Loading...
HomeMy WebLinkAboutStation SubdivisionII it 'I ii �i iil i ►ii II'i illli i' I I'I JI' I I 'll D S530 ° 2023073924 12107/2023 01:59:32 PM 29 Page(s) \ JEFFERSON COUNTY, Colorado SUBDIVISION IMPROVEMENT AGREEMENT THIS AGREEMENT made this V of OD(le N"&-z� 10 he t t ,�(the "Effective Date") by and between the CITY OF WHEAT RIDGE, COLORADO, a home rule municipal corporation (the "City"), and 4600 Kipling, LLC, a Colorado limited liability company, (the "Developer"), together referred to as the "Parties." RECITALS A. The Developer is the owner of certain real property located in the City of Wheat Ridge, which is more particularly described in Exhibit A and made a part hereof (the "Property"), commonly known as Station Subdivision. B. On May 8, 2023, the City Council of the City of Wheat Ridge, after holding all required public hearings, approved the final plat for the Property titled Station Subdivision (the "Final Plat"). A copy of the Final Plat is attached hereto as Exhibit B and incorporated herein. C. The approvals cited above are contingent upon the express condition that all duties created by this Agreement be faithfully performed by the Developer. AGREEMENT NOW, therefore, for and in consideration of the mutual promises and covenants contained herein, the sufficiency of which are mutually acknowledged, the Parties hereto agree as follows: 1. Purpose. The purpose of this Agreement is to set forth the terms, conditions, and fees to be paid by the Developer upon subdivision of the Property. All conditions contained herein are in addition to any and all requirements of the City of Wheat Ridge Subdivision Ordinance and Zoning Ordinance, the City of Wheat Ridge Charter, any and all state statutes, and any other sections of the City of Wheat Ridge Municipal Code and are not intended to supersede any requirements contai ed therein. 2. Related City Agreements and Approvals. The Property will be subject to future review and approval of site plan(s), civil construction documents, right-of-way permit application(s), site work permit application(s), and building permit application(s). Through such approvals, the City will review and approve the final design any development and Public Improvements related thereto. This Agreement is based on information available at the time of approval of the Final Plat and shall not constitute approval of the Public Improvement designs. The Property is subject to that certain Concept Plan titled "Concept Plan for Kipling Street and 44th Avenue", commonly known as "441h and Kipling Concept Plan", recorded with the Jefferson County Clerk and Recorder under reception number 2021048289. The Property is subject to that certain Declaration of Covenant and Restriction recorded with the Jefferson County Clerk and Recorder under reception number 2021048289 related to mixed use development and a limitation on drive through uses. 3. Fees. The Developer hereby agrees to pay City Development Review fees to the City for engineering, hydrological, surveying, legal, and other services rendered in connection with the review of the subdivision of the Property. 4. Parkland dedication fee -in lieu. Fees in lieu of land dedication shall be calculated pursuant to the formula in Section 26-413 and shall be paid at the time the building permit for any future residential development is issued. 5. Title Policy. Prior to recording of the Final Plat, a title commitment for all those portions of the Property, as well as any other interests in real property (easements, etc.) to be reserved for public purposes or dedicated to the City shall be provided to the City. The title commitment shall show that all such property is or shall be, subsequent to the execution and recording of this Agreement, free and clear of all liens and encumbrances (other than real estate taxes which are not yet due and payable) which would make the dedication or reservation unacceptable as the City determines in its reasonable discretion. The City, in its sole discretion, may accept any dedication regardless of encumbrances. The title policy evidenced by the title commitment shall be provided within thirty (30) days after the recording of th's Agreement, in an amount equal to the fair market value of the property so dedicated or reserved. 6. Breach by the Developer; the City's Remedies. In the event of a breach of any of the terms and conditions of this Agreement by the Developer, the City may take such action as permitted and/or authorized by law, this Agreement, or the ordinances and Charter of the City as the City deems necessary to protect the public health, safety and welfare; to protect lot buyers and builders; and to protect the citizens of the City from hardship and undue risk. These remedies include, but are not limited to: (a) The refusal to issue any building permit or certificate of occupancy; (b) The revocation of any building permit previously issued under which construction directly related to such building permit has not commenced, except a building permit previously issued to a third party, (c) A demand that the security given for the completion of the Public Improvements be paid or honored, or (d) Any other remedy available at law or in equity. Unless necessary to protect the immediate health, safety and welfare of the City or to protect the City's interest with regard to security given for the completion of f;ie Public Improvements, the City shall provide the Developer thirty (30) days written notice of its intent to take any action under this paragraph during which thirty (30) day period the Developer may cure the breach described in the notice. E 5 7. Installation of Public and On -Site Improvements. All storm sewer lines, drainage structures, paved streets, curb, gutter, sidewalk, amenity zones, street and pedestrian lighting, shared access drives, the undergrounding of all overhead utilities, and necessary appurtenances as shown on the subdivision plat and the associated construction documents (the "Improvements") as approved by the City's Community Development Director or designee ("Director"), shall be installed and completed at the expense of the Developer within the timeframes set forth in Section 11 of this Agreement and as outlined in Exhibit C. Improvements shall consist of two categories: 1) "Public Improvements" which refers to all improvements within the City of Wheat Ridge Right -of -Way (and for the purposes of this project the following: water and sanitation lines as shown on the approved construction documents within the Right -of - Way and on private property, all stormwater and water detention infrastructure shown on the approved construction documents) and 2) "On -Site Improvements" which refers to all other infrastructure improvements being made on private property (not in the Right -of -Way or otherwise accepted by the City). The On -Site Improvements may also be referred to as private improvements. The Public Improvements shall be substantially complete, with only such exceptions as shall be approved in advance by the Director in the exercise of his or her sole discretion, prior to the issuance of any Certificate of Occupancy on the Property. On -Site Improvements shall be substantially complete, with only such exceptions as shall be approved in advance by the Director in