HomeMy WebLinkAboutWalgreens at Maple GroveSUBDIVISION IMPROVEMENT AGREEMENT
THIS AGREEMENT made this 22nd of February , 2002 by and between
the CITY OF WHEAT RIDGE, COLORADO, a home rule municipal corporation (the "City "),
and Net Lease Development, LLC (the "Developer "), together referred to as the
"Parties"
RECITALS.
The Developer is the owner of certain real property located in the City of Wheat t
�p Ridge, which is more particularly described in Exhibit A if applicable and made a part `
hereof (the "Property "), commonly known as Walgreens Development at the SE corner of
�i 32 "d Avenue and Youngfield Wheat Ridge CO 80033
On November 26 2001 the City Council of the City of Wheat Ridge, after holding all
required public hearings, approved the final plat for the Property titled
Walgreens at Maple Grove Subdivision No. 1 A copy of the Final Plat is attached hereto
as Exhibit B and incorporated herein
The approvals cited above are contingent upon the express condition that all duties
created by this Agreement be faithfully performed by the Developer
AGREEMENT
NOW, therefore, for and in consideration of the mutual promises and covenants
contained herein the sufficiencv of which are mutually acknowledged, the parties hereto
agree as follows
1 Purpose The purpose of this Agreement is to set forth the terms, conditions,
and fees to be paid by the Developer upon subdivision of the Property All conditions
contained herein are in addition to any and all requirements of the City of Wheat Ridge
Subdivision Ordinance and Zoning Ordinance, the City of Wheat Ridge Charter, any and
all state statutes, and any other sections of the City of Wheat Ridge Municipal Code and
are not intended to supersede any requirements contained therein
2 Other Requirements None
3 Fees The Developer hereby agrees to pay City Development Review fees
to the City for engineering, hydrological, surveying, legal, and other services rendered in
connection with the review of the subdivision of the Property
4 Title Policy A title commitment for the Property has been provided to the
City
5 Breach by the Developer the City's Remedies In the event of a breach of
any of the terms and conditions of this Agreement by the Developer, the City Council shall
be notified immediately and the City may take such action as permitted and /or authorized
by law, this Agreement, or the ordinances and Charter of the City as the City deems
necessary to protect the public health, safety and welfare, to protect lot buyers and
builders, and to protect the citizens of the City from hardship and undue risk. These
SUBDIVISION IMPROVEMENT AGREEMENT 1198
RECErTION NO.
E; f - FE
e iii:i�_,:FE:GE:: G!)
I:F.I.uRDF1 .1:A J:.FFF:P'n N 000NTT l_I]L0RAD0
remedies include, but are not limited to
(a) The refusal to issue any building permit or certificate of occupancy;
(b) The revocation of any building permit previously issued under which
construction directly related to such building permit has not commenced,
except a building previously issued to a third party,
(c) A demand that the security given for the completion of the Public
Improvements be paid or honored, or
(d) Any other remedy available at law or in equity
Unless necessary to protect the immediate health, safety and welfare of the City or to
protect the City's interest with regard to security given for the completion of the Public
Improvements, the City shall provide the Developer thirty (30) days written notice of its
intent to take any action under this paragraph during which thirty day period the Developer
may cure the breach described in the notice
6 Public Improvements and Warranty All public storm sewer lines, drainage
structures, paved streets including curb, gutter and sidewalk, and necessary
appurtenances as shown on the subdivision plat and the associated construction
documents, if any (the "Public Improvements" or "Improvements ") as approved by the
Director of Public Works (herein after "Director ") or designee of the City, shall be installed
and completed at the expense of the Developer within the time frames set forth on
Exhibit C The Public Improvements required by this Agreement and shown on the
construction documents approved by the Director of Public Works of the City, the time
frames for construction of the Improvements and the itemized costs of these Improvements
are set forth on Exhibit C if applicable All Public Improvements covered by this
Agreement shall be made in accordance with the construction documents drawn according
to regulations and construction standards for such improvement and approved by the
Director of Public Works of the City It is understood by the Parties that the description of
the Public Improvements may be general in nature, and that reasonable modifications of
the scope, nature, costs, and similar aspects of the Public Improvements may be
necessary to secure final approval of the Public Improvements The quantities and
locations for the Public Improvements are based on information that was available at the
time of approval of the Final Plat.
The Developer shall warrant any and all Public Improvements which are conveyed
to the City pursuant to this Agreement for a period of two (2) years from the date the City's
Director of Public Works certifies that the same conform with specifications approved by
the City Specifically, but not byway of limitation, the Developer shall warrant the following
(a) That the title conveyed shall be marketable and its transfer rightful,
(b) Any and all facilities conveyed shall be free from any security interest or
other lien or encumbrance, and
(c) Any and all facilities so conveyed shall be free of defects in materials or
workmanship for a period of two (2) years as stated above
(d) To the degree the Developer is required to install and maintain landscaping
SUBDIVISION IMPROVEMENT AGREEMENT 1/93
on public or private property, it is the obligation of Developer to maintain the
required landscaping for two (2) growing season(s)
The City will finally accept for maintenance all Public Improvements after the
warranty period has expired provided all warranty work has been completed The City shall
accept for snow removal purposes only, all dedicated public streets after the City issues
