Loading...
HomeMy WebLinkAbout0028SUBDIVISION IMPROVEMENT AGREEMENT TH IS AGREEMENT made this Z 3 j2.0 of ~~tAA-P--'1 , 2 o lS by and between the CITY OF WHEAT RIDGE, COLORADO, a home rule municipal corporation (the "City"), and William Fritz, (the "Developer"), together referred to as the "Parties". REC ITALS: The Developer is the owner of certain real property located in the City of Wheat Ridge, which is more particularly described in Exhibit A and made a part hereof (the "Property"), commonly known as Yukon Grove Subdivision. On December 8, 2014, the City Council of the City of Wheat Ridge, after holding all required public hearings, approved the final plat for the Property titled Yukon Grove Subdivision. A copy of the Final Plat is attached hereto as Exhibit B and incorporated herein. The approvals cited above are conti ngent upon the express condition that all duties created by th is Agreement be faithfully performed by the Developer. AGREEMENT NOW, therefore, fo r and in consideration of the mutual promises and covenants contained herein, the sufficiency of which are mutually acknowledged, the parties hereto agree as follows: 1. Purpose. The purpose of this Agreement is to set forth the terms, conditions, and fees to be paid by the Developer upon subdivision of the Property. All conditions contained herein are in addition to any and all requirements of the City of Wheat Ridge Subdivision Ordinance and Zoning Ordinance, the City of Wheat Ridge Charter, any and all state statutes, and any other sections of the City of Wheat Ridge Municipal Code and are not intended to supersede any requirements contained therein. 2. Other Requirements. Intentionally deleted. 3. Fees. The Developer hereby agrees to pay City Development Review fees to the City for engineering, hydrological. surveying, legal, and other services rendered in connection with the review of the subdivision of the Property. 4. Parkland dedication fee-in lieu. Fees in lieu of land dedication in the amount of $49,945.80 were received on February 18, 2015. SUBDIVISION IMPROVEMENT AGREEMENT 10/14 1 111M ~lrl llilllilll lilll llilllllilllllllillllilil lillllll ~ ~~~0~0 2015016466 02/23/2015 04:52:40 PM 16 Page(s) JEFFERSON COUNTY. Colorado 5. Title Policy. Prior to recording of the final plat (or, if no plat is associated with the development; prior to and as a condition of final approval of the development by the City), title commitment for all those portions of the Property, as well as any other interests in real property (easements, etc.) to be reserved for public purposes or dedicated to the City shall be provided to the City. The title commitment shall show that all such property is or shall be , subsequent to the execution and recording of this Agreement. free and clear of all liens and encumbrances (other than real estate taxes which are not yet due and payable) which would make the dedication or reservation unacceptable as the City determines in its reasonable discretion. The City, in its sole discretion, may accept any dedication regardless of encumbrances. The title policy evidenced by the title commitment shall be provided within thirty (30) days after the recording of this Agreement, in an amount equal to the fair market value of the property so dedicated or reserved. 6. Breach by the Developer; the City's Remedies. In the event of a breach of any of the terms and conditions of this Agreement by the Developer, the City Council shall be notified immediately and the City may take such action as permitted and/or authorized by law, this Agreement, or the ordinances and Charter of the City as the City deems necessary to protect the public health, safety and welfare; to protect lot buyers and builders; and to protect the citizens of the City from hardship and undue risk. These remedies include, but are not limited to: (a) The refusal to issue any building permit or certificate of occupancy; (b) The revocation of any building permit previously issued under which construction directly related to such building permit has not commenced, except a building previously issued to a third party, (c) A demand that the security given for the completion of the Public Improvements be paid or honored, or (d) Any other remedy available at law or in equity. Unless necessary to protect the immediate health, safety and welfare of the City or to protect the City's interest with regard to security given for the completion of the Public Improvements, the City shall provide the Developer thirty (30) days written notice of its intent to take any action under this paragraph during which thirty day period the Developer may cure the breach described in the notice. 