the exercise of his or her sole discretion, based on the phasing plan outlined in Exhibit C. The itemized costs of the Improvements required by this Agreement and shown on the construction documents approved by the Director are set forth on Exhibit D, with one itemized list for Public Improvements and another itemized list for On -Site Improvements. All Public Improvements covered by this Agreement shall be made in accordance with the construction documents drawn according to regulations and construction standards for such improvement and approved by the Director. It is understood by the Parties that the description of the Public Improvements may be general in nature, and that reasonable modifications of the scope, nature, costs, and similar aspects of the Public Improvements may be necessary to secure final approval of the Public Improvements. The quantities and locations for the Public Improvements are based on information that was available at the time of approval of the Final Plat. Additional Public Improvements may be required, and Developer shall be responsible for submitting construction documents for review of all Public Improvements and/or revisions to the Final Plat approved by the City. Construction in the City Right -of -Way shall be limited to the hours of 7:00 a.m. to 5:00 p.m. Monday through Friday. The Developer may request to perform work in the Right -of -Way outside of these days and/or times, subject to approval from the Public Works Department, and the Developer shall be liable for any overtime payments required by the inspector (per Section 21-53a of the City Code). Section 21-60(5) of the City Code limits work during rush hour on collector and arterial streets, which includes Kipling Street and W. 44th Avenue, for the purposes of this project. Any obstruction of Kipling Street and W. 441h Avenue for construction -related purposes (including but not limited to deliveries to the Property) shall be subject to the same regulations applying to Q construction in the Right -of -Way. Kipling Street construction is also subject to approval by CDOT. Any construction activity on site, including construction of homes, driveways, retaining walls, or demolition, and installation of landscaping, shall be limited to the hours of 7:00 a.m. to 7:00 p.m., per section 5-46 of the City Code. All Public Improvements and On -Site Improvements are subject to the City's review and approval of Right -of -Way, Stormwater Management, Site Work, and Building permits, which may be subject to conditions related to adequate provisions for contractor parking, traffic management, and erosion and dust control. 8. Warranty of Public Improvements. The Developer shall warrant any and all Public Improvements which are conveyed to the City pursuant to this Agreement for a period of two (2) years from the date the Director certifies that the same conforms to the specifications approved by the City (the "Warranty Period"). Specifically, but not by way of limitation, the Developer shall warrant the following: (a) That the title conveyed shall be marketable and its transfer rightful; (b) Any and all Public Improvements conveyed shall be free from any security interest or other lien or encumbrance; and (c) Any and all Public Improvements so conveyed shall be free of defects in materials or workmanship for a period of two (2) years as stated above; and (d) To the degree the Developer is required to install and maintain landscaping on public or private property, it is the obligation of Developer and its successors and assigns, to maintain the required landscaping in perpetuity. The City will finally accept for maintenance all Public Improvements, exclusive of landscaping materials, after the two-year Warranty Period has expired provided all warranty work has been completed. The City shall accept for snow removal purposes only, all dedicated public streets after the City issues the first certificate of occupancy. 9. Reserved. 10. Observation, Inspection and Testing. The City shall have the right to require reasonable engineering observations and testing at the Developer's expense. Observation and testing, acquiescence in, or approval by any engineering inspector of the construction of physical facilities at any particular time shall not constitute the approval by the City of any portion of the construction of such Public Improvements. Such approval shall be made by the City, only after completion of construction and in the manner hereinafter set forth. ll The Director is designated by the City to exercise authority on its behalf under this Agreement and to see that this Agreement is performed according to its terms. Work under this Agreement may, without cost or claim against the City, be suspended by the Director for substantial cause. The Director shall, within a reasonable time after presentation, make decisions in writing on all claims of Developer and on all other matters relating to the execution and progress of the work or the interpretation of this Agreement, the master plan and specifications. All such decisions of the Director shall be final. The Director shall make all determinations of amounts and quantities of work performed hereunder. To assist them in this work Developer shall make available for inspection any records kept by Developer. The Director and their authorized representatives shall have free access to the work at all times, and Developer shall furnish them with facilities for ascertaining whether the work being performed, or the work which has been completed, is in accordance with the requirements of the Agreement. The Director will make periodic observations of construction (sometirr es commonly referred to as "supervision"). The purpose of these observations and construction checking is to determine the progress of the work and to see if the work is being performed in accordance with the plans and specifications. He will in no way be responsible for how the work is performed, safety in, on, or about the job site, methods of performance, or timeliness in the performance of the work. Inspectors may be appointed to inspect materials used and work done. Inspections may extend to all or any part of the work and to the preparation or manufacture of the materials to be used. The inspectors will not be authorized to alter the provisions of this Agreement or any specifications or to act as foreman for Developer. The Inspector will have authority to reject defective materials and to suspend any work that is being done improperly, subject to the final decision of the Director. 11. Completion of Improvements. The obligations of the Developer provided for in Section 7 of this Agreement and Exhibits C and D, including the inspections hereof, shall be performed on or before October 30, 2025, and proper application for acceptance of the Public Improvements shall be made on or before such date. Upon completion of construction by the Developer of such Improvements, the Director, shall inspect the Improvements and certify with specificity its conformity or lack thff reof to the City's specifications. The Developer shall make all corrections necessary to bring the Improvements into conformity with the City's specifications. Once approved by the Director, the City shall accept said Improvements upon conveyance; provided, however, the City shall not be obligated to accept the Public Improvements until the actual costs described in this Agreement are paid in full by the Developer. 