the first certificate of occupancy
7 Reserved.
8 Observation, Inspection and Testing The City shall have the right to require
reasonable engineering observations and testing at the Developer's expense Observation
and testing, acquiescence in, or approval by any engineering inspector of the construction
of physical facilities at any particular time shall not constitute the approval by the City of
any portion of the construction of such Public Improvements Such approval shall be made
by the City, only after completion of construction and in the manner hereinafter set forth
The Director is designated by the City to exercise authority on its behalf under this
Agreement and to see that this Agreement is performed according to its terms Work
under this Agreement may, without cost or claim against the City, be suspended by the
Director for substantial cause
The Director shall, within a reasonable time after presentation, make decisions in
writing on all claims of Developer and on all other matters relating to the execution and
progress of the work or the interpretation of this Agreement, the master plan and
specifications All such decisions of the Director shall be final
The Director shall make all determinations of amounts and quantities of work
performed hereunder To assist him in this work Developer shall make available for
inspection any records kept by Developer with respect to all work required by Exhibit C
The Director and his authorized representatives shall have free access to the work
at all times, and Developer shall furnish them with facilities for ascertaining whether the
work being performed, or the work which has been completed, is in accordance with the
requirements of the Agreement.
The Directorwill make periodic observations of construction (sometimes commonly
referred to as "supervision ") The purpose of these observations and construction checking
is to determine the progress of the work and to see if the work is being performed in
accordance with the plans and specifications He will in noway be responsible for how the
work is performed, safety in, on, or about the job site, methods of performance, or
timeliness in the performance of the work.
Inspectors maybe appointed to inspect materials used and work done Inspections
may extend to all or any part of the work and to the preparation or manufacture of the
materials to be used The inspectors will not be authorized to alter the provisions of this
Agreement or any specifications or to act as foreman for Developer The Inspector will
have authority to reject defective materials and to suspend any work that is being done
improperly, subject to the final decision of the Director
SUBDIVISION IMPROVEMENT AGREEMENT 1/98 -?-
9 Completion of Public Improvements The obligations of the Developer
provided for in paragraph 6 of this Agreement, including the inspections hereof, shall be
performed on or before September 30, 2002 , and proper application for acceptance
of the Public Improvements shall be made on or before such date Upon completion of
construction by the Developer of such Improvements, the City's Director of Public Works
or designee, shall inspect the Improvements and certify with specificity its conformity or
lack thereof to the City's specifications The Developer shall make all corrections
necessary to bring the Improvements into conformity with the City's specifications Once
approved by the City's Director of Public Works, the City shall accept said Improvements
upon conveyance, provided, however the City shall not be obligated to accept the Public
Improvements until the actual costs described in this Agreement are paid in full by the
Developer
10 Protection Developer, at its expense, shall continuously maintain adequate
protection of all Improvements from damage prior to acceptance by the City and shall
protect the City's property from injury and loss arising in connection with this Agreement.
Developer shall make good any such damage, Injury or loss except such as may be
caused directly by authorized agents or employees of the City Developer shall adequately
protect adjacent property and shall provide and maintain all passageways, guard fences,
lights and other facilities for protection required by public authority or local conditions
Developer shall be responsible for damage to any public and private property on
and adjacent to the site of Developer's Improvements caused by negligent or willful acts
of Developer, its agents or subcontractors Developer shall take all reasonable effort
necessary to prevent damage to pipes, conduits, and other underground structures and
to overhead wires, and to water quality Developer shall protect carefully from disturbance
or damage all land monuments and property marks until an authorized agent of the City
has witnessed or otherwise referenced their location, and shall not remove them until
directed When any director indirect damage or injury is done to public or private property
by or on account of any act, omission, neglect or misconduct in the construction of
Improvements, or in consequence of the non - execution thereof on his part, such damaged
property shall be restored by Developer at its own expense to a condition similar or equal
to that existing before such damage or injury
Developer shall at all times, whether or not so specifically directed by the Director,
take necessary precautions to insure the protection of the public Developer shall furnish,
erect and maintain, at its own expense, all necessary barricades, suitable and sufficient
red lights, construction signs, provide a sufficient number of watchmen, and take all
necessary precautions for the protection of the work and safety of the public through or
around his construction operations as Developer and the Director shall deem reasonably
necessary
11 Related Costs - Public Improvements The Developer shall provide all
necessary engineering designs, surveys, field surveys, testing and incidental services
related to the construction of the Public Improvements at Its sole cost and expense,
including final drainage study letter certified accurate by a professional engineer registered
in the State of Colorado
12 Improvements to be the Property of the City All Public Improvements for
SUBDIVISION IMPROVEMENT AGREEMENT 1198 -4-
roads, concrete curb and gutters, public storm sewers and public drainage improvements
accepted by the City shall be dedicated to the City and warranted for a period of twenty -
four (24) months following acceptance by the City, as provided above
13 Performance Guarantee In order to secure the construction and installation
of the Public Improvements the Developer shall furnish the City, at the Developer's
expense, with the Performance Guarantee described herein The Performance Guarantee
provided by the Developer shall be an irrevocable letter of credit or a cash deposit
simultaneous with execution hereof in which the City is designated as beneficiary, for one
hundred twenty -five percent (125 %) of the estimated costs of the Public Improvements to
be constructed and installed as set forth in Exhibit C, if applicable to secure the
performance and completion of the Public Improvements as required by Section 26 -413
of the Wheat Ridge Subdivision Regulations The Developer agrees that approval of this
Agreement by the City is contingent upon the Developer's provision of an irrevocable letter
of credit or cash deposit to the City within ninety (90) days of the execution of this
Agreement in the amount and form provided herein Failure of the Developer to provide,
an irrevocable letter of credit or cash deposit to the City in the manner provided herein shall
negate the City's approval of this Agreement. Letters of credit shall be substantially in the
form and content set forth in Exhibit D, if applicable, and shall be subject to the review and
approval of the City Attorney The Developer shall not start any construction of any public
or private improvement on the Property including, but not limited to, staking, earth work,
overlot grading or the erection of any structure, temporary or otherwise, until the City has
received and approved the irrevocable letter of credit or cash deposit.