7. Public Improvements and Warranty. All storm sewer lines, drainage structures, paved streets, curb, gutter and sidewalk, including the undergrounding of all overhead utilities. and necessary appurtenances as shown on the subdivision plat and the associated construction documents (the "Public Improvements" or "Improvements") as approved by the Director of Public Works or designee of the City, shall be installed and completed at the expense of the Developer within the timeframes set forth in Section 10 of this Agreement. The itemized costs of the Public Improvements required by this Agreement and shown on the construction documents approved by the Director SUBDlVISION IMPROVEMENT AGREEMENT 10114 2 of Public Works of the City are set forth on Exhibit C. All Public Improvements covered by this Agreement shall be made in accordance with the construction documents drawn according to regulations and construction standards for such improvement and approved by the Director of Public Works of the City. It is understood by the Parties that the description of the Public Improvements may be general in nature, and that reasonable modifications of the scope, nature, costs, and similar aspects of the Public Improvements may be necessary to secure final approval of the Public Improvements. The quantities and locations for the Public Improvements are based on information that was available at the time of approval of the Final Plat. Additional Public Improvements may be required , and Developer shall be responsible for submitting revisions to the Final Plat approved by the City. The Public Improvements shall be substantially complete, with only such exceptions as shall be approved in advance by the Director of Public Works in the exercise of his or her sole discretion, prior to the issuance of the first Building Permit. The Developer shall also warrant any and all Public Improvements which are conveyed to the City pursuant to this Agreement for a period of two (2) years from the date the City's Director of Public Works certifies that the same conforms to the specifications approved by the City. Specifically, but not by way of limitation, the Developer shall warrant the following: (a) That the title conveyed shall be marketable and its transfer rightful; (b) Any and all facilities conveyed shall be free from any security interest or other lien or encumbrance; and (c) Any and all facilities so conveyed shall be free of defects in materials or workmanship for a period of two (2) years as stated above. (d) To the degree the Developer is required to install and maintain landscaping on public or private property, it is the obligation of Developer and its successors and assigns, to maintain the required landscaping in perpetuity. The City will finally accept for maintenance all Public Improvements, exclusive of landscaping materials, after the warranty period has expired provided all warranty work has been completed. The City shall accept for snow removal purposes only, all dedicated public streets after the City issues the first certificate of occupancy. 8. Installation of Traffic Signal. A traffic signal may be required to serve this development. Determination of the need for the signal shall be made by the City's Public Works Director, hereinafter "Director'', prior to building permit issuance and based upon a traffic study for this development approved by the City. The Developer shall provide collateral for the estimated cost of installation of the traffic signal prior to SUBDIVISION IMPROVEMENT AGREEMENT 10/14 3 } building permit issuance, if the Director has determined that a signal is needed. Prior to building permit issuance, the Developer shall provide traffic signal plans for approval by L/ the Developer and the Colorado Department of Transportation. 