5 41 12. Deferred Installation of Landscaping and Financial Guarantee. If a Certificate of Occupancy is requested prior to completion of landscaping and irrigation, an escrow account shall be accepted for the completion of necessary landscaping and irrigation. Said financial guarantee shall be in the amount of one hundred and twenty five percent (125%) of the cost of installation. Escrows shall not be released until all planting and finish materials shown on the approved landscape plan are installed and accepted and the irrigation is installed and functional. The amount of the escrow shall be based on an itemized cost estimate for required landscaping and irrigation. The itemized cost for required landscaping and irrigation shall be accepted at the discretion of the Community Development Director prior to acceptance of the escrow account. Should the required landscaping not be properly installed upon the expiration of the escrow account, the City reserves the right to use such funds to have the required landscaping placed upon the subject premises. Any costs reasonably incurred by the City in excess of the funds provided by the escrow shall be recovered by the City through normal lien proceedings. 13. Protection. Developer, at its expense, shall continuously maintain adequate protection of all Improvements from damage prior to acceptance by the City and shall protect the City's property from injury and loss arising in connection with this Agreement. Developer shall make good any such damage, injury or loss except such as may be caused directly by authorized agents or employees of the City. Developer shall adequately protect adjacent property and shall provide and maintain all passageways, guard fences, lights and other facilities for protection required by public authority or local conditions. Developer shall be responsible for damage to any public and private property on and adjacent to the site of Developer's Improvements caused by negligent or willful acts of Developer, its agents or subcontractors. Developer shall take all reasonable effort necessary to prevent damage to pipes, conduits, and other underground structures and to overhead wires, and to water quality. Developer shall protect carefully from disturbance or damage all land monuments and property marks until an authorized agent of the City has witnessed or otherwise referenced their location, and shall not remove them until directed. When any direct or indirect damage or injury is hone to public or private property by or on account of any act, omission, neglect or misconduct in the construction of Improvements, or in consequence of the non -execution thereof on his or her part, such damaged property shall be restored by Developer at its own expense to a condition similar or equal to that existing before such damage or injury. Developer shall at all times, whether or not so specifically directed by the Director, take necessary precautions to insure the protection of the public. Developer shall furnish, erect and maintain, at its own expense, all necessary barricades, suitable and sufficient red lights, construction signs, provide a sufficient number of watchmen, and take all necessary precautions for the protection of the work and safety of the public through or around the Property's construction operations as Developer and the Director shall deem reasonably necessary. 14. Related Costs - Improvements. The Developer shall provide all necessary engineering designs, surveys, field surveys, testing and incidental services related to the construction of the Improvements at its sole cost and expense, including final drainage study letter certified accurate by a professional engineer registered in the State of Colorado. 15. Improvements to be the Property of the City. All Public Improvements for roads, concrete curb and gutters, public storm sewers and public drainage improvements accepted by the City shall be dedicated to the City and warranted for a period of twenty-four (24) months following acceptance by the City, as provided above. 16. Performance Guarantee for Public Improvements. In order to secure the construction and installation of the Public Improvements the Developer shall, within ninety (90) days after the execution of this Agreement, furnish the City, at the Developer's expense, with the Performance Guarantee described herein. The Performance Guarantee provided by the Developer shall be in the form of an irrevocable letter of credit in which the City is designated as beneficiary, for one hundred twenty-five percent (125%) of the estimated costs of the Public Improvements to be constructed and installed as set forth in Section 1.0 of Exhibit D, if applicable to secure the performance and completion of the Public Improvements as required by Section 26-418 Security for Required Improvements, of the Wheat Ridge Subdivision Regulations. The Developer agrees that approval of this Agreement by the City is : untingent upon the Developer's provision of an irrevocable letter of credit to the City within ninety (90) days of the execution of this Agreement in the amount and form provided herein. Failure of the Developer to provide an irrevocable letter of credit to the City in the manner provided herein shall negate the City's approval of this Agreement. Letters of credit shall be substantially in the form and content set forth in Exhibit E, if applicable, and shall be subject to the review and approval of the City Attomey. The Developer shall not start any construction of any public or private improvement on the Property including, but not limited to, staking, earthwork, overlot grading or the erection of any structure, temporary or otherwise, until the City has received and approved the irrevocable letter of credit. Notwithstanding the foregoing, the Developer may obtain the appropriate permits and commence demolition and/or remediation of the Property prior to the City's receipt and approval of the irrevocable letter of credit. The estimated costs of the Public Improvements shall be a figure mutually agreed upon by the Developer and the Director, as set forth in Exhibit D if applicable. If, however, they are unable to agree, the Director's estimate shall govern after giving consideration to information provided by the Developer including, but not limited to, construction contracts and engineering estimates. The purpose of the cost estimate is solely to determine the amount of security. No representations are made as to the accuracy of these estimates, and the Developer agrees to pay the actual cons of all such Public Improvements. 