The estimated costs of the Public Improvements shall be a figure mutually agreed
upon by the Developer and the City's Director of Public Works, as set forth in Exhibit C if
applicable If, however, they are unable to agree, the Director of Public Works' estimate
shall govern after giving consideration to information provided by the Developer including,
but not limited to, construction contracts and engineering estimates The purpose of the
cost estimate is solely to determine the amount of security No representations are made
as to the accuracy of these estimates, and the Developer agrees to pay the actual costs
of all such Public Improvements
The estimated costs of the Public Improvements may increase in the future
Accordingly, the City reserves the right to review and adjust the cost estimate on an annual
basis If the City adjusts the cost estimate for the Public Improvements, the City shall give
written notice to the Developer The Developer shall, within thirty (30) days after receipt
of said written notice, provide the City with a new or amended letter of credit or cash
deposit in the amount of the adjusted cost estimates If the Developer refuses or fails to
so provide the City with a new or amended letter of credit or cash deposit, the City may
exercise the remedies provided for in this Agreement; provided, however, that prior to
increasing the amount of additional security required, the City shall give credit to the
Developer for all required Public Improvements which have actually been completed so
that the amount of security required at all time shall relate to the cost of required Public
Improvements not yet constructed
In the event the Public Improvements are not constructed or completed within the
period of time specified by paragraph 9 of this Agreement or a written extension of time
mutually agreed upon the parties to this Agreement, the City may draw on the letter of
SUBDIVISION IMPROVEMENT AGREEMENT 1 '98
credit or cash deposit to complete the Public Improvements called for in this Agreement.
In the event the letter of credit is to expire within fourteen (14) calendar days and the
Developer has not yet provided a satisfactory replacement, the City may draw on the letter
of credit and either hold such funds as security for performance of this Agreement or spend
such funds to finish Public Improvements or correct problems with the Public
Improvements as the City deems appropriate
Upon completion of performance of such improvements, conditions and
requirements within the required time, the Developer shall issue an irrevocable letter of
credit or cash deposit to the City in the amount of twenty -five percent (25 %) of the total
cost of construction and installation of the Public Improvements, to be held by the City
during the warranty period If the Public Improvements are not completed within the
required time, the monies may be used to complete the improvements Upon completion
of the Public Improvements, the City shall release the letter of credit or cash deposit with
the exception of the warranty deposit described above
14 Indemnification The Developer shall indemnify and hold harmless the City
and its officers, employees, agents or servants from any and all suits, actions, and claims
of every nature and description caused by, arising from or on account of this Agreement
any act or omission of the Developer, or of any other person or entity for whose act or
omission the Developer is liable, with respect to the Public Improvements, and the
Developer shall pay any and all judgments rendered against the City as a result of any suit,
action, or claim, together with all reasonable expenses and attorney's fees and costs
incurred by the City in defending any such suit, action or claim
15 Waiver of Defects In executing this Agreement, the Developer waives all
objections it may have concerning defects, if any, in the formalities whereby it is executed,
or concerning the power of the City to impose conditions on the Developer as set forth
herein, and concerning the procedure, substance, and form of the ordinances or
resolutions adopting this Agreement.
16 Third Party Beneficiaries There are and shall be no third party beneficiaries
to this Agreement.
17 Modifications This instrument embodies the whole agreement of the Parties
There are no promises, terms, conditions, or obligations other than those contained herein,
and this Agreement shall supersede all previous communications, representations, or
agreements, either verbal or written, between the parties. There shall be no modification
of this Agreement except in writing, executed with the same formalities as this instrument.
Subject to the conditions precedent herein, this Agreement may be enforced in any court
of competent jurisdiction
18 Release of Liability It is expressly understood that the City cannot be legally
bound by the representations of any of its agents or their designees except in accordance
with the City of Wheat Ridge Code of Ordinances and the laws of the State of Colorado
19 Captions The captions to this Agreement are inserted only for the purpose
of convenient reference and in no way define, limit, or prescribe the scope or intent of this
Agreement or any part thereof
SUBDIVISION IMPROVEMENT AGREEMENT 1198 -6-
20 Binding Effect This Agreement shall be binding upon and inure to the benefit
of the parties hereto and their respective heirs, successors, and assigns as the case may
be
21 No Waiver No waiver of any of the provisions of this Agreement shall be
deemed or constitute a waiver of any other provisions herein, nor shall such waiver
constitute a continuing waiver unless otherwise expressly provided, nor shall the waiver of
any default hereunder be deemed a waiver of any subsequent default hereunder
22 Invalid Provision If any provision of this Agreement shall be determined to
be void by any court of competent jurisdiction, then such determination shall not affect any
other provision hereof, all of the other provisions shall remain in full force and effect. It is
the intention of the Parties that if any provision of this Agreement is capable of two
constructions, one of which would render the provision void, and the other which would
render the provision valid, then the provision shall have the meaning which renders it valid
23 Governing Law The laws of the State of Colorado shall govern the validity,
performance and enforcement of this Agreement. Should either party institute legal suit
or action for enforcement of any obligation contained herein, venue of such suit or action
shall be in Jefferson County, Colorado
24 Attorneys Fees Should this Agreement become the subject of litigation to
resolve a claim of default of performance or payment by the Developer and a court of
competent jurisdiction finds in favor of the City, the Developer shall pay the City's attorney's
fees and court costs
25 Notice All notices required under this Agreement shall be in writing and shall
be hand delivered or sent by registered or certified mail, return receipt requested, postage
prepaid, to the addresses of the parties herein set forth All notices so given shall be
considered effective seventy -two (72) hours after deposit in the United States mail with the
proper address asset forth below Either party by notice so given may change the address
to which future notices shall be sent.