1 The Developer shall notify the City in writing, a minimum of one hundred sixty (160) days prior to the desired time of installation/modification of the traffic signal in order to allow the City to coordinate the timing of the traffic signal improvements. If the Director approves installation of the signal based on meeting traffic warrants, the City shall then notify the Developer in writing of the exact amount required for the traffic signal improvements. The Developer shall then make payment to the City in cash for the required amount within sixty (60) days of receipt of such letter. The City will not commence traffic signal improvements until the Developer has paid to the City the total amount determined by the Director to be the total cost of improvements. 9. Observation. Inspection and Testing. The City shall have the right to require reasonable engineering observations and testing at the Developer's expense. Observation and testing, acquiescence in, or approval by any engineering inspector of the construction of physical facilities at any particular time shall not constitute the approval by the City of any portion of the construction of such Public Improvements. Such approval shall be made by the City, only after completion of construction and in the manner hereinafter set forth . The Director is designated by the City to exercise authority on its behalf under this Agreement and to see that this Agreement is performed according to its terms. Work under this Agreement may, without cost or claim against the City, be suspended by the Director for substantial cause. The Director shall, within a reasonable time after presentation, make decisions in writing on all claims of Developer and on all other matters relating to the execution and progress of the work or the interpretation of this Agreement, the master plan and specifications. All such decisions of the Director shall be final. The Director shall make all determinations of amounts and quantities of work performed hereunder. To assist him in this work Developer shall make available for inspection any records kept by Developer. The Director shall make all determinations of amounts and quantities of work performed hereunder. To assist him in this work Developer shall make available for inspection any records kept by Developer. The Director and his authorized representatives shall have free access to the work at all times, and Developer shall furnish them with facilities for ascertaining whether the work being performed, or the work which has been completed, is in accordance with the requirements of the Agreement. SUBDIVISION IMPROVEMENT AGREEMENT 10/14 4 The Director will make periodic observations of construction (sometimes commonly referred to as "supervision"). The purpose of these observations and construction checking is to determine the progress of the work and to see if the work is being performed in accordance with the plans and specifications. He will in no way be responsible for how the work is performed, safety in, on, or about the job site, methods of performance, or timeliness in the performance of the work. Inspectors may be appointed to inspect materials used and work done. Inspections may extend to all or any part of the work and to the preparation or manufacture of the materials to be used. The inspectors will not be authorized to alter the provisions of this Agreement or any specifications or to act as foreman for Developer. The Inspector will have authority to reject defective materials and to suspend any work that is being done improperly, subject to the final decision of the Director. 10. Completion of Public Improvements. The obligations of the Developer provided for in paragraph 6 of this Agreement, including the inspections hereof, shall be performed on or before f) 2-Ira I 2.. 