7 The estimated costs of the Public Improvements may increase in the future. Accordingly, the City reserves the right to review and adjust the cost estimate on an annual basis. If the City adjusts the cost estimate for the Public Improvements, the City shall give written notice to the Developer. The Developer shall, within thirty (30) days after receipt of said written notice, provide the City with a new or amended letter of credit in the amount of the adjusted cost estimates. If the Developer refuses or fails to so provide the City with a new or amended letter of credit, the City may exercise the remedies provided for in this Agreement; provided, however, that prior to increasing the amount of additional security required, the City shall give credit to the Developer for all required Public Improvements which have actually been completed so that the amount of security required at all time shall relate to the cost of required Public Improvements not yet constructed. In the event the Public Improvements are not constructed or completed within the period of time specified by Section 11 of this Agreement or a written extension of time mutually agreed upon by the Parties to this Agreement, the City may draw on the letter of credit to complete the Public Improvements called for in this Agreement. In the event the letter of credit is to expire within fourteen (14) calendar days and the Developer has not yet provided a satisfactory replacement, the City may draw on the letter of credit and either hold such funds as security for performance of this Agreement or spend such funds to finish Public Improvements or correct problems with the Public Improvements as the City deems appropriate. Upon completion of performance of such improvements, conditions and requirements within the required time, the Developer shall issue an irrevocable letter of credit to the City in the amount of twenty-five percent (25%) of the total cost of construction and installation of the Public Improvements (including the cost of landscaping), to be held by the City during the Warranty Period. If the Public Improvements are not completed within the required time, the monies may be used to complete the improvements. If the Public Improvements require repair or replacement during the Warranty Period and the Developer fails to complete said repairs or replacement prior to the end of the Warranty Period, the City may draw on the letter of credit to make required repairs or replacements to the Improvements. 17. Indemnification. The Developer shall indemnify and hold harmless the City and its officers, employees, agents or servants from any and all suits, actions, and claims of every nature and description caused by, arising from or on account of this Agreement any act or omission of the Developer, or of any other person or entity for whose act or omission the Developer is liable, with respect to the Improvements; and the Developer shall pay any and all judgments rendered against the City as a result of any suit, action, or claim, together with all reasonable expenses and attorney's fees and costs incurred by the City in defending any such suit, action or claim. The Developer shall pay all property taxes due on any portion of the Property dedicated to the City and shall indemnify and hold harmless the City for any property tax liability in connection therewith. (I 18. Waiver of Defects. In executing this Agreement, the Developer waives all objections it may have concerning defects, if any, in the formalities whereby it is executed, or concerning the power of the City to impose conditions on the Developer as set forth herein, and concerning the procedure, substance, and form of the ordinances or resolutions adopting this Agreement. 19. Third Party Beneficiaries. There are and shall be no third party beneficiaries to this Agreement. 20. Modifications. This instrument embodies the whole agreement of the Parties. There are no promises, terms, conditions, or obligations other thar those contained herein; and this Agreement shall supersede all previous communications, representations, or agreements, either verbal or written, between the Parties. There shall be no modification of this Agreement except in writing, executed with the same formalities as this instrument. Subject to the conditions precedent herein, this Agreement may be enforced in any court of competent jurisdiction. 21. Release of Liability. It is expressly understood that the City cannot be legally bound by the representations of any of its agents or their designees except in accordance with the City of Wheat Ridge Code of Ordinances and the laws of the State of Colorado. 22. Captions. The captions to this Agreement are inserted only for the purpose of convenient reference and in no way define, limit, or prescribe the scope or intent of this Agreement or any part thereof. 23. Binding Effect. This Agreement shall be binding upon and inure to the benefit of the Parties hereto and their respective heirs, successors, and assigns as the case may be. 24. No Waiver. No waiver of any of the provisions of this Agreement shall be deemed or constitute a waiver of any other provisions herein, nor shall such waiver constitute a continuing waiver unless otherwise expressly provided, nor shall the waiver of any default hereunder be deemed a waiver of any subsequent default hereunder. 25. Invalid Provision. If any provision of this Agreement shall be determined to be void by any court of competent jurisdiction, then such determination shall not affect any other provision hereof, all of the other provisions shall remain in full force and effect. It is the intention of the Parties that if any provision of this Agreement is capable of two constructions, one of which would render the provision void, and the other which would render the provision valid, then the provision shall have the meaning which renders it valid. 26. Governing Law. The laws of the State of Colorado shall govern the validity, performance and enforcement of this Agreement. Should either party institute 9 1� legal suit or action for enforcement of any obligation contained herein, venue of such suit or action shall be in Jefferson County, Colorado. 27. Attorneys Fees. Should this Agreement become the subject of litigation to resolve a claim of default of performance or payment by the Developer and a court of competent jurisdiction finds in favor of the City, the Developer shall pay the City's attorney's fees and court costs. 28. Notice. All notices required under this Agreement shall be in writing and shall be hand delivered or sent by registered or certified mail, return receipt requested, postage prepaid, to the addresses of the Parties herein set forth. All notices so given shall be considered effective seventy-two (72) hours after deposit in the United States mail with the proper address as set forth below. Either Party by notice so given may change the address to which future notices shall be sent. Notice to Developer: �l 00 /,�V i!hL.lx Z I N Scp w l vela 3 39 Notice to City: Community Development Director 7500 West 29th Avenue Wheat Ridge, CO 80033 City Attorney 7500 West 29th Avenue Wheat Ridge, CO 80033 29. Force Maieure. Whenever the Developer is required to complete the construction, repair, or replacement of Public Improvements by an agreed deadline, the Developer shall be entitled to an extension of time equal to a delay in completing the foregoing due to unforeseeable causes beyond the control and without the fault or negligence of the Developer including, but not restricted to, acts of God, weather, fires and strikes. 30. Assignment or Assignments. There shall be no transfer or assignment of any of the rights or obligations of the Developer under this Agreement without the prior written approval of the City. 31. Recording of Agreement. This Agreement shall be recorded in the real estate records of Jefferson County and shall be a covenant running with the Property in order to put prospective purchases or other interested parties on notice as to the terms and provisions hereof. 