIBED AS FDU.QWS: 0<SCRlPll0N, A PARCEl OF ~D SmJ.\TEO IN THE HE 11. OF SECTION 25, l'l)WNSI-:lP J ~, RANG( &9 WEST Of 'THE 6l1-t PRINClf'Al lolERlDlAH, IN THE CITY Of WHEAT RIDGE, COUNTY Of JEmRSON, STATE OF COlORADO, lr.IORE PNrnCU't..<lm. Y OESCRlSED AS FOllOWS: ~~~~5~~~{ ~~~ ~~:t JlV1~ ~\~~N 25: DlSTAW;E Of 993.08 FEET; MHCi SOO"17'M"E ALONG THE WEST ~~ ~E AE~~ ~ :'ri/~ ~ ~.:ItZG ~ ~ 1/. OF ~o SOlIDlERlY R,O.W. UHE OF WEST 31TH "VE~ SAID POINT stING lHE POINT Of BEGINNING, THENCE Na9"59'58t: ALONG s.w SClU1'HERLY R.O.W. UHE PAAAU.El WITH THE NORTH UNE: OF 5o'ID NE ~/~0ISJ0~~1~~A= ~5~Le:~ENCE AlONG DISTANCE OF 21.15 FEET, SNO CURVE HA'JING A. CENTRAl ANGlE OF ll9'42'32", ... IWllUS Of 15.00 F"EET, Nl MC LtNGnI Of 23.49 FEET TO A. POINT OF TNolGENT LYING ON THE WESTERLY R.D.W, UN[ OF DEPEW SOO"I7'JO"E N.DHG sw WESITR!.Y R.O.W. Wl1l1 AND 25.00 FtET WESTERLY or THE ~ 14~~ ~E,:.di~;~E~ ~~!la:.!l~~ NE 1/4 Of P AHD 230 fEET SOU1'HtRl Y or THf NOR1H UNE OF l"HE NE 1/4 or SAID SECTION 25 A DISTANCE or 305.99 FrET TO A POINT ~~~ANO~~T~~;E~ct~~j~~~~~GTH~~ 1/4 or THE WEST LINt: A OISTAHCE Of 200.00 rn:r TO THE POINT Of SEGlHNlNG; ItAVE l.}i[) OUT, $UBOMOED AND PlATTEO SAID !.AND AS PER THE lMAWING HfRfDH CONTAAED UNDER M NNoIE AHD ST'tt..E or PERRIN'S ROW SlJBDMSlON, A SUBDMSlOH OF A. PNrr or l"l-CE Cl'lY Of' WHEAT RIDGE. COl..OAAOO NIlO BY n-tESE PRESfIiTS 00 DEDICA.TE TO THE Cl'lY Of WHfAT RlOOE NlD THOSf hlUN\C1P"LLY OWWED ANO/OR lolUNICIP"lLY FRANCtlISEO IJT1UTIES AHD SEfMC(S THOSE PORTIONS OF REAl.. PROPERTY SHQWtrt AS E,lSEMENTS FOR THE CONSTRUCTION, INSTAU.ATlON, OPEAATION, UAlKTENNlCE, REPAIR AHD R&tACEIoIENT FOR AU SEFMCtS. THIS lNCUJOES BUT IS NOT UW1T[!) TO TElEPHO~t "NO El..[C1"RIC UNES, GAS UNES. WA~ AND SMIITARY SEWt'R UNES. HYD!WITS, SiORlol SEWER SYSTalS AND PIPES, DETENTION PONOS. 1fIill llllB IiIB i'/:l: ;f,'~~~; .- R~HAAO D. ONESLAGER, JR. ",~~~/J :? SIGNATURE ~ STATE OF" COLORADO COUNT'I' OF" AotAU,UItI! )ss WITNESS WY HAHl) ANO OF"f1C1.4L sv.L lIY COW.wJSSJON EXPlRES: .,1/4/7..64)" NQIN<T ~~ hwr """" 8EARlNGS USED ON THIS SURVEY ARE SASEO ON THE CITY or WHEAT RIDGE DATUW, WHICH IS THAT THE NOR'111 UNE OF THE: NE 1/4 Of 5(CT1ON 25. T..35., R.S9w.. OF 'lliE 5TH P.lol. BEARS N89'59'S6'"E BOUNDED AND REfEREHCtO IIY THE WONuuOOS' SHOWN HEREON. 