0 I" ' and proper application for acceptance of the~Public Improvements shall be made on or before such date. Upon completion of construction by the Developer of such Improvements, the City's Director of Public Works or designee, shall inspect the Improvements and certify with specificity its conformity or lack thereof to the City's specifications. The Developer shall make all corrections necessary to bring the Improvements into conformity with the City's specifications. Once approved by the City's Director of Public Works, the City shall accept said Improvements upon conveyance; provided, however, the City shall not be obligated to accept the Public Improvements until the actual costs described in this Agreement are paid in full by the Developer. 11 . Protection. Developer, at its expense, shall continuously maintain adequate protection of all Improvements from damage prior to acceptance by the City and shall protect the City's property from injury and loss arising in connection with this Agreement. Developer shall make good any such damage, injury or loss except such as may be caused directly by authorized agents or employees of the City. Developer shall adequately protect adjacent property and shall provide and maintain all passageways, guard fences, lights and other facilities for protection required by public authority or local conditions. Developer shall be responsible for damage to any public and private property on and adjacent to the site of Developer's Improvements caused by negligent or willful acts of Developer, its agents or subcontractors. Developer shall take all reasonable effort necessary to prevent damage to pipes, conduits, and other underground structures and to overhead wires, and to water quality. Developer shall protect carefully from SUBDIVISION IMPROVEMENT AGREEMENT 10/14 5 disturbance or damage all land monuments and property marks until an authorized agent of the City has witnessed or otherwise referenced their location, and shall not remove them until directed. When any direct or indirect damage or injury is done to public or private property by or on account of any act, omission. neglect or misconduct in the construction of Improvements, or in consequence of the non-execution thereof on his part, such damaged property shall be restored by Developer at its own expense to a condition similar or equal to that existing before such damage or injury. Developer shall at all times, whether or not so specifically directed by the Director, take necessary precautions to insure the protection of the public. Developer shall furnish, erect and maintain, at its own expense. all necessary barricades, suitable and sufficient red lights, construction signs, provide a sufficient number of watchmen, and take all necessary precautions for the protection of the work and safety of the public through or around his construction operations as Developer and the Director shall deem reasonably necessary. 12. Related Costs -Public Improvements. The Developer shall provide all necessary engineering designs, surveys, field surveys, testing and incidental services related to the construction of the Public Improvements at its sole cost and expense, including final drainage study letter certified accurate by a professional engineer registered in the State of Colorado. 13. Improvements to be the Property of the City. All Public Improvements for roads, concrete curb and gutters, public storm sewers and public drainage improvements accepted by the City shall be dedicated to the City and warranted for a period of twenty-four (24) months following acceptance by the City, as provided above. 14. Performance Guarantee. In order to secure the construction and installation of the Public Improvements the Developer shall, prior to record ing the Final Plat, if applicable, in the real estate records of Jefferson County, which recording shall occur no later than ninety (90) days after the execution of this Agreement, furnish the City, at the Developer's expense, with the Performance Guarantee described herein. The Performance Guarantee provided by the Developer shall be an irrevocable letter of credit in which the City is designated as beneficiary, for one hundred twenty-five percent (125%) of the estimated costs of the Public Improvements to be constructed and installed as set forth in Exhibit C, if applicable