10 32. Title and Authority. The Developer expressly warrants and represents to the City that it is the record owner of the property constituting the Property and further represents and warrants, together with the undersigned individual(s) that the undersigned individual(s) has or have full power and authority to enter into this Subdivision Improvement Agreement. The Developer and the undersigned individual(s) understand that the City is relying on such representations and warranties in entering into this Agreement. WHEREFORE, the Parties hereto have executed this Agreement on the day and year first above written. [Remainder of Page Intentionally Left Blank] 11 ATTEST: 4 Stev r patrick, City Clerk CITY OF WHEAT RIDGE, COLORADO B,V : y j �� Bud Starker, Mayor 12 DEVELOPER 4600 Kipling, LLC By: Name: Pi6�6-r-� Title: Wilt STATE OF COLORADO SS. COUNTY OF The foregoing instrument was acknod(rledged before me this day of (SEAL) 20 , by of Witness my hand and official seal. My commission expires: Notary Public , as 13 ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. State of California County oflCY��t-t:� ) On r��►�1)- -� before me, IvA (insert name and title of the officer) personally appeared ?\ Gk(j--- J �,d)jLk- who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature (Seal) �\ A.J.CASCADDEN _ /,,;`€°""" - Notary Public • California .; Los Angeles Ceunty Commission z 2s6092< �N. Cc,rT. Expires !_I 1C. -1q EXHIBIT A Legal Description of Developer Property STATION SUBDIVISION, CITY OF WHEAT RIDGE, COUNTY OF JEFFERSON, STATE OF COLORADO 14 �b EXHIBIT B Final Plat (see attached) 15 01A8ns ONV 910'IZ'ON BOf 133HSN3A00 E/1139HS mn1� DSVU 3SaNYI u�od io fivN3e 1 0 MM3"0 31ND NO ONv ao OCIVdO100'3OGN 1Y3HM uqM, , Yy I I[ff O°V fN3�11 NOISIAlognS N0I1b1S 9 3'1 N°a3NY� i0f VUSV IUIND iO NOIfNa3Mf S.0 dEiM lYJINHJ31 IZ'FI'10 IOIp 3AY IAMYJ N3M M 09tB U3al° 3Nt NOLLVbYd3Nd 1YM91N0 IZ'91'f0 On'9Nu3MNODWgI rearm �ara3ad 1Yld NOSIA109liS N011dle053(1 - 31V0 E; !o E In jR dig pfl gFg� z g..a -g �== 1'5 s O = � �2:1 W $- 5 $ �d2 S 3 = z `p g= .. W 'aS eft g�Ed � O O Q Q Q Q es'G$f s€`E ago "v 25; at x f ze °as w a tta 3 3^aS°Y `ag�v Z fI_ ua Asa �JU �Q� W W U O U V) Z W z x QL1-Q00 '� W I- Ze = 1 Q W \ < Q VLL. it a l 1 U x C/) W O LL W W W k < `gx3 m3 g LU U ci 3 0 �ZOQU v) LLJ Z rg b�� ab$.oz e 6 I c7€ t= N Ll- ODo It 'XINSIp HxW€ � 9 ee � ����E-� x � e xx� � � a x Hip g$.JIM m - U gO x =� xhl g $ =< e�g mg g s 3s rae ax g a�sn Yn i4 e It z 8g ° aW f. 7 - 'gal sc �� °€3 nx 9 _ s 5"a =ac $ ae��g aoa s= es $Wu 0' a 3 gi 3€€ i=g$x3 0 im lhl 6 HH g 11 o.u,vs O.v rommvroo 910'IZ'ON & SNOWONOO ONIISIX3 6/Z 133HS 3aNav 3dtl0$4NV1 OwH33NOAMO N3 vN0 I iNoa i0 ilv�3e aNr aoi Icx oN asreon OQYNOl00"3001N 1V3HM 1 aoowo N � 9E899SZQLL Elm OO'NO IUI ��r v w io NgSWB i NOISIAlcionS NOIIVIS SN019A3a 1tlO1NH031 NCLLtlatld3ad ltlwOlaO - fL'fl"ri1 ILYI'M) IN 3AVUMVON3a M0908 On'ONu1MNOOMINI aaaNn®In®aa ll3Ca 3Nl 1VId NONIAKIOM NOI1dINOS30 - 31V0 ;n RZ ?a W S z Jim _ ,s9rarn _ �� �---.3AVH1bb.M 9f FF.aas 9-- nLLF.0-- � o� ear:W.... '�'�I 39 iu Iu Hi Lao $C 6 9 � �+ ,GIYtlI M1f,Ol.69S l mva I IP I 31E AS.6Yx � I q I J � z O§ IB I Q 0�N= Ei Q I ¢ 3� i C\i E2 e I CvwO— Z ` J - ,990113.[f,rF.g9N Yo° O 2 o F I $ e J O O m„aw o A �� � oa� M < 1 < Z �0CL $ zw=N W F'— z ° W _z a g Y Cn o W g I > Q I_ I m�nLWOw aI Z O W IZa 2 3 O �a v> Z LU >- OF'OZZ 3GF�ZF,f9N 1 OLL = W � j �� I CI311VIdV1dNf1 F—_ O O Z U I Z O I I g8 �I.,r.�J �%% O W o O< z (� 8 Y"a� 2� $ ce�::wuicStYE i V) Q 0 LU C 2 i agQ i �3 y5y5 Q 3 f IIn Wo = W z 0 U i------------ z }fig e o z 33"s�o pg �9 MC I ■ I ,. [as'.a �.z Cg I E I I I• � i , ■ sW t=====--------gg-�-_� z� I i8 I i N1251 m s§3Xa: mm �T5 ,9f'SFZ 3,[7,97,b'BN Dh �2 �� f l� ow"S aNV 3anLaW:,V 3dYJsaW >n'ownsxo> Woe a03lV19Y 910'tZ'ON 90f NOliva1OI1NOJ 101 M3N £/£133HS OOVMOl003O01J 1V3HM oMa33NoN3IN3 No ary ao I ItR'ON 3SN3>a 1 �NI�NNYid 9Z9 LD 9LIO90J'NO131111t ap lzplylggK NOISIn1aum N0I1d1S SN"VdgMijVMVdll NOLLtlaYdOI lYOSK EZ11- IL"91'K3 Ml'3AtlIAMVJN3MM09Y9 >n'oxmnsxoo 3xk>d u3ap>u a3a'n alatle3ae ltlld NOISINo90S NOI1dIilOS34 - 31V0 zlL--L Al .s9'rnL 9FB9.u9s 3AVH144'M -- 5gvg I szs 3.zE as.a9N a9rN F.o9.w9 I �F .it9a aaP EE �W I R-Mi 8 f r ;laa F I n Fs 8a" 3q0 �I3 S ze b Z ; y3 lwwr..( IA9.dBS 31E g5.6Bx E OI¢ z O Icy Q :d�� FOz ESQ I bvG N I R O N w C J � orr3 f.ZF. Nz maaW i Z O wwUO gT UcnZw z �0CL s O Z 2 i zsUj 'O Z cn o W "Y I > < Z:) 5 U_, m cn w O Z F— 3 y� r3 p w r ;al_,_ I = O 3 �e rre9E M�E.EE RED_ gnu - T e> a s Z U W W _ __ OFDZZ 3.bfiFEe j 301 .Q s $ AYN O-1H91x>f1911d,E9 Or w 2 W 2 E _—_ I - _ — •Id H1St, A o _ � p (D p Q v> 0 z - ZZQ cn0 LL, �w W gg Z p 7�1 $ i��'tl: uicstYE CL O I o ^PI `z$I I m Q V) Q� LU M 1 I Q 3=6 3. 2 HIP ig c-I Ut" Di` _ ` OII � U r------- I k„6i ?,�c o h $ gpG AFC sQ �=a Ca8�131x��>�'s�a I I SSY° m�<a o $ i o w I rim o cgs A a�3� I iY I FY�s� �aa i I K cib ,9F5BZ 9.Lf,9f.68N if .9E.69 d $i 0 0 EXHIBIT C Phasing Plan for Public Improvements and On -Site Improvements The Public and On -Site improvements for the property shall be installed as outlined below. Future SIAs shall be required for each Block to specify requirements unique to each Block and proposed development, including additional requirements for receiving Certificates of Occupancy (C.O.). Public Improvements: As provided in Section 11, all Public Improvements shall be completed by October 30, 2025, but may be completed in phases as outlined below: Phasing for permit issuance: Prior to the issuance of vertical building permits in Block 2, paved access adequate for Arvada Fire and inspector access shall be installed within the Jellison Street and W. 45th Place ROW. See On -Site Improvements for additional requirements needed prior to issuance of vertical building permits. Lighting, landscaping, sidewalks, and top lift shall not be required prior to issuance of vertical building permits. Prior to the issuance of vertical building permits in Block 1, paved access adequate for Arvada Fire and inspector access shall be installed within the W. 45th Place ROW. Other than the requirements above, vertical building permits for either Block may be issued prior to the completion of Public Improvements, including all of those along the Kipling Street and W. 44th Avenue frontages. Phasinq for C.O. issuance: All Public Improvements shall be completed prior to the first Certificate of Occupancy in either Block. This includes all right-of-way improvements for both Blocks including top lift of W. 45th Place and Jellison Street; curb, gutter, sidewalks, lighting, fixtures, signage, striping, landscaping, an irrigation on all Public Streets (45th Place, Jellison, Kipling, and 44th Avenue); all utilities in ROW and any necessary on -site utilities including water and sanitation mains. This shall include the off -site sidewalk connection on the north side of the site along Kipling Street to the sidewalk adjacent to 4700 Kipling Street to ensure a continuous sidewalk; this requirement shall apply if the City and Developer are able to secure the ability to construct the improvements within/along 4700 Kipling Street. Until such time that the ability to construct is secured, the sidewalk shall terminate at the northern property line. Finalization of the land transfer for the CDOT Right -of -Way in Kipling Street (portion of Tract B) shall be completed prior to the first C.O. in either block. All water detention facilities including the underground detention facilities and all stormwater improvements shall be completed prior to the first C.O. for any of the developments being served by those stormwater improvements. 