8o'SEO ON FLOOO INSURANCE RATE w,p COWI.lUNfTY PANEL NO. 0a5079 ~ C COVERING THE CfTY OF' WHEJ.,T RIDGE AND DATED F'EBRUAR't' 4, 1986 ISSUED BY .'\'tiE: FtOfRAI... Oot:flCE:NCY MAJ>W;E:JJEWT ADENC'f, >>It SUSJECT PROpm is IN ZONE C, DEFINED JS -AREAS OF IolINIw.L FlOOOINC. AND IS NOT S/TW.TEO IN A SPECIAL FlOOD fiAZARD AREA.. THE STORI,/ OCTENTION AREA HERE SHOWN AS Df:TENnON PCmD E.4SEMENT "A' AND DEtEtffiON POND ~OIENT 'S' SHALl SE CONSTRUcTED AND WJNTAlNEQ BY THE OWNER. .IrNO SUBSEQtlENT O'''tNERS. HEIRS. SUCCESSORS AND ASSIGNS. IN THE EVen 1'HAT SUCH CON~UCT10N AND MAlNTtNANCE IS HOT P~E'O 9Y" !WO QltN(R, rHf" CIlY Of' WHf.,U RlOG( SHALl. HAl,'f" n-a::: RIGHT TO ENTER SUCH AAt:A AND PERFORlol NECESSARY WORK, THE COST OF" 'MilCH ~o OWNER, HEIRS. SUccts:sDRS AND ASSIGNS AGREES TO PAY. NO aUtLDlt-lG OR STRUCTURE WIll. 6E CONSl1'!:UCTtD IN THE OETrnTlON AREA ANO N<:l C~~~ OR Al"TEAA110KS ,I,fl'ECTI~ T11€. KVt!R.<J.JUC CKAAAI;1'ERISllCS ~ M 0ETUmDW. !oRU. 'MLl.. 'at hL/trlE 'fffi\'.O\J1 \'ME o'PPRO'IAI... Or Tl-\t OIRECTOR Of puauc WORKS. THE OWNERS Or lO1'3 1 'THROUGH 13. \NCLU$l'<E, SlOCK 1 OF' PERRIN'S ROW SU8OMSIOH, HIS SUCCESSORS Al-lD ASS1GNS GAANTS UWITU! ~:OC~~~~(l~ ~~~60b~ :~lol~~~~~~~RO~;~. SUCH GIt*(! or 000100 SHAll.. & u",m.t1 'ro 1i-\E O'<<NERS, TOIN'01'3 CUSI"OloiEPS A.tID GUtsTS Of ~E OWNERS, NolO S~ I:l FURTHtRwORE GRWT' ~CESS TO, NID FREE~~: ~~~~ SAI ~=~:S =N~~&f~~PE!mE'S, .',No/o~ fRO'" ~\llCP\.IaUCSl'REEi5. 1~! 2 12 JO rL;J...., , I 06 20 40 SCALE; 1- - 20' 1Olllli;COIIT1IlOOl LOTS 1 "THROUGH 13, IHCLUSM:, &LOCK 1 Of" 11-115 SUBDMSlON AREA ZONED PWUO (PLANNED 10llXED USE DEVE!..OPWOO). NON-EXClLlSNt ~ GRANTED ACROSS LOTS 7, 8 AND 13 ARE HERESY DftlICATEO TO THE PERRIN'S ROW SUBOI\l1SlON HOWEOWNERS' ASSOCIATION FOR "THE WAlNT!NANCE. REPAIR ANO/Ofl RtPtACEhI€NT Of CQMI.lON E!..DtIENT IIotPRQI,/ElolEt-(TS CQt.lSTRLICTtO WllHIN ~D USElotEWS. I, 8R('l1" L IotIULR. DO HEREBY CERTIFY lWAT ritE SURVEY OF THE BOUNDAAY OF PERRIN'S ROW SUBOMSlON WAS IotADE UNDER t.tT' SUPEfMSlON, RESPOHS/BfUTY NIl) CHECKJHG OH MARCH 25, 2002 A.ND TO THE BEST Of Ilf KHOWI.EDGE. IHF'ORWA.TlON AND BOlD' AND IN .ACCOROAHCE Wf1'H ALL APPUCABtE COlOIWX> STAT1JTES, CURROO RE.'Y'lsm EDITlON AWENDED At40 THE ACCQWPAN'f1NG PlAT ACCURATELY SAID ~ .a.ccoRDING TO COlORADO LAW 'l'OIJ !.lUST COMMENCE 1N1 LEGAL ACTION BASED UPON mf OEfECT IN nns SURVEY WITHIN 7HHEl' l'!;MS