to secure the performance and completion of the Public Improvements as required by Section 26-418 Security for Required Improvements, of the Wheat Ridge Subdivision Regulations. The Developer agrees that approval of this Agreement by the City is contingent upon the Developer's provision of an irrevocable letter of credit to the City within ninety (90) days of the execution of this Agreement in the amount and form provided herein. Failure of the Developer to provide an irrevocable letter of credit to the City in the manner provided herein shall negate the City's approval of this Agreement. Letters of credit shall be substantially in the form and content set forth in Exhibit D, if applicable, and shall be SUBDIVlSION IMPROVEMENT AGREEMENT 10/14 6 subject to the review and approval of the City Attorney. The Developer shall not start any construction of any public or private improvement on the Property including, but not 1 limited to. staking, earthwork, overlot grading or the erection of any structure, temporary or otherwise, until the City has received and approved the irrevocable letter of credit. The estimated costs of the Public Improvements shall be a figure mutually agreed upon by the Developer and the City's Director of Public Works, as set forth in Exhibit C if applicable. If, however, they are unable to agree, the Director of Public Works' estimate shall govern after giving consideration to information provided by the Developer including, but not limited to, construction contracts and engineering estimates. The purpose of the cost estimate is solely to determine the amount of security. No representations are made as to the accuracy of these estimates, and the Developer agrees to pay the actual costs of all such Public Improvements. The estimated costs of the Public Improvements may increase in the future. Accordingly, the City reserves the right to review and adjust the cost estimate on an annual basis. If the City adjusts the cost estimate for the Public Improvements, the City shall give written notice to the Developer. The Developer shall, within thirty (30) days after receipt of said written notice, provide the City with a new or amended letter of credit in the amount of the adjusted cost estimates. If the Developer refuses or fails to so provide the City with a new or amended letter of credit, the City may exercise the remedies provided for in this Agreement; provided, however, that prior to increasing the amount of additional security required, the City shall give credit to the Developer for all required Public Improvements which have actually been completed so that the amount of security required at all time shall relate to the cost of required Public Improvements not yet constructed. In the event the Public Improvements are not constructed or completed within the period of time specified by paragraph 9 of this Agreement or a written extension of time mutually agreed upon by the parties to this Agreement, the City may draw on the letter of credit to complete the Public Improvements called for in this Agreement. In the event the letter of credit is to expire within fourteen (14) calendar days and the Developer has not yet provided a satisfactory replacement, the City may draw on the letter of credit and either hold such funds as security for performance of this Agreement or spend such funds to finish Public Improvements or correct problems with the Public Improvements as the City deems appropriate. Upon completion of performance of such improvements, conditions and requirements within the required time, the Developer shall issue an irrevocable letter of credit to the City in the amount of twenty-five percent (25%) of the total cost of construction and installation of the Public Improvements, to be held by the City during the warranty period. If the Public Improvements are not completed within the required time, the monies may be used to complete the improvements. SUBDIVISION IMPROVEMENT AGREEMENT 10/14 7 15. Indemnification. The Developer shall indemnify and hold harmless the City and its officers, employees, agents or servants from any and all suits, actions, and claims of every