16 On -Site Improvements: Prior to issuance of vertical building permits for anticipated development in Block 2, a future subdivision improvement agreement shall be required for Block 2 to specify the installation, timing and sequence of on -site drive aisles sufficient for fire department and building inspector access. A replat shall be required for Block 2 to dedicate appropriate access and emergency access easements, utility easements, water detention easements, and the appropriate right-of-way for the RTD bus stop on Kipling Street. Prior to issuance of the first vertical building permit for Block 1, the on -site drive aisle along the eastern boundary of Block 1 as shown in the Concept Plan shall be installed to allow sufficient paved access for Arvada Fire and building inspectors; ligh"L-ing, landscaping, top lift, and sidewalks are not required to be installed prior to issuance of vertical permits for Block 1. Additional access may be required by Arvada Fire prior to issuance of vertical permits for Block 1. A future subdivision improvement agreement shall be required for Block 1 prior to issuance of permits for Block 1. A replat shall be required for Block 1 to dedicate appropriate access and emergency access easements (including for the on -site drive aisle along the eastern boundary), utility easements, water detention easements, and to create individual lots for each development site as necessary. Notes on Permit Issuance for Block 2 (also shall be included in future SIA for Block 2 replat): • A Site Work Permit for horizontal construction in Block 2 may be issued upon approval of civil construction drawings (CDs), construction control plan (CDs), stormwater management plan (SWMP), submittal of the required Letter of Credit for the Public Improvements, and payment of the required City use tax. • Foundation -only building permits may be issued for all buildings in Block 2 upon submittal of separate foundation -only permit applications and plans to the City and appropriate plan review, permit, and use tax fees paid. These permits may be issued prior to completion of the required paved access in order to allow concurrent construction and pouring of concrete. • Vertical building permits (which will allow combustible vertical construction) shall only be issued for buildings in Block 2 after all required paved Public and On -Site access is completed per the requirements in the Public and On -Site improvements sections. In addition, the following shall be completed prior to issuance of vertical building permits: o All applicable foundation inspections have been conducted by the City and the foundations have passed inspections. o Installation of water mains and activations of the appropriate fire hydrants for the respective phase, with written acknowledgement from the water and/or fire districts. Exception to the above requirements: 17 ai US • Installation of landscaping, street trees, and irrigation is not required prior to Certificate of Occupancy of issuance of C.O. occurs outside of the planting season, generally October to June. Refer to Section 12 of this Agreement. IN EXHIBIT D Section 1, 0 — Cost Estimate for Public Improvements (see attached) 19 STATION at Wheat Ridge Engineers Estimate of Probable Cost Public Improvement Cost Estimate Prepared by: Point Consulting, LLC Date: November 20, 2023 SITEWORK Quantity Unit Unit Cost ;Current OPC Temporary Site Items j - -----------------------------------------------------------------------------------------------------*-------------- Const action Fencing around site, pond, building etc. ; - ;L.F. ; - $2 50 ------- -- ----- ---- $0 ------ - - �raveTlay mown aridsfagirig"areas ; - t ;Lump Sum ; -- $15,000.00 ; - $15,000 0 u - o a emporary bite items $15,000 Demolition of Natural Features --------------------------------------------------------------------------------------------------------------------f------------------F----------------F-------------------i---------------------- Site Gear, grub and preparation (6" and smaller trees) 1_28 `AC $21500.00 $3.200 emovaTbflarge stumps andiBTiri voids �S" aridTa�ge"r ifiameief sfumpsj ; 4 ;EACH ; $2,000.00 ; $8,000 bub-total uemolition o aura ea ures1 $11,200 Site Preparation/Demolition ----------------- ----- ----------------------------------------------------------------------------------------------------------------- Demo existing wet utilities (Water) ------------------------------------------ 125 L F -$15 00----�--------- 875 Demo existing paving ------------------------------------------------------------------------------------------------------------ 1 1,626 1S.Y. ----------- 1 $25.00 ; $40,650 ------------------ ----- Demo existing curb and gutter - - 4--- 1,615 ;L.F. •--------------- +------------ - -- ------ i-------------------- $12.00 $19,380 Removal of Inlet / Manholes (Sizes based on cy quantities) ; 4 EACH 1 $2,000.00 1 - $8,000 -------- ---- ----+- --------------F-------------+---------------- SidewalkTfe F�replDemb 900 ;S.Y. -i------------------- -- $45.00 $40,500 Sub -total i e rep emo i ion 1 $110,405 Earthwork -----------------------------------------------------------------------------------------------------------------------------------------------------1-------------------•-------------------- Remove top soils (6" Assumption) 1 980 1CY ; $15.00 ; $14,700 ------------- - - - --- --+- -- -----------t-----------------------------------i --------- Proof roll site (Roadway Sections) ; 57,000 ;SF T $1 00 ------------------- ---------------------------------------------- -- - $57.000_ Bank dirt cut and reuse on site 228 ICY $10 00 $2 280 - - - - - - - - - - - - - - ------+- -------- + -------- --t----- --------i -------------- Off site Import from Borrow Pit (Operations performed by Earth Contractor) 2,520 ,CY $30 00 $75,600_ �uT and F1f12ofat;on TorF;nisfi Grade - 300 ;CY i $6.00 $1,800 Sub -total a wor $151,380 Erosion and Sediment Control ----------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------------- Erosion control temporary silt fencing 1,500 ;L.F- $215 $3,225 Erosion control silt fence inlet protection ; 6 ;EACH ; $500.00 ; $3_000- - - - - - r-----------------------' Truck exit wash down area as need and/or I$10,000.00 ------------------------------------------ - $0 Temporary truck wash out pit --- ; ---- • --------T--- --------------------- ;EACH ; $7,500.00 ; ------- $0 ------------------------------------------------ ermanent Seeding arid-�fabiliiation ` - - 1-----------y 12.15 ;AC -------------- $2,200.00 ------- $26,730 Yg,735 Sub -total Erosion an a ;men on ro $32,955 Storm Drainage Storm Sewer ------------------------------------------------------------------------------------------------------------------------------------------------------------------------------ 15 inch dia. RCP Pipe 13 ;L.F. $245.