AFTE:R YOU FIRST OlSCMR SUCH OEITer. fH NO MW, WAY ,t.N( ot.enbN BASED UPON itH'( OEFECT IN THIS SURVEY BE COWI.lENCEO WORE THAN TEN)'l;o(RS FROM THE, DATE OF THE CtRTlFlCATlON SHOWN HEREON. N(f PERSON WHO KNOWl~'1' REMOVES, ALTERS Oft DEFACES ANY PUBUC LAND SURVEY WON\JUOO OR lNiD BOLI+lOo6R'Y IIONUlolENT OR ACCESSORY COMMITS A CI,),SS lWO(Z) t.lISDDAtANOft PURSUANT TO STATESTAME ll'-4-~, Of mE' COlORADO REVISED STAn/TE WA.Yl"lR'!< CFR1'FY'ATF". A ~ L c,,~~.. ~ CrT'( SrfJ...., ',". C>. I ~u~~~ ~N1mInK t:FIlMCATInN. AC"C~'!tAUNG IN TIlE OF'F'lCE OF OF THE COlJNlY ClERK AND RECORDER OF Rl:.\,;t.I'IlON NO. EffERsON COUN1Y AT GOLnEN. COlORADO ON THIS DAY or 2lt....-AT_O.CLOCK.......-.1ol JEFFERSON COI,J>IT'f ~Rl<, _0 fl.ECQROEfl. aYe OEI'Ull" CLERK ~ CITYWIDE BANKS Banking With the Human Touch. EXHIBIT D October 31, 2002 City of Wheat Ridge 7500 W 29th Ave. Wheatridge, Co 80215-6713 To Whom It May Concern: We hereby authorize you to draw on us for the account of Crosswire Investments, LLC and Richard Oneslager up to an aggregate amount of$15,427 19 (estimated cost of improvements) available by your drafts at sight for 125 percent invoice value accompanied by your signed statement that the above is drawn in payment of street improvements covering west side of Depew St. Each draft presented under this Letter of Credit must state that it is drawn under Letter of Credit of Citywide Banks dated 10-31-02 and the amount endorsed on this Letter of Credit. We hereby agree with the drawers, endorsers, and bona fide holders of all drafts drawn under and in compliance with the terms of this credit that such drafts will be duly honored upon presentation to the drawee, S~ < , ;' ohn Me a ghlin (j Branch President, Citywide Banks / ,,, '/ 10660 E. Colfax Ave. Aurora, Colorado 80010 (303) 365.3600 Fax (303) 365.3601 13731 E. Mississippi Ave. Aurora, Colorado 80012 (303) 365.4000 Fax (303) 365.4001 8101 E. Belleview Aw. Denver, Colorado 80237 (303) 365.4080 Fax (303) 365.4081 12075 E. 45th Ave. Denver, Colorado 80239 (30J) 365-8000 Fax (303) 365.8001 Trinity Place, Suit~ 100 1801 Broadway Denver, Colorado 80202 (303) 365.3800 Fax (303) 365.3801 3345 S. Wadsworth Blvd. Lakewood. Colorado 80227 (303) 365.8040 Fax (303)365.8041 9500 w: 49th Ave. Suite ClOD Wheat Ridge, Colorado 8DOJ) (303) 365.8060 Fax {303) 365.8061