nature and description caused by, arising from or on account of this Agreement any act or omission of the Developer, or of any other person or entity for whose act or omission the Developer is liable, with respect to the Public Improvements; and the Developer shall pay any and all judgments rendered against the City as a result of any suit, action, or claim, together with all reasonable expenses and attorney's fees and costs incurred by the City in defending any such suit, action or claim. The Developer shall pay all property taxes on the Property dedicated to the City and shall indemnify and hold harmless the City for any property tax liability. 16. Waiver of Defects. In executing this Agreement, the Developer waives all objections it may have concerning defects, if any, in the formalities whereby it is executed , or concerning the power of the City to impose conditions on the Developer as set forth herein, and concerning the procedure, substance, and form of the ordinances or resolutions adopting this Agreement. 17. Third Party Beneficiaries. There are and shall be no third party beneficiaries to this Agreement. 18. Modifications. This instrument embodies the whole agreement of the Parties. There are no promises, terms, conditions, or obligations other than those contained herein; and this Agreement shall supersede all previous communications, representations, or agreements, either verbal or written , between the parties. There shall be no modification of this Agreement except in writing , executed with the same formalities as this instrument. Subject to the conditions precedent herein, this Agreement may be enforced in any court of competent jurisdiction. 19. Release of Liability. It is expressly understood that the City cannot be legally bound by the representations of any of its agents or their designees except in accordance with the City of Wheat Ridge Code of Ordinances and the laws of the State of Colorado. 20. Captions. The captions to this Agreement are inserted only for the purpose of convenient reference and in no way define, limit, or prescribe the scope or intent of this Agreement or any part thereof. 21 . Binding Effect. This Agreement shall be binding upon and inure to the benefit of the parties hereto and their respective heirs, successors, and assigns as the case may be. 22. No Waiver. No waiver of any of the provisions of this Agreement shall be deemed or constitute a waiver of any other provisions herein, nor shall such waiver SUBDIVISION IMPROVEMENT AGREEMENT 10/14 8 constitute a continuing waiver unless otherwise expressly provided, nor shall the waiver of any default hereunder be deemed a waiver of any subsequent default hereunder. 23. Invalid Provision. If any provision of this Agreement shall be determined to be void by any court of competent jurisdiction, then such determination shall not affect any other provision hereof, all of the other provisions shall remain in full force and effect. It is the intention of the Parties that if any provision of this Agreement is capable of two constructions, one of which would render the provision void , and the other which would render the provision valid, then the provision shall have the meaning which renders it valid. 24. Governing Law. The laws of the State of Colorado shall govern the validity, performance and enforcement of this Agreement. Should either party institute legal suit or action for enforcement of any obligation contained herein, venue of such suit or action shall be in Jefferson County, Colorado. 25. Attorneys Fees. Should this Agreement become the subject of litigation to resolve a claim of default of performance or payment by the Developer and a court of competent jurisdiction finds in favor of the City, the Developer shall pay the City's attorney's fees and court costs. 