-- ------------ $3,185 18 inch dia. RCP 640ALF. ; $152 00 ; $97,280 -Pipe - - - ----- - 24 inch dia. RCP Pipe ---------------------------------------------------------------------------------------------------------- - 732 ;L.F. $185.00 $135,420 30 inch dia. RCP Pipe -4`-- ------------------------------------------------------------------------------------------------------------------1---------------I' ----- S $200.00-' - $ 28.800 Drainage Structures Pre Cast Structures (includes excavation, backfill and compaction) - ------------•------------------ --------------- Wheat Ridge Curb Inlet _ Single ; 8 'EACH -^------------------------------------------ ; $7,500.00 ; $60,000 Wheat Ridge Curb Inlet: Triple - +-------------------------------t------------------i-------------------- 3 ;EACH ; $10,600.00 ; $31,800 - CDOT Type R Inlet_ 10 Foot ------------------------------- -------------------------------------------------------------- ; 17EACH 1 $14,500 00 $14,500 +--------- -+--------------- ------- 24" Storm End Cap 1 ;EACH - - +------------- ; ----- $4,000.00 - -- i----------- --------------------- ---------- $4,000 48" Manholes ; 3 !EACH ; $7,500.00 1 $22,500 -----------------------------------------------------------------------------------------------------------------+------------------I•---------------+-------------------i--------------------- 60" Manholes 5 ;EACH $10,000.00 $50,000 72" Manholes ; 1 !EACH ; $15,000.00 ; $15,000 -----------------------------------------------------------------------------------------------------------------+------------------I•---------------+------------------i--------------------- 48" Water Quality Manhole 1 ;EACH ; $14,000.00 ; $14,000 _ nde�gfoundUefenfion Sytem (ATiFeafures ar dTiuct iies7ricT� ---------------------t--------- ; 5.'U -----------------�-------------------1------- 59,000CF $12.00 -------------- $708,000 Sub -total orm Drainage $1,184,485 a41 Landscaping Trees Small - -------------------------------------------------------------------------------- -- - -- 19yEACH I $550.00 I $10.450 Trees Large 29 ;EACH 1 $800 00 1 $23,200 --_---------- ----- ---------------- - - - - Shrubs/Plants _ _ _ - - _ _ - -319?EACH - - --------------- - -_ I $55.00 1 $17,545 Green Area sod�top sails etc_-------------------------------------------------------------------- t - -5,796 SF ---------T---- - - - - - - -- -- -----a------ 592- Green Area seeding_ top soils etc. ; 9,365 ISF 1 $1.50 1 -- $14,048 _ _ - _ _ -- - - _ -- '--------- ------t----------- t---- ------- -----'------------------- Green Area shrub mulching top soils etc 8,857 ;SF $1_75- $15,500- Landscape Area mulching top soils etc.$824 Bench fumishin�s - - - - - - - - - - 7 !EACH - - - T - - 1 $1 500 00 $101500 T--=- - a Trash recepticle furnishing 7 :EACH - 1 $800.00 1 - - $5,600 _-------- _--- _--- _ ------- _--------------------- __ -------t---------------t-------------- Site lighting pedestrian 33 ;EACH ---------------i-------------------- $7,500.00 $247,500 Site lighting street _ - - - - - - - - I 19?EACH `------- 1 $g,000.00 1 $171,000 - - Elecirical Service Installation - - - - - - - - - - -- 2 :EACH ----- $10 000.00 1 $20,000 rogation system I 24,842 ISF : $2.00 $49 684 Sub -total Landscaping $597,442 UTILITIES Water Service - - - - - - - - - - - - - - - - - 6 DI - - - - - - - - - - - - - - - + - - - - - -------------T--- - 9�?� F - - - - - ------------------ 00 1 $11,880 12" DI - -- ------------------------------------------------------------------------------- - - 10 lL.F. -$132 - 1------------------- $250.00 $2,500 _7 12" C-900 PVC ; _ - - - - 2.040?L F T $126. 0 - I $-26.00 I $257,040 $257,040 - Ta valve, valve box, i e/fittin sand mainline tee 1 35 EACH - e - - - - - p P---- _q------- ------e tee -------- ------- -------- - --- ----------------- ---- - 1 $1 200.00 $42,000 -° - � - - - Fire Hydrant 6" includes fire hydrant, valve, valve box, pipe/fittings and mainline tee ; 5 :EACH 1 $9,750.00 1 $48.750 12" Gate Valve with valve box 13 ,EACH I $,00.00 $15,00 mga-fionWaterNfeie"r-- --- --- -- ______ I 2'IEACI-I I $7,500.00 I $15,000 u - o a a er ervlce $413,570 Sanitary Sewer 8" PVC-SDR35 - - - - - ---------------------------------------------------------------------------- Manhole P.C. cover 1 1,4791L.F. { - - - +-- --- ------+- 1 $13700 1 - -=- $202,623 with ______________1____________81EACH- - - - -- - 1 $7,000_00 J corinectiiri sariiCa sewer 1 'EACH ____$56,000- $4,500.00 1 $4,500 Sub -total Sanitary Sewer $263,123 PAVING AND PARKING LOT PAVING Regular duty asphalt (6" AC) 780 !TON ! - $105.00 $81,900 - - - - - - - - - - - - - - - - - - - - Heavy duty asphalt19__AC)__------------ - _ _ - - - -------T--------- - -- -------- - 7 - 1,700 TON --- -- --T---- - - - $105.00 $178,500 Aggregate Base Course (ABC)- - - - ---- ------------------------------------ - - i _ 1.850 !TON - ! $50.00 j $92.500 ------------ -ncrete Median Concrete Median $22,500- - -- - - Sidewalks ! 2,5301S.Y. ! $82.00 $207,460 - - - ------------------------------------------------------------------------------ Si�na�e +------- - 1?L.S________-T $97,650.00 $97,650 Traffic Control ! 1 lL.S. ! $83,000.00 ! $83,000 Drivecut _----------___- ------------------------------------------------------------------------------ --- 1_ _ 1.300ySF - - -L---$---------1___ $15.600 Porkchop ! 3 !EACH ! $3,600.00 1 $10,800 - f - -- ConcreteCrosspan- _ --2.100FSF - 7 $15.00 - $31.500� ADA Ramps ! 12 :EACH ! $2,000.00 1 $24,000 �6- eiid-guli4Fuliiic F- -------------------------------------------- --------------------------- +-------3, -- ,250?LF.---------- - - - - $31.00 1 - - - $100,750 Sub -total Paving and Flanking Lot $946,160 vublic improvements Un-bite Uonstruction Staking Construction Staking 1 Lump Sum 1 $30,000.00 $30,000 Sub -total Public Improvements n- l e Construction b a Ing $30,000 3,755,720 6% $225,343 $3,981,063 25 % $995,266 4,976,329 Approved City of Wheat Ritlge -Community Development Engineering Division Rocky Macsalka, Development Review 1112012023 Section 2. D — Cost Estimate for On -Site Improvements STATION at Wheat Ridge Engineers Estimate of Probable Cost Private Improvement Cost Estimate Prepared by: Point Consulting, LLC Date: November 20. 