Notice to Developer Net Lease Development LLC
50 S. 6 "' Street #1480
Minneapolis MN 55402
612- 313 -2500
Notice to City -
irector of Public Works
7500 West 29` Avenue
Wheat Ridge, CO 80215
26 Force Majeure Whenever the Developer is required to complete the
construction, repair, or replacement of Public Improvements by an agreed deadline, the
Developer shall be entitled to an extension of time equal to a delay in completing the
foregoing due to unforeseeable causes beyond the control and without the fault or
negligence of the Developer 4 ncluding, but not restricted to, acts o,`. Gcd, weather
Sjffi` i NT ti6W i4b %N6 )NGREEMENT 1198 _7
27 Assignment or Assignments There shall be no transfer or assignment of any
of the rights or obligations of the Developer under this Agreement without the prior written
approval of the City
28 Recording of Agreement This Agreement shall be recorded in the real estate
records of Jefferson County and shall be a covenant running with the Property in order to
put prospective purchasers or other Interested parties on notice as to the terms and
provisions hereof Upon completion of the obligations imposed by this agreement,
including the running of all warranty periods, either party may terminate this agreement and
file such instruments as necessary to memorialize such completion and to remove the
agreement as an encumberance of the property in the public records The parties shall c�
cooperate with each other to this end
29 Title and Authoritv The Developer, Net Lease Development, LLC expressly
warrants and represents to the City that it is the record owner of the property constituting
the Property and further represents and warrants, together with the undersigned
individual(s) that the undersigned individual(s) has or have full power and authority to enter
into this Subdivision Improvement Agreement. The Developer and the undersigned
individual(s) understand that the City is relying on such representations and warranties in
entering into this Agreement.
SUBDIVISION IMPROVEMENT AGREEMENT 1198 -8-
WHEREFORE, the parties hereto have executed this Agreement on the day and
year first above written
ATTEST
Wanda Sang, City Ctdrk
CITY OF WHEAT RIDGE, COLORADO
t _
retchen Cerveny, Mayor
DEVELOPER
Net Lease Development LLC
j
Allison F Kern, Vice Manager
STATE OF
ss
COUNTY OF / /(�` / /j,!< )
The foregoing Instrument w acknowledged before me this day of
)! t�f 2002, by - r/rz T : , as
/l of
Witness my hand and official seal
E KEI i. 7 BESSEN
,W�� NUTAF� MINNESOTA
M9 Ca Jan31 2006
iy
My commission expires
Notar ublic
(SEAL)
SUBDIVISION IMPROVEMENT AGREEMENT 1/98 -�>-
EXHIBIT A
Lot 1, Wal;reens at Maple Grove Subdivision Filing No 1, City of Wheat Ridge, County
of Jefferson, State of Colorado
16
5
k
F �f - C2 n -
WALGREENS AT MAPLE G OV
A RESUBDMSION OF A PART OF TRACT A. RESUB
TOGETHER WITH A PART OF AND SITUATED IN THE SW 1,
CITY OF WHEAT RIDGE, COUNTY OF
SHEET 1 t
r , 1
4
q twE s,l 1/4 m,Gl a. WEST 32ND AVENUE
RI m
.X. R OF 1ME TI P.LL -o.w. W+WS) TA R. OF t
(faww ��z wuwlw.l w m tIN Po'A° a , arods w
u No. ,� m w P/HGE sen
M_BYa'%VE 1322.4r cm c; MOLE BfIWNCS SITIFl1 WRIN lK YF n1E Ic , a O[ M w , ar SF+.l1oN a. T. P (Yw� K m_a)11 FY. b. , ,2 w MM'E e
- --- WIFAT )— '- - --- - �r - -- - --- -- ---- ,``�---
d690'18�38
E
ffiaA 29'16" .., )(CEITM)11 R =44.00' 1 '�b:EO i 10 .50 18 (mac lav -rc.a 69,35 1 (mac nN�sa) i IY P"- �aa4•scslS)
Ctq- NH'19'SrE 1 1
szs9• 1 N89'29'16'E 153.46'
62b
49' _ II I _t ' % �l - F__I
NE ]IYJS RA.4. 1 III m' UhlfY //� I I - " nlbUC SEN
uEnrAr,oN 10.00 I m 1 ts anatl4x tKFwfMrJ IbbA...P 1 u 1 corvzl. cur
1 (ATME IIQ.W. G6MI.iAN J11N4 10' F.O.w. OmG,gN a ' ; F44J1FLLt
lq BF OEDIG1fD f �wt,F� MO S fASE,pIf a _' I (0.E' 94MV
' ,Ar s PFOEV¢tlrs) (vanN¢ 0.o.w. w° F/SFYFNf i uI, a l
4, . ruw° cwlsF2ra wu ro s oEtNrwtm slwrzl Ier : IIR t I $� II 1 1
fW MCtc I%wNR 0.FLEW(W$) I 11' 1 I I I I I
I oA4T1,AAaw a g Inam FK416l1f i 8I I'� 1 I � .