26. Notice. All notices required under this Agreement shall be in writing and shall be hand delivered or sent by registered or certified mail, retum receipt requested , postage prepaid , to the addresses of the parties herein set forth. All notices so given shall be considered effective seventy-two (72) hours after deposit in the United States mail with the proper address as set forth below. Either party by notice so given may change the address to which future notices shall be sent. Notice to Developer: Notice to City: Scott Brink Director of Public Works 7500 West 29th Avenue Wheat Ridge, CO 80033 27. Force Majeure. Whenever the Developer is required to complete the construction, repair, or replacement of Public Improvements by an agreed deadline, the Developer shall be entitled to an extension of time equal to a delay in completing the SU8DIVISION IMPROVEMENT AGREEMENT 10/14 9 foregoing due to unforeseeable causes beyond the control and without the fault or negligence of the Developer including, but not restricted to, acts of God, weather, fires /0 and strikes. 28. Assignment or Assignments. There shall be no transfer or assignment of any of the rights or obligations of the Developer under this Agreement without the prior written approval of the City. 29. Recording of Agreement. This Agreement shall be recorded in the real estate records of Jefferson County and shall be a covenant running with the Property in order to put prospective purchases or other interested parties on notice as to the terms and provisions hereof. 30 . Title and Authority. The Developer, William Fritz for Yukon Grove, LLC, expressly warrants and represents to the City that it is the record owner of the property constituting the Property and further represents and warrants, together with the undersigned individual(s) that the undersigned individual(s) has or have full power and authority to enter into this Subdivision Improvement Agreement. The Developer and the undersigned individual(s) understand that the City is relying on such representations and warranties in entering into this Agreement. WHEREFORE, the parties hereto have executed this Agreement on the day and year first above written. CITY OF WHEAT RIDGE, COLORADO By: ATIEST: Joyce Jjt. Ma/Pf / v SUBDIVISION IMPROVEMENT AGREEMENT 10/14 10 GeraidDahi, CitYttQmey DEVELOPER STATE OF COLORADO COUNTY OF \_)e-f-\e_,v 'SLrV\ ) ) ) SS. The foregoing instrument was acknowledged before me this __lK_ day of _1fi..X..:L..\?J;...XVUA~II\J\'4--' 20 _1$... by ~h l \ liMY\ fu f:z_ , as \ _\Vti,..II....Lo<.·-\~"'~o...&,.'ou..r....L.v ____ of ~tdkeo &vr 1'-L LLL- (SEAL ) Witness my hand and official seal. My commission expires: __ 0_7_/J_q_/_J.rJ_I_7..:......_ ______ _ KIM WAGGONER NOTAAY PUBLIC STATE OF COLORADO Notary 10 20134045648 My Comrnls81on Exptm 07/1912017 11 SUBDIVISION IMPROVEMENT AGREEMENT 10/14 1( EXHIBIT A LEGAL DESCRIPTION A PARCEL OF LAND LOCATED IN THE NORTHWEST QUARTER OF SECTION 26, TOWNSHIP 3 SOUTH, RANGE 69 WEST, OF THE 6TH PRINCIPAL MERIDIAN, CITY OF WHEAT RIDGE, COUNTY OF JEFFERSON, STATE OF COLORADO AS DESCRIBED IN THE DOCUMENTS RECORDED AT RECEPTION NO. F2156985 (DEED) AND RECEPTION NO. 2015005269 (BOUNDARY AGREEMENT) IN THE OFFICIAL RECORDS OF SAID COUNTY OF JEFFERSON, AND BEING MORE PARTICULARLY DESCRIBED AS FOLLOWS: COMMENCING AT THE CENTER QUARTER CORNER OF SAID SECTION 26, THENCE S89°45'02'W, 423.03 FEET ALONG THE SOUTHERLY LINE OF SAID NORTHWEST QUARTER OF SECTION 26; THENCE DEPARTING SAID SECTION LINE N00°14'58'W, 25.00 FEET TO THE NORTHERLY RIGHT-OF-WAY LINE OF 32ND AVENUE, AND THE POINT OF BEGINNING; THENCE S89°45'02'W, 111 .41 FEET ALONG SAID NORTHERLY RIGHT-OF-WAY LINE; THENCE DEPARTING SAID NORTHERLY RIGHT-OF-WAY LINE N00°19'27'W, 10.00' TO A POINT ON THE EASTERLY LINE OF RIDGEVIEW ESTATES SUBDIVISION; THENCE ALONG THE EASTERLY LINE OF SAID RIDGEVIEW ESTATES SUBDIVISION N00°19'27'W, 360.00 FEET; THENCE CONTINUING ALONG SAID EASTERLY LINE N89°45'02"E, 106.41 FEET; THENCE N00°19'27'W, 469.71 FEET; THENCE S53°44'06"E, 285.21 FEET; THENCE S00°19'27"E, 300.00 FEET; THENCE N89°45'02"E, 184.00 FEET TO THE WESTERLY RIGHT-OF-WAY LINE OF WADSWORTH BOULEVARD; THENCE S00°19'27"E, 60.00 FEET ALONG SAID RIGHT-OF-WAY LINE; THENCE DEPARTING SAID RIGHT-OF-WAY LINE S89°45'02'W, 408.00 FEET; THENCE S00°19'27"E, 310.00 FEET TO THE NORTHERLY RIGHT-OF-WAY LINE OF 32ND AVENUE AND THE POINT OF BEGINNING. SAID PARCEL CONTAINS 153,832 SF (3.5315 ACRES) MORE OR LESS. BASIS OF BEARINGS: BEARINGS ARE BASED ON THE SOUTHERLY LINE OF THE NORTHWEST QUARTER OF SECTION 26, TOWNSHIP 3 SOUTH, RANGE 69 WEST OF THE SIXTH PRINCIPAL MERIDIAN BEARING N89°45'02"E BETWEEN THE WEST QUARTER CORNER BEING A FOUND 3 Y." ALUMINUM CAP PLS # 132121N RANGE BOX AND THE CENTER QUARTER CORNER BEING A FOUND 3 Y." ALUMINUM CAP PLS # 132121N RANGE BOX. FEBRUARY 10, 2015 ~ EXHIBIT B YUKON GROVE SUBDIVISION, FILING NO. 1 A PARCEL OF LAND LOCATED IN THE NW 1/4 OF SECTION 26 T 3S R 69W OF THE 6TH PM CllY OFWHEAT RIDGE. COUNlY OF JEFFERSON, STATE OF COLORADO -· , / SHEET 01 OF 03 . .,.."" , I ~ ' __ ..... I e n ··'"--~ i ~ ~ f'),.....