2023 SITEWORK Quantity Unit Unit Cost 1Current OPC Temporary Site Items -- --"--'"-"'"-"----"-"------'---"-"---------------"-----""-"-""-"---'""---"--"r-"______------f-"'"'-"'"--"----- Construction Fencing around site, pond, building etc 4,100 ILF $2.50 $10,250 Gr°a"vefTay Sow"ri aiid-sfagiiig area<�'���--�--`--------'-----"-""-"-�-"-----""---""---"--""-- I ---------`-1 (Lump Sum I $15,000.00 I _ $15,000 Sub -total Iemporary Site items $25,250 Demolition of Natural Features - - - - - - - - - - - --"-------------------------------------- Site clear, g ub and preparNc (6" and smaller trees; emoJaToTTai""e sfum-"s m"void9 8" dri Tar er diamefei slum "s """-"""-"""""""-""" I-------------1X---------- i i;EACH----t--------- I ------ ---------`-------- 10.87 IAC 1 $2,500.00 ; -- #---- ,------- $27,175 ------- aria-fiTl 9 P t 9 P j 18 $2,000.00 $36,0 $36,000 Sub -total emo i ion ot Naturalea ureE 63,175 Earthwork r--- -emov-op-soils-(6"-Ass-ump-tion) - - - - - -- - - -; - -_8_,8_0_rC- _______-__;r- $15.00 ; -------- ---- - $132,300 Proof roll site (Access Sections) 1 -_______-__---- 49,50F $1.00 0 IS _ $49,500 - - - - - - - - ----- ------- -------- - --- - ------ - Bank dirt cut and reuse on site --- -------- - --- -t- - -- r------ - ----- t-------- ------- 2,050 ICY $10 00 - $20 500 --------------------------- ------------------------------------------------------------ - - - -----------------F------------+--------=------#---------=-------- Off site Import from Borrow Pit (Operations performed by Earth Contractor) t 15,830 ICY 1 $30.00 ; $474,900 G'uiandTill l�pTaTlOnT6F7tFfsITGF5dE _____ --_______-___-_______-___-�-_ _ ______-_ti-____________-__1____-___-__-_____ 2,700'CY $6.00 $16,200 Sub -total a wo 693,400 Erosion and Sediment Control - - - - - - ---------- - ------------ -------- - Erosion control temporary silt fencing Erosion control silt fence inlet ------------ ---- ------------ ; ------------ ------ --------- - --- -------- 2,600 'LF $2.15 4 ---- -------- - -$5_590 - protectior ------------------------------------------------------------------------------------------T----------'-t Truck exit wash down area as need and/or require( - - - - - - - - -------------- ---- - ------- - ; ------------ - -� - ;EACH ; $500.00 -- - --7--- --- ---r----- 1 EACH , $10,000.00 - `-- $2,000 --------- $10,000 - -""-- --- - Temporary truck wash out pit 1 1 1EACH 1 $7,500.00 ; --- 9Tife'9fefilGza r5n "-`"' - - - - - - - - - - - - - - --+--------f 0.87 ----------4- $------ 00 ------ $7,500 6ub-total Lrosion ana Sedimenton ro $49,004 Storm Drainage Storm Sewer -------------------------------------------------------------------- I-------------13-•--'LF inch dia. RCP Pipe --------- 18 inch dia. RCP Pipe ----------- - - - - - - 1 -- 640 LF $152 00 $97,280 24 inch dia. RCP Pipe 1 - 732 ILF I $185.00 1 - $135,420 -----" --- --- - - - - - - - - - - - - - 30 inch dia. RCP Pipe -rpe -j -- Drainage Structures Pre Cast Structures (includes excavation, backfill and compaction) - - - - - - -------------------- - - - - --------------------------------------------------------------------------------- Wheat Ridge Curb Inlet- Single ---------------------------------------------------------------------------------------------------i----------------F----------------------- I 8 IEACH 1 $7,500.00 ; $60,000 Wheat Ridge Curb Inlet - Triple 3 IEACH ; $10,600.00 ; $31,800 CT Type R Inlet ---- Foot - - - - - - - - -- CDOT Type R- 10 Foot - - -r - 1 - - -• - - - •- ---"--- • 1 IEACH ; $------ ; - 1-4,5------- $14,500 24" Storm End Cap _------------------------------------------ "-------------------- �-'""-"- - - - ----------------- --- ....... 1 EEACH------�-$4=000.00 --�-----$4,000 48" Manholes 1 3 IEACH $7,500.00 ----- $22,500 60" Manholes - - - - - - - - - - - - - - - j 5 EACH $10,000.00 $50,000 - 72" Manholes 1- EACH $15 000.00 $15,000 - ------------------------------------------------------------------------�----- 48" Water Quality ManholE ` - - - -, "--------------------=- -------- -------------'--- -------- 't 1 'EACH $14 -------- - ' _ �CUFT + i $14---- r oeig�o irid CTeFent on"$yiem ZAIi Feaiiires anfr iciu"es fncT 59,000 $12.00 $708,000 Sub -total Sorm Drainage $1,184,485 UTILITIES Water Service 6---" --D----I-----------------------------------------------------------------------------------------------------_-___------- 3-7--L------------ f___$13200 ----- T____-$4884 _-_-_-- --------------------------------------------------------------------------- " ----------,----t---. ----PVC--------------------------------------------------------------------- ------ -----------4-------=------- #--------= 6---------1$00- ---"2"-___i-----$-'-8 ---- 9, -- Tap valve, valve box, pipeffittings and mainline teE ; 11 !EACH 1 $1,200.00 1 $13,200 Fire Hydrant 6" includes fire hydrant, valve, valve box, pipeffttings and mainline to 3 EACH $9,75---- t $29,250 12" Gate Valve with valve box I 3 IEACH I $2,800.00 1 $8,400 m"aiionNVaTeil6Teier-------------------------------------------------------------------- -t- 9 - r - - t- 2 Each � $7,500.00 -000 - $15,000 bub-total Water bervice $229,872 Sanitary Sewer 8" PVC-SDR35 - ------------------------------------------------------------ - - -# - 1,416 -L.F. $137 00 $193,992 - ---t----------- 1----------------'----------------- Manhole P.C. with cover 8 EACH 1 $7,000.00 ; --- $56,000 - - ry----------------------------------------------------------t------------ Coi necf on san fa sewer "-"-"---- --t--------------f------------- ---- - 1 EACH $4,500.00 $4,500 Sub -total Sanitary bewer $254,492 Public improvements On-Sne uonstruction Staking ons ruc wn a ing 1 !Lump Sum $30,000.00 30,000 bub-lotal Public Improvements On -bite Construction Stakinc 30,000 PRIVATE IMPROVEMENTS BASE BID AMOUNT $2,529,678 6 % 151,781 2,681,4 9 A roved cM of wnan aiape-cmmmun hr Dm.bn Aq EXHIBIT E Letter of Credit Template (see attached) 21 EXAMPLE LOC — Parentheses O indicate applicant bank defined fields C` (Bank Letterhead) LETTER OF CREDIT # (L.O.C. #) BENEFICIARY: The City of Wheat Ridge ADDRESS: 7500 West 29t1 Avenue, Wheat Ridge, CO 80033 DATE: (Date of Issue) EXPIRY DATE: (Exp. Date) IRREVOCABLE STANDBY LETTER OF CREDIT For: (Developer's Name) (Developer's Address) Gentlemen: We hereby open our IRREVOCABLE STANDBY LETTER OF CREDIT in your favor available by your drafts drawn on (Bank Name, and Address) for any sum or sums not to exceed in total (Amount of L.O.C.). We hereby authorize you to draw on us for the account of (Developer's Name) up to an aggregate amount of (Amount of L.O.C.) (125% engineer's estimated cost of improvements) available by your drafts at sight accompanied by your signed statement that the above is: 1) drawn in payment of street improvements including, but not limited to, curb, gutter, sidewalk, asphalt patching, street paving, and other street improvements shown on the final plat and associated construction documents for The (Project Name) (the "Project"), and/or 2) drawn in payment of storm drainage improvements including, but not limited to, detention pond grading, detention pond outlet structure(s), storm sewer system, and other drainage facilities shown on the final plat and associated construction documents for the Project. Drafts must be accompanied by 1) a sight draft; 2) a signed statement by an authorized representative of the Beneficiary stating as follows: "We hereby certify that the amount of our draft represents funds owed to the City of Wheat Ridge for payment obligations pursuant to the conditions stated above, between (Developer's Name) and the City of Wheat Ridge." 3) This original Letter of Credit. Each draft must bear upon its face a clause "Drawn under Letter of Credit No. (L.O.C. #) dated (Date of Issue). This IRREVOCABLE STANDBY LETTER OF CREDIT is not transferable. We hereby agree with you that drafts drawn under and in compliance with the terms of the Letter of Credit will be duly honored if presented to the above mentioned drawee Bank on or before (Exp. Date). Except as otherwise expressly stated herein, this Letter of Credit and all negotiations hereunder are subject to all applicable provisions of Uniform Customs and Practices for Documentary Credits, 2007 Revision, International Chamber of Commerce Publication No. 600. Sincerely, (BANK NAME) By: (Name and Title of Bank Officer) DEN-132644-2