1 I CwAIWf9 xtla1N911
tl! I I 1 11 1 1
III (1� III 1 1 I m j I 4 I
y 1 I MIK 0' 0.0.W. pFIMfAl10N x$' IG(ESS E.t �f 11�� I 1 I t1 1 1 I
KI Nq'Y' FISELFMT ( PLC NxNMx) II 1 I ' `� I _1______
fU11Rf RO.w. NG E\SFlglr (PEC. �`0%69)O) 11 1 1 I I I I I
'6� tat aE oEAC.ao s/wlol 3m x
PFDC\'ElAP4) I 1
il' I 1 1/IaJI'( ----------------- 1 t 1
$I III -- 1 1 I ( I
�1 Y I -y 1 1
1
�� 11' b •. 1 1 I
e422Z(.N/Ip lo• PUwK sEIM1X£- I1� 1 � eiP2a tl1W J 1 1
( N 205 FKF 2) Q
«I O atOia�rt. (al:.xas: - rcxs) I , 1
W I I
. � I•'1 m g 1 1 I
"IN S
el$ III 1 1 m N
IQ ' I
Un A la - u - -- - -- +t- - - - - -�
" FIN N I A
11 R' 2
1 1 0
Y y,
(Re EwxwENl I )a��
LOT 1 R W I t
Y (rtFC. /amnc]Jj 1 I Op n I
b 149.74
1 I I I Q I
I R —x' II:CESS flSEllryi r I I I I 1 I
41.0'
1 I
so — oo'T ]I — oo S89'29'18 W 178.55 ' i i 1 I LorA?
I
I I I I 1
1 I
' I I �� 1a1X1U'Im) 8 1 I I I- ErIS11NL 8' a
2 � N'tE`3 6/SFII`Ni I 1 }, FASf llfll
I I g I 1 I
1 I
I I FOI.w9 1 1/2 • K6ala11A1 CIP— _� `\ 1 igW w° ,1Lt
I a CKC10./9FD a W11kA if `\
I I CCpIFT w w
A- 111:N/lq �
I f dY IIVG +0. IE) `\\ \` \\ I�wriv
I ql I T'1 1
Z
i
1 Ivl I ♦ 1
i
I I 0 • \ '\ h i
I E%CO'TION $ Cawem ,e'
7 (axc,m,•.P9.an) o `T 1 I ""cawwU
, )
I 8 rsws I IP . /PGNOL q
t i M r _ _t. _. ._� .
I I I &I H I I 7;EZ6 700fv 1
20.00 I I lYYl4'ItiRR.1�LlAf6YlY1' I O E_�_1.__.__._J 1 ,oa
45 21.00' _ 92:__
I - Sb9'29'16'W 104.45
Q LQ'E__.2193i'_____s ________
- -'- - "- tranw oC�w , R - w&wr un Faw a
0 9 30 60 I 1 �auxxtr %mMrt� I�o.tnw kYE �_il
SCALE 1' b' l0/11ar aw1aE truer Lori? °t1oOm i
I ; , �gAp;'pcIIVYEBUWFII¢li�t[[Y.f'1 i i
Rt?IpY4l2 R- 120WA2 { M2p1Nt7
MUN
w u In new
Mlam Norm wNaawsF P 9EPAREO F
119 Itr daavo w M CASE HISTORY Service
° �9�n Prc�w oa lt*x csE No.:, � P••°,
ell: 1
•' -��ev SON -77x3¢
'UBDIVIBION
FILING NO. 1
i OF MAPLE GROVE VILLAGE, BLOCK 1,
SECTION 29, US., R.69W., OF THE 6TH P.M.
;ON, STATE OF COLORADO
-0
Dt3�E0
SUSAN R. HETDTADE FAA. SUSAN MITI -ER. AS SOLE SIK`OESSOR TRUSTEE UNDER
THE WILL DATED WY 11. 1 %7 OF CON" R DECKER DECEASED. DRAKE REAL
ESTATE SEANCES. LLC APO SEWS Bfl`EIDMEENT OF COLORADO, NC. WINS THE
OWNERS OF A PART OF TRACT A. RESAOM6ION OF MAPLE CROVE WLWL BLOCK 1.
TOGETEIER WHt A PART OF ARID SmIASFD N IIIE SW 1/4 OF SEC1gI1 N, 7,3S,
FLOW.. OF RTE 6M P.M., CRY OF W1EAT WQE. COUMI'T OF JEFFERSON. STATE 0i
COLORADO. WORE P/RTKL y DESCRIBED AS FOLLOAS
HE
STATE DF r o Ao /�
COUNTY S
TY DF r,.6RF,.Y„
' OE _D. . AA j _ L ACK TfnS 2Lq DAY
al D MAYVITr19�6t OOFF CWMy 0. BECIE0. DE GSED AS O
WITNESS MY NMEO AND OFFC��IW)_SN"R.����''
MY COIJML'SIOH EXP66�yLQ
V
! R LOT 1
DRAKE ES'M7E LC A COLORADO .UA{iBRY
NA
A'y SLATE OF
I CdNRY OF 1�CAAFer )A
THE FIERCER W..iMlMEM WAS A4KIMUEEE BFEDRE ME lIK � MT
OF A.D. 200 DY .9N i4NSER a MANAGER OF
D ATE SE ES. LLC• A COLORADO COMPANY
As OWNM
WRNE66 MY H NO O AL SEAL
,y
W COMMISSION EXPRES'
� ' PTY. W�
Pa �.
R„ Y
AYES MAT 2
nr
AS SO R NEAR F. SUSAN MW1ER
WI SOLE D MAY 1 IN7 OF F CONRA 7FE
WILL DATED WT 1, 1I6) O CONRM R. DECKER. DECEASED.
STATE OF C.
COUNTY OF 1lueJCJaA
3n
TIE r, IISIRULHENI W!6 A!]OgWLF BEFORE LE THLS 224 DAY
ID 20Q BY SLSAN R. HERIINX
FXk 53 MILLER AS SCCE AlIXI55DR TRUSTEE UMFA THE W11
DATED MAY 11. 1567 OF CDWAD R DECKER, DECEASED AS OMNEY,-
WITNESS MY HAND AND OFFTCML SEAL
MY COLHM6SgN E XMM W/1
�l�IJSAO �ad�
MITI Y F.
ucm.
EEAAW" II= ON TN6 SURVEY ARE DASED ON THE ASSLAO'V ON TN,T TIME NORM LINE OF SECTION Of W L1Y V4 OF SW 1 • Wk0 NDO E 87'2 �I!•E . (W% LK 'WK1., IFTH P.M. Off
RWDCVE
DATUM) AS REFERpq(O ,WO aDJNDED W THE IH0IRNEMS 61gWW HEREDHL
W GRAPHIC PLORND ONLY. THE WAArT PROPERTY S SRWTED WMdi 1019 C
DEFNED AS: (N THIS Q�SE) AREAS OF MINIMAL FLDDO D 1N0' A 6 NW SNUOM N A
SPEDYLL FLOW HYIAib AREA ACNRDR6 IO THE ROOD INSURANCE 1 WP 110M)
CONM� PAEL W. 0660)0. DD06 C aE~ A REVISION NUE OF F�BR�R'1 a, im.
ND FIELD WORK OR OFFICE aauLw*XS WEPT PEiBORMEV BY THIS SMNEAWI 70 VFPIY
TANS DETEAMNAROH
THE ACOMT EASEME/FE WTIICII SEEMS TIME CELL TOWER SKA L BE REIOCARD $0 AS
"TO PRO" CONTINUOUS ACCESS 79 TIME LESSEES,
ACC�,RDR1G 70 COLORADO MAW YOU MUST COMMENCE ANY LECiL ACTION
RASED UPON ANY DEf N THIS SIR.EY WMW IhOFf IEW AFTER
YOU iWST DISCDlfIE SUCH DEFECT. N ND EVEM, MAY ANY ACTION BASED
UPON ANY DEFECT N THIS SUREY BE COMMENCED MORE TARN 7EV IEWM
FTKW THE TAX OF ME CERWr.4W N SNOWN HEREON,
ANY PERSON WHO IODWNOLY REIAONS, ALTERS OR DEFACES AMY PUSUC
LANtU SUR"TY MONUMENT OR LAND BOUNNANY MONU4"li T OR ACCESSORI'
COMMITS A CLASS i YWLT() N�ENSANDR PMRSU4NT 10 STATE STATUTE
1D -4306, OF INE COI1RUNi0 0.r SED STAIM.
TIFFS 6 TD COMFY W YIIRWI PLAT HAS BEEN APPROND SY THE
PINNNO COMMISSION Of THE EC CITY ] OF WREN RIDGE. COLORADO,
,;a s.y f rao a�am•'•'a<,�..•..r. a
I, NETT L ALUM A PROFES$KNAL IAMB SMREY9R REER6'IFREO N
THE STAFE OF 0SVMDp AD6, CERTIFY IM ON *0 7TH DAY OF S&PWM8M
2001, ARS NAT WAS PPEPAAW UINBE W DIRECT WPOWXK AND
TO THE BEST BF PROK mm AND BELIES 5
ACL%RW. Y
PRDFESSTBK LS. GOAT-,
rl FOR AHB ON
E � " ,
IFS" 6 W CERTIFY 710T THE CITY OF `MEAT RACE, CCIDRMO. BY ;j
Frs CITY COUNCW ND CH TI I(,ff — � DAY a
�Y 200L_. ADOPT " APPROVE THE WITHIN .•
MAARg F IBEON WOE E 631 a., ar
yk�GFl �t THE DEII A�2 2 r�.� ' �iPd 7'TthW V`
r�
ATTE
CITY
IXERK AMO RFLYWNV, FFTFTMAIT
SLATE OF COLORADO )SS
CWNTY OF JEFFERSON) A �
IIIS 000I1MEHT ACCEMED FOR FILING N THE OFFICE OF THE CO MW >fO . ' :i [ _.
LI.ERN RECORDER OF �FFftiRGON COLIJTT AT CgL0E1, COLORADO, Aar'
�.TI S MY (_Y .. 2GSLZ A AA. IN ,. :?,wT_ �.
. P REl,EP7KN N0, -LL IO 4911 ,'..sw 0.' .
A-MER50N COUNTY CLEW AND RECORDER a `J
.. O
0
0
PARCEL DONTANS (MN,N SD AME FEET) LANTS A ICS, MORE OR LESS.
� LET 1
BY .,......- KU..'Y F.x. .M.. -.-) LW'
SUSAN R AE
AS S .ILA 1WS a U N
SOLE D MAY It. TEE NlOFR
Wll DATED MAY 11. 5967 OF COWAD R BEOIRR, OEOFI3�.
'
~0440A21F JVWUROF 7 "1
aWUxr /Of I
, x
f, r
SUSAN R. HERITAGE F.KA. SUSAN MILLER
.- •. Yri'�'
1200 AWAHOE
GODOL COI.oRwO Bowl
l t" ' E F ;y! / . ., o - ,� �!•
[ - .+Fr-
PIDNE: 303 -2T9 -2563
: • _ ?r Ei.�.
y 1
"
AND
Ay.l r T
i l ai
DRAKE REAL ESTATE LUC
SSLRETEE
-p
1200 ~AWE FJLA SUSAN MILLER
CgDEN. COIDR.Yq 6M01
PF10HE: GDS- I]B -TSU
i.. ISM+•! -. � It
••' ...:.. a ]
R
+1 B .
SdREFOI ♦ eAW% JB
)- x ,
• a ..II
aMC.*
BNETT L tL% NS N0. 2]600.
FOR A NG BEHACE 6
a
r� ,. 16G °
_ I.
A Y
1 � N1OIUC � SOITE 126
AUIRORh a7LORADD 19001Z
T P
AYES MAT 2
nr
AS SO R NEAR F. SUSAN MW1ER
WI SOLE D MAY 1 IN7 OF F CONRA 7FE
WILL DATED WT 1, 1I6) O CONRM R. DECKER. DECEASED.
STATE OF C.
COUNTY OF 1lueJCJaA
3n
TIE r, IISIRULHENI W!6 A!]OgWLF BEFORE LE THLS 224 DAY
ID 20Q BY SLSAN R. HERIINX
FXk 53 MILLER AS SCCE AlIXI55DR TRUSTEE UMFA THE W11
DATED MAY 11. 1567 OF CDWAD R DECKER, DECEASED AS OMNEY,-
WITNESS MY HAND AND OFFTCML SEAL
MY COLHM6SgN E XMM W/1
�l�IJSAO �ad�
MITI Y F.
ucm.
EEAAW" II= ON TN6 SURVEY ARE DASED ON THE ASSLAO'V ON TN,T TIME NORM LINE OF SECTION Of W L1Y V4 OF SW 1 • Wk0 NDO E 87'2 �I!•E . (W% LK 'WK1., IFTH P.M. Off
RWDCVE
DATUM) AS REFERpq(O ,WO aDJNDED W THE IH0IRNEMS 61gWW HEREDHL
W GRAPHIC PLORND ONLY. THE WAArT PROPERTY S SRWTED WMdi 1019 C
DEFNED AS: (N THIS Q�SE) AREAS OF MINIMAL FLDDO D 1N0' A 6 NW SNUOM N A
SPEDYLL FLOW HYIAib AREA ACNRDR6 IO THE ROOD INSURANCE 1 WP 110M)
CONM� PAEL W. 0660)0. DD06 C aE~ A REVISION NUE OF F�BR�R'1 a, im.
ND FIELD WORK OR OFFICE aauLw*XS WEPT PEiBORMEV BY THIS SMNEAWI 70 VFPIY
TANS DETEAMNAROH
THE ACOMT EASEME/FE WTIICII SEEMS TIME CELL TOWER SKA L BE REIOCARD $0 AS
"TO PRO" CONTINUOUS ACCESS 79 TIME LESSEES,
ACC�,RDR1G 70 COLORADO MAW YOU MUST COMMENCE ANY LECiL ACTION
RASED UPON ANY DEf N THIS SIR.EY WMW IhOFf IEW AFTER
YOU iWST DISCDlfIE SUCH DEFECT. N ND EVEM, MAY ANY ACTION BASED
UPON ANY DEFECT N THIS SUREY BE COMMENCED MORE TARN 7EV IEWM
FTKW THE TAX OF ME CERWr.4W N SNOWN HEREON,
ANY PERSON WHO IODWNOLY REIAONS, ALTERS OR DEFACES AMY PUSUC
LANtU SUR"TY MONUMENT OR LAND BOUNNANY MONU4"li T OR ACCESSORI'
COMMITS A CLASS i YWLT() N�ENSANDR PMRSU4NT 10 STATE STATUTE
1D -4306, OF INE COI1RUNi0 0.r SED STAIM.
TIFFS 6 TD COMFY W YIIRWI PLAT HAS BEEN APPROND SY THE
PINNNO COMMISSION Of THE EC CITY ] OF WREN RIDGE. COLORADO,
,;a s.y f rao a�am•'•'a<,�..•..r. a
I, NETT L ALUM A PROFES$KNAL IAMB SMREY9R REER6'IFREO N
THE STAFE OF 0SVMDp AD6, CERTIFY IM ON *0 7TH DAY OF S&PWM8M
2001, ARS NAT WAS PPEPAAW UINBE W DIRECT WPOWXK AND
TO THE BEST BF PROK mm AND BELIES 5
ACL%RW. Y
PRDFESSTBK LS. GOAT-,
rl FOR AHB ON
E � " ,
IFS" 6 W CERTIFY 710T THE CITY OF `MEAT RACE, CCIDRMO. BY ;j
Frs CITY COUNCW ND CH TI I(,ff — � DAY a
�Y 200L_. ADOPT " APPROVE THE WITHIN .•
MAARg F IBEON WOE E 631 a., ar
yk�GFl �t THE DEII A�2 2 r�.� ' �iPd 7'TthW V`
r�
ATTE
CITY
IXERK AMO RFLYWNV, FFTFTMAIT
SLATE OF COLORADO )SS
CWNTY OF JEFFERSON) A �
IIIS 000I1MEHT ACCEMED FOR FILING N THE OFFICE OF THE CO MW >fO . ' :i [ _.
LI.ERN RECORDER OF �FFftiRGON COLIJTT AT CgL0E1, COLORADO, Aar'
�.TI S MY (_Y .. 2GSLZ A AA. IN ,. :?,wT_ �.
. P REl,EP7KN N0, -LL IO 4911 ,'..sw 0.' .
A-MER50N COUNTY CLEW AND RECORDER a `J
.. O
0
0
PARCEL DONTANS (MN,N SD AME FEET) LANTS A ICS, MORE OR LESS.
� LET 1
BY .,......- KU..'Y F.x. .M.. -.-) LW'
SUSAN R AE
AS S .ILA 1WS a U N
SOLE D MAY It. TEE NlOFR
Wll DATED MAY 11. 5967 OF COWAD R BEOIRR, OEOFI3�.
EXHIBIT C
WALGREENS AT MAPLE GROVE
Item No Description Unit Quantity Cost ($) Total ($)
West 32nd Avenue
Western Entrance
1 20' Curb Return w/
Handicap Ramp
2 Conc. Apron & Temp Median
3 6" Conc. Vertical
Curb & 2' Gutter
Sub -Total Eastern Entrance. 5920.00
EA. 1 0 120000 120000
L.S 1 0 500000 500000
L.F 22.0 1000 22000
Sub -Total Western Entrance. 6420.00
Page 1 of 2
General:
1
Remove Curb & Gutter
L.F
2000
500
100000
2
Remove 16' Attached Walk
L.F
1500
1000
150000
3
Remove 6' Attached Walk
L.F
200
500
10000
4
Remove Lane Striping
L.F
2200
1000
220000
5
Sawcut Exist. Pavement
L.F
2000
300
60000
6
Lane & Directional Striping
L.S.
1 0
500000
500000
7
5' Detached Conc. Walk
L.F
1000
1000
100000
8
6" Conc. Vertical
Curb & 2' Gutter
L.F
82.0
1000
82000
9
'9" Full Depth Asphalt
S.Y
1280
2000
256000
10
Traffic Control
L.S
1 0
300000
300000
Sub -Total General:
17780.00
'Note. The pavement costs are merely for estimating and
for the Subdivision Agreement
purposes.
A pavement design will need to
be submitted for approval by the City of
Wheat Ridge Engineering Department prior to the start of paving
Eastern Entrance.
1
15' Curb Return w/
2
Handicap Ramp
EA.
2.0
100000
200000
3
8' Conc Crosspan
L.F
560
7000
392000
Western Entrance
1 20' Curb Return w/
Handicap Ramp
2 Conc. Apron & Temp Median
3 6" Conc. Vertical
Curb & 2' Gutter
Sub -Total Eastern Entrance. 5920.00
EA. 1 0 120000 120000
L.S 1 0 500000 500000
L.F 22.0 1000 22000
Sub -Total Western Entrance. 6420.00
Page 1 of 2
EXHIBIT C
WALGREENS AT MAPLE GROVE
Item No.
Description
Unit Quantity Cost ($)
Total ($)
Youngfield Streeet
General:
1
Remove Curb & Gutter
L.F 600 500
30000
2
Remove 4' Attached Walk
L.F 600 500
30000
3
Sawcut Exist. Pavement
L.F 600 300
18000
4
Curb Cut Entry
L.S 1 0 200000
200000
5
6" Conc Vertical
Curb & 2' Gutter
L.F 200 1000
20000
6
6' Attached Conc Walk
L.F 200 1000
20000
7
Traffic Control
L.S 1 0 300000
300000
6180.00
Sub -Total Youngfield Street:
Erosion Control:
1
Vehicle Tracking Control Pad
EA. 1 0 75000
75000
2
Silt Fence
L.F 5800 2.00
116000
3
314" Gravel (Inlet Protection)
T 2.0 3000
6000
Sub -Total Erosion Control.
197000
Sub -Total General:
1778000
Sub -Total Eastern Entrance.
592000
Sub -Total Western Entrance
642000
Sub -Total Youngfield Street:
618000
Sub - Total:
3827000
25% Contingency
956750
Total:
47837.50
Prepared By Engineering Service Company Engineer (
Douglas W Mize D
iy
Page 2 of 2
EXHIBIT D
BTS CONSTRUCTION, LLC
I
�.s,,,��„.',.=
£ �vW�
r a. �.,�pe,.
'��.�.tv?��'. =v
....�? �:z���
„ *����s'r �.... �'.� ,.a'a�.; �.N��:r�.,y,:•:.. €�.� �,.:.a .`mss ..xf..
���