-r APPROX SlfF:lOC:AtlO'j ~ "" ,... &n.O..... .\ • . l ,. ~ .l ... • ~!"···~--····­r.....-------·--------··· {. .J' ~ - . ,, .. YUKON GROVE SUBDIVISION, FILING NO. 1 A PARCEL OF LAND LOCATED IN THE NW 1/4 OF SECTION 26. T 3S R 69W OF THE 6TH PM CITY OFV'MEAT RIDGE COUNTY OF JEFFERSON. STATE OF COLORADO r ·', SHEET 02 OF 03 <1- ' I I Co ,- /t --N-io=- .., _., ~-··-__ ... .,_ , .... -----··-------·---·· -·····-·--···-- \.n YUKON GROVE SUBDIVISION, FILING NO. 1 A PARCEL OF LAND LOCATED IN THE NW 1/4 OF SECTION 26. T 3S R 69W OF THE 6TH PM CITY OFWHEAT RIDGE COUNTY OF JEFFERSON. STATE OF COLORADO SHEET 03 OF 03 ~-...... .,-----·--------·----·· CITY OF 'MiEAT RIDGE PUBUCWORKS DATE 01/2212015 RECEIVED 01/2212015 EXHIBIT C CITY OF WHEAT RIDGE PUBLIC WORKS. ENGINEERING APPROVED FOR: 2nd Submittal YUKON GROVE SUBDMSION ODRAINAGE O SIDEWN.J( I I I MARTIN I MARTIN Client: YUKON GROVE, LLC ·BILL FRITZ No.. Arri .,._,.of pnco pr-~ pr~ C<»>l 0t COI'lll\letoon to sis renclere4 by MARn~ MARnN fep,-e<~ef'!l ... be:l\ ~ •nd art futf'IISI'ted tor 9ltMf'8 QUIOatKe MA.Rl'IN1MARTIN ,. ..... no ,....,.yolptlf\tH t•llttt""t•M<I 0t-0010 h accncyol -.n .,._,. U ....,.,_., 10 t>d Ot-COli lttmNo lltm Dncrlptlon SITE CLEARING I CltAAING AND GRUBBlNG 2 POTHOLING EROSION CONTROL 3 SILT FENCE 4 CONCRETE WASHOUT STRUCTURE 5 VEHICLE rRACI<ING CONTROL 6 STABILIZED STAGING AREA 7 INLET PROTECTION 8 TEMPORARY SEEDING 9 SEDIMENT CONTROL LOG 10 SVRFACE ROUGHENING II ROCK SOCKS 12 OUTLET PROTECTION EARTHWORK 13 SITE GRADING FRONTAGE IMPROVEMENTS 14 ASPHAlT 15 CURB ~ GUTTER 16 SIDEWAlK 17 CURB RAMPS ROAD IMPROVEMENTS 18 ASPHALT 19 AGGREGATE BASE COURSE 20 CURB~ GUTTER 21 SIDEWALK STORM SEWER 22 \2 INCH RCP CLASS Ill 23 15 INCH PVC (To Roc:J<y Min 01teh) 24 18 INCH RCP CLASS Ill 26 STORM SEWER MANHOLE 26 WHEAT RIDGE SINGLE COMBINATION INLET 27 WHEAT RIDGE TRIPLE COMBINATION INLET 28 OUTLET STRUCTURE 29 CONNECT TO EX 32NO STORM INLET 30 CONCRETE TRICKLE CHANNEL 31 24" NYLOPLAST INLET 32 CAST-IN-PLACE CONCRETE WAll SANITARY MAIN 33 8-IN PVC SEWER PIPE 34 4·FT DIA SSMH 35 CONNECT TO 32NO AVE SEWER 36 4-PVC SEWER SERVICE MISC CONSTRUCTION ITEMS 37 CONSTRUCTION SURVEY STAKING 38 MOBILIZATION 39 TEMP CONSTRUCTION FENCING Rtmart<•' ""'Cl.ate 1·'22/'20'5 11 06AM Units LS LS LF EA EA EA EA LS LF SY EA SY LS TN LF SY EA TN TN LF SY LF LF LF EA EA EA EA EA LF EA SF LF EA EA LF LS LS LF 0 CURB & GUTTER OSTRfET JZI MISCELLANEOUS 0 PLAT COMMENT -.. tnao-•C001ht- Date: 22-Jen-15 Job No.: 13 0606 Prep. By: MAT CAM Ckd. By: MDT .t.2 . .t44c CML ENGINEER • ...... 011Jl/J01f ~T£ SUBJECT TO FIELD INSP£CTIOHS Quantity Unit Price Item Cost I s 10.00000 $ 10.00000 I s 80000 $ 80000 1515 s 400 s 6,06000 I s 1 50000 $ 1,500 00 I s 2 200 00 s 2.200 00 I s HOOOO s 4,50000 8 s 16500 $ 1.320 00 I $ 3.00000 $ 300000 950 $ 200 $ 190000 1250 s 200 s 2.500 00 21 $ 1500 $ 31500 10 s 6000 s 60000 \ $ 7.500 00 s 7500 00 24 s 95 00 $ 2,280 00 54 $ 3000 s 1.620 00 30 s 4500 s 1,350 00 2 $ 1 000 00 s 2.00000 690 $ 9500 $ 65.55000 988 s 2000 $ 19.76000 1722 s 3000 $ 51.66000 781 s 4500 $ 35.14500 39 s 6500 $ 2,535 00 61 s 6500 s 3,965.00 259 $ 75.00 s 19,425 00 2 $ 4.000 00 $ 8000.00 2 s 3,000 00 $ 8,000.00 2 s 600000 s 12.000 00 2 s 10.000 00 $ 2000000 I $ 5.00000 s 5.00000 69 s 4500 s 3.10500 I s I 50000 s 1.50000 1599 s 4000 $ 63.96000 784 $ 6000 s 47 040.00 5 s 4.00000 $ 20.00000 1 s I 000.00 $ 1,000.00 668 $ 2000 s 13,360 00 I $ 25.00000 s 25,000.00 I $ 5.000.00 s 5,00000 250 $ 1000 s 2.50000 Cost of Items: s 480.95000 25"!. City Contlnoencv S 12023700 Total Cost: